Loading...
HomeMy WebLinkAbout15- Robert Peccia and Associates, Engineering Pre-design phase for new 5.3 Million Gallon Water Storage Tank PROFESSIONAL SERVICES AGREEMENT THIS IS AN AGREEMENT made as of. . �t S't` l5 , between THE CITY OF BOZEMAN, a Municipal Corporation, Bozeman,Montana,5971. (OWNER)and ROBERT PECCIA AND ASSOCIATES, HELENA,MT, 59604 ,Montana,(ENGINEER). Whereas the accomplishment of the work and services described in this Agreement is essential to the OWNER'S public works improvement program. Whereas the OWNER intends to and has selected the ENGINEER to provide necessary and professional engineering services for the project. Whereas the ENGINEER represents that it is willing and qualified to perform the professional engineering services for this project described in this Agreement_ Therefore, in consideration of the foregoing recitals and the mutual covenants and conditions contained herein,the parties agree as follows: The conditions and provisions set forth in the attached EXHIBIT A (Scope of Services), and EXHIBIT B (Fee Proposal),are hereby incorporated in and made part of this Agreement. ARTICLE I -ENGINEERING SERVICES 1.1. The detailed description of the specific project components is described as follows: This project is the engineering pre-design phase for the design and construction of a new 5.3 million gallon water storage tank. Major work tasks include completion of the design survey and a Final Pre-Design Report. 1.2. The scope of services under this contract is set forth in this agreement and the attached EXHIBITS. ARTICLE 2-ENGINEER'S RESPONSIBILITIES 2.1. ENGINEER shall perform for OWNER professional engineering services in all phases of the Project to which this Agreement applies as hereinafter provided. These services will include, but not be limited to, serving as OWNER's professional engineering representative for the Project, providing professional engineering consultation and advice and furnishing customary civil and structural engineering services incidental thereto. 2.2. The ENGINEER shall furnish all labor,materials,equipment,supplies,and incidentals necessary to conduct and complete the ENGINEER'S portions of the Project and to prepare and deliver to the OWNER all data, reports, plans, specifications,and recommendations as designated herein. 2.3. The ENGINEER shall ascertain such information as may have a bearing on the work from local units of government, public, and private organizations and shall be authorized to procure information from other authorities as to the extent of these contacts and the results thereof. 2.4. The ENGINEER'S work shall be in accordance with the standards of sound engineering practices. 2.5. The ENGINEER shall name a Principal-In-Charge for the duration of the project. The Principal-In-Charge shall be Keith Jensen,P.E.,President. 2.6. The ENGINEER shall name a Project Manager who shall be the liaison between the ENGINEER and the OWNER. The Project Manager shall be Gary Swanson,P.E. .The OWNER may name a Task Director who would be the 1 85 liaison between the ENGINEER and the OWNER during the design segment of the Project. 2.7. The ENGINEER shall submit an estimated progress schedule at the beginning of the work,and monthly progress reports thereafter until the project is completed. ARTICLE 3-OWNER'S RESPONSIBILITIES 3.1 The OWNER shall name a Task Director who shall be the liaison between the ENGINEER and the OWNER during DESIGN segment of the Project. The Task Director designated shall be Robert Murray Jr., P.E. 3.2 The OWNER shall have the right of review and examination of the ENGINEER'S work at all times. 3.3 The OWNER shall make available all records(record drawings,construction records,etc.)indicating the existing configuration of the city utilities. ARTICLE 4-BASIC ENGINEERING SERVICES The ENGINEER shall render professional Engineering Services as follows: 4.1 PRE-DESIGN INVESTIGATION PHASE After written authorization to proceed,ENGINEER shall: 4.1.1 Consult with OWNER to clarify and define OWNER's requirements for the Project and review available data. 4.1.2 Advise OWNER as to the necessity of OWNER's providing or obtaining from others, data or services and assist OWNER in obtaining such data or services. 4.1.3 Identify and analyze requirements of governmental authorities having jurisdiction to approve the design of the Project and participate in consultations with such authorities. 4.1.4. Provide analyses of OWNER's needs, planning surveys, site evaluations and comparative studies of prospective sites and solutions. 4.1.5. Provide a general economic analysis of OWNER's requirements applicable to various alternatives. 4.1.7. Prepare a Report containing schematic layouts, sketches and conceptual design criteria with appropriate exhibits to indicate clearly the considerations involved (including applicable requirements of governmental authorities having jurisdiction as aforesaid) and the alternative solutions available to OWNER and setting forth ENGINEER's findings and recommendations. This Report will be accompanied by ENGINEER's opinion of probable costs for the Project, including the following which will be separately itemized: Construction Cost, allowance for engineering costs and contingencies, and (on the basis of information furnished by OWNER) allowances for such other items as charges of all other professionals and consultants, for the cost of land and rights-of-way, for compensation for or damages to properties,for interest and financing charges and for other services to be provided by others for Owner. The total of all such costs,allowance,etc. are hereinafter called"Total Project Costs". 4.1.8. Furnish 3 copies and an electronic copy of the Study and Report documents and review them in person with OWNER. 2 The Pre-design Investigation Phase will be completed and submitted within 60 calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.2 PRELIMINARY DESIGN PHASE—NOT USED 4.3 FINAL DESIGN PHASE—NOT USED 4.4 BIDDING OR NEGOTIATING PHASE—NOT USED 4.5 CONSTRUCTION PHASE—NOT USED 4.6. PROJECT DOCUMENTATION—NOT USED 4.7. CONSTRUCTION TESTING—NOT USED ARTICLE 5-ADDITIONAL SERVICES 5.1. If OWNER wishes ENGINEER to perform any of the following Additional Services,OWNER shall so instruct ENGINEER in writing, and ENGINEER shall perform or obtain from others such services and will be paid therefor as provided in the Agreement: 5.1.1. Legal land surveys performed to obtain data for preparing easements and rights-of-way descriptions. 5.1.2. Preparation of applications and supporting documents for governmental agencies in addition to those required under Basic Services; preparation or review of environmental studies and related services; and assistance in obtaining environmental approvals. 5.1.3. Services resulting from significant changes in the general scope, extent or character of the Project or major changes in documentation previously accepted by OWNER where changes are due to causes beyond ENGINEER's control. 5.1.4. Providing renderings or models. 5.1.5. Preparing documents for alternate bids requested by OWNER for work not executed or for out-of- sequence work. 5.1.6. Providing other services not otherwise provided for in the Agreement, including services normally furnished by the OWNER as elsewhere herein described. 5.1.7. Furnishing the services of independent professional associates or consultants for other than Basic Services. 5.2. When required by the Contract Documents in circumstances beyond ENGINEER's control, ENGINEER shall perform or obtain from others any of the following Additional Services as circumstances require during construction and 3 without waiting for specific instructions from OWNER, and ENGINEER will be paid therefor as provided in this Agreement: 5.2.1. Services in connection with work directive changes and change orders to reflect the changes requested by OWNER if the resulting change in compensation for Basic Services is not commensurate with the additional services rendered. 5.2.2. Services in making revisions to Drawings and Specifications occasioned by the OWNER'S acceptance of substitutions proposed by Contractor(s); services after the award of each contract in evaluating and determining the acceptability of an unreasonable or excessive number of substitutions proposed by Contractor; and evaluating an unreasonable or extensive number of claims submitted by Contractor(s)or others in connection with the work. 5.2.3. Services resulting from significant delays, changes or price increases occurring as a direct result of materials,equipment or energy shortages. 5.2.4. Additional or extended services during construction made necessary by (1) work damage by fire or other causes during construction, (2) a significant amount of defective or neglected work of any Contractor, (3) acceleration of the progress schedule involving services beyond normal working hours, (4) default by any Contractor. ARTICLE 6- COMPENSATION FOR ENGINEERING SERVICE 6.1 LUMP SUM AGREEMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER 6.1.1 Payment. The OWNER shall for design phase services performed as Basic Engineering Services under sections 4.1 through 4.3 of this agreement pay a total sum in the amount of$ 40,573.00 for such services. 6.1.2 Payment Schedule. Total cumulative payments for the design phase engineering services (sections 4.1 through 4.4)shall not exceed the following ceilings: $ 36.515 (90 % of design fee) until the Pre-design Investigation and Report have been submitted to the OWNER. 6.1.3 General. Engineer shall submit monthly statements for services rendered. The statements shall be based upon Engineer's estimate of the proportion of the total services actually completed at the time of billing, subject to any limitations on Payments based on completion of tasks or specific retainage requirements pursuant to the payment provisions of the Agreement. 6.1.4 Reimbursable Expenses. Only those expenses specifically identified for payment under section 6.2 of this Agreement are reimbursable. All other design related expenses are included in the Lump Sum Payment for the Basic services (4.1 through 4.4) and are not separately reimbursable. Additional Services specifically identified under the scope of design services for payment under 6.I are not separately reimbursable. 6.2 DIRECT LABOR COST PAYMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER. 6.2.4 The OWNER shall pay an amount for Additional Services rendered by the ENGINEER and approved in writing by the OWNER on the basis of the ENGINEER'S Direct Labor Costs times a factor of 3.04, or an amount otherwise negotiated at the time such services are requested and approved by the OWNER. 4 ARTICLE 7-MEANING OF TERMS 7.1 AGREEMENT As used herein the term "this Agreement" refers to the contents of this document and its Exhibits attached hereto and referred to as if they were part of one and the same document. 7.2 CONSTRUCTION COSTS The construction cost of the entire Project(herein referred to as "Construction Cost") means the total cost to OWNER of those portions of the entire Project designed and specified by ENGINEER, but it will not include ENGINEER's compensation and expenses, the cost of land, rights-of-way, or compensation for or damages to, properties unless this Agreement so specifies, nor will it include OWNER's legal, accounting, insurance counseling or auditing services, or interest and financing charges incurred in connection with the Project or the cost of other services to be provided by others to OWNER. 7.3 DIRECT LABOR COSTS Direct Labor Costs used as a basis for payment mean the actual salaries and wages paid to all ENGINEER's personnel engaged directly on the Project, including, but not limited to, engineers, architects, surveyors, designers, drafters, specification writers,estimators,other technical and business personnel;but does not include indirect payroll related costs or fringe benefits. For the purposes of this Agreement the principals and employees of the ENGINEER maximum billable Direct Labor Costs are: Principals $ 61.03 /hour Project Manager $ 50.37 /hour Senior Engineer $ 46.50 /hour Staff Engineer $ 32.20 /hour Structural Engineer $ 46.41 /hour Survey Manager $ 40.47 /hour Surveyor $ 34.23 /hour Survey Crew Chief $ 28.58 /hour CADD Manager $ 31.55 /hour CADD Operator $ 25.62 /hour Accountant $ 31.35 /hour Administrative Assist. $ 22.00 /hour Landscape Architect $ 51.36 /hour 7.4 REIMBURSABLE EXPENSES Reimbursable Expenses mean the actual expenses incurred by ENGINEER or ENGINEER'S independent professional associates or consultants directly in connection with the Project, such as expenses for: transportation and subsistence incidental thereto; obtaining bids or proposals from Contractor(s); subsistence and transportation of Resident Project Representatives and their assistants;toll telephone calls and telegrams; reproduction of reports,Drawings, Specifications, Bidding Documents and similar Project-related items;and if authorized in advance by OWNER,overtime work requiring higher than regular rates. In addition,when compensation for Basic Services is on the basis of Direct Labor Costs method 5 of payment,Reimbursable Expenses will also include the amount billed to ENGINEER by special consultants employed by ENGINEER and authorized by OWNER (other than as an authorized Additional Services) and will also include expenses incurred for computer time and other specialized equipment, including an appropriate charge for previously established programs and expenses of photographic production techniques. ARTICLE 8-PAYMENT PROVISIONS 8.1 TIMES OF PAYMENTS. ENGINEER may submit monthly statements for Basic Services and approved Additional Services rendered and for Reimbursable Expenses incurred; however, payments shall not exceed the ceilings provided in 6.1 and 6.2. Final payment shall be made only after acceptance of the project by the OWNER. If OWNER disputes the amount of the billing, OWNER will notify the ENGINEER in writing within ten (10) calendar days of the receipt of bill of the dispute. 8.2 REQUESTS FOR PAYMENT. Each request for payment shall include a documentation summary of the period incremental man hours incurred,direct Iabor rates and billed rates,detail of reimbursable costs,total period billing, and total cumulative billing. When requested by OWNER services for distinct project segments shall be accounted and billed separately. 8.3 PAYMENT UNDER TERMINATION. In the event of termination by the OWNER upon the completion of any phase of the Basic Services,progress payments due ENGINEER for services rendered through such phase shall constitute total payment for such services. In the event of such termination by OWNER during any phase of the Basic Services, ENGINEER also will be reimbursed for the charges of pre-approved independent professional associates and consultants employed by ENGINEER to render Basic Services, and paid for services rendered during that phase on the basis of the payment provisions of the Agreement. In the event of any such termination, ENGINEER will be paid for unpaid pre- approved Additional Services and unpaid Reimbursable Expenses which are authorized under this agreement. ARTICLE 9-GENERAL CONSIDERATIONS 9.1 TERMINATION OF AGREEMENT 9.1.1 The sole right is hereby reserved to the OWNER to terminate this Engineering Agreement for any and all causes or for its convenience at any time upon fifteen(15)days written notice to the ENGINEER. 9.1.2 If termination for default is effected by the OWNER,an equitable adjustment in the price provided for in this Agreement shall be made, but (1) no amount shall be allowed for anticipated profit on unperformed services or other work,and(2)any payment due to the ENGINEER at the time of termination may be adjusted to cover any additional costs to the OWNER because of the ENGINEER's default. If termination for convenience is effected by the OWNER, the equitable adjustment shall include a reasonable profit, as determined by owner, for services or other work performed. The equitable adjustment for any termination shall provide for payment to the ENGINEER for services rendered and expenses incurred prior to the termination, in addition to termination settlement costs reasonably incurred by the ENGINEER relating to commitments which had become firm prior to the termination. 9.1.3 Upon receipt of a termination action under paragraph 9.1.2, the ENGINEER shall (I) promptly discontinue all affected work(unless the notice directs otherwise),and(2)deliver or otherwise make available to the OWNER within ten (10) days copies of all data, design drawings, specifications, reports, estimates, summaries and such other information and materials as may have been accumulated by the ENGINEER in performing this Agreement,whether completed or in process. 6 9,1.4 In the event this Contract is terminated prior to completion, the original copies of the ENGINEER'S data,recommendations, plans,specifications, analysis and other related documents prepared by the ENGINEER prior to said termination shall be delivered to and become the property of the OWNER. 9.1.5 Upon termination,the OWNER may take over the work and may award another party an Agreement to complete the work under this Agreement. 9.1.6 OWNER'S right to terminate is in addition to any other remedies OWNER may have under the law. 9.2 INSPECTION AND AUDIT All books, papers, records, payrolls, vouchers and invoices relating to costs and expenditures incurred as to the performance of the services by the ENGINEER hereunder shall be made available to the OWNER, or their authorized representatives for audit and review, at the ENGINEER'S respective offices at all reasonable times during the contract period and for three years from the date of final payment. 9.3 EMPLOYMENT The ENGINEER warrants that he has not employed or retained any company or persons, other than a bona fide employee, working solely for the ENGINEER, to solicit to secure this contract, and that he has not paid or agreed to pay any company or person,other than bona fide employees working solely for the ENGINEER,any fee,commission,percentage, brokerage fee, gifts or any other considerations contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty,the OWNER shall have the right to annul the Contract without liability or in its discretion to deduct from the price or consideration or otherwise recover the full amount of such fee, commission, percentage,brokerage fee,gift or contingent fee. All employees of the ENGINEER or other persons while engaged in the performance of work or services required by the ENGINEER shall be considered employees of the ENGINEER only and not of the OWNER. 9.4 NONDISCRIMINATION The ENGINEER will have a policy to provide equal employment opportunity in accordance with all applicable state and federal anti-discrimination laws,regulations,and contracts. The ENGINEER will not refuse employment to a person,bar a person from employment,or discriminate against a person in compensation or in a term,condition,or privilege of employment because of race,color,religion,creed,political ideas, sex, age, marital status, national origin, actual or perceived sexual orientation, gender identity, physical or mental disability,except when the reasonable demands of the position require an age,physical or mental disability,marital status or sex distinction. The ENGINEER shall be subject to and comply with Title VI of the Civil Rights Act of 1964; Section 140,Title 2,United States Code,and all regulations promulgated thereunder. The ENGINEER shall require these nondiscrimination terms of its sub-consultants providing services under this agreement. 9.5 SUBLETTING OR ASSIGNING OF WORK The ENGINEER shall not sublet or assign any of the work covered herein without prior written approval of the OWNER. 7 9.6 STANDARD OF CARE In providing services under this agreement,the ENGINEER will perform in a manner consistent with the degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances. If any service should be found to be not in conformance with this standard, the ENGINEER shall, at the OWNER's request,re- perform the service at its own expense. Engineer shall also, at its own expense, make such changes, modifications or additions to the project which are made necessary as a result of the initial non-performance or the re-performance of services. The OWNER's rights herein are in addition to any other remedies the OWNER may have under the law. 9.7 LEGAL RELATIONS: 9.7.1 The ENGINEER shall, consistent with the standard care, comply with those Federal, State, and Local laws and ordinances applicable to the work to be done. 9.7.2 The ENGINEER agrees to defend, indemnify and hold harmless the OWNER, its officers, directors, agents and employees from and against any suit,cause of action, claim,cost,expenses,obligation and liability of any character, including attorney's fees, which is brought or asserted for any bodily injury, death, or physical damage to property received or sustained by any person, persons,property,business or any other entity,arising out of or resulting from,or in connection with the ENGINEER'S negligent performance of the work specified in this agreement. 9.7.3. The ENGINEER agrees to defend, indemnify and hold harmless the OWNER, its officers, directors, agents and employees, should OWNER, its officers, directors, agents or employees be named as a defendant in any action where the OWNER'S alleged liability arises from the negligent performance of the ENGINEER'S work herein described. The obligations of the ENGINEER to defend,indemnify and hold harmless the OWNER will apply to any suit, cause of action,claim,cost or obligation including,without limitation,those alleged under the common law or pursuant to a federal or state statute or regulation including those arising in tort, trespass, nuisance,and strict liability. 9.7.4 In the event the OWNER is found proportionately responsible for any damages ultimately awarded to a plaintiff or plaintiffs in any lawsuit, the ENGINEER will be responsible for only those damages, costs, or Iiabilities as are attributable to the ENGINEER'S percent of fault as compared with 100%of the fault giving rise to the damages. Should the OWNER be found responsible for negligence by its own officers,directors,agents or employees,then in that event the OWNER agrees to reimburse the ENGINEER for the reasonable attorney's fees and costs incurred in any defense of the OWNER in an amount proportional to the fault attributed to the OWNER. The indemnity required herein shall not be limited by reason of the specification of any particular insurance coverage in this Agreement. 9.7.5 Should either OWNER or ENGINEER be held responsible, for any damages, costs or liabilities resulting from intentional misconduct by any officer, director, agent or employee in connection with the work specified in this Agreement,then in that event,that party shall defend, indemnify and hold harmless the other as to any damages, costs or liabilities that result from or arise out of that intentional misconduct, including reasonable attorney's fees and costs which shall include costs and salary of the city attorney or other in-house counsel. Further,notwithstanding the obligations set forth in paragraphs 9.7.2 and 9.7.3 above,the ENGINEER agrees to defend OWNER where the OWNER'S alleged liability arises from intentional misconduct by the ENGINEER. Should the OWNER be found responsible for intentional misconduct by its own officer, director, agent or employee, then OWNER agrees to reimburse ENGINEER for the reasonable attorney's fees and costs incurred in any defense of the OWNER. 9.7.6 The ENGINEER shall perform this agreement as an independent contractor,and as such,is responsible to the OWNER only as to the results to be obtained in the work herein specified, and to the extent that the work 8 shall be done in accordance with the terms, plans and specifications. The ENGINEER shall have and maintain complete control over all of its employees, subcontractors, agents and operations, being responsible for any required payroll deductions and providing required benefits, such as, but not limited to worker's compensation with statutory limits,and unemployment insurance. 9.8 INSURANCE The ENGINEER shall secure and furnish to the OWNER certificate of insurance, therein, naming the OWNER as an additional insured,to include thirty(30)days notice of cancellation or non-renewal. Without limiting any of ENGINEER's obligations hereunder, ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, insurance coverage naming the OWNER as additional insured with minimum insurance coverage as follows: 9 Type of Coverage Limits Employers'Liability: $ 100,000.per accident General Liability: Bodily Injury&Property Damage Single and combined $ 1,000,000.per accident General Aggregate: $2,000,000. Excess Liability Coverage(umbrella) $I,000,000.each occurrence Automobile: Bodily Injury covering all $ 1,000,000 each person automobiles,trucks, tractors,trailers,or $ 1,000000 each occurrence other automotive equip- ment whether owned or rented by Engineer or owned by employees of Engineer. Property Damage covering $ 100,000 each occurrence all automobiles,trucks, tractors,trailers or other automotive equipment whether owned or rented by Engineer or owned by employees of Engineer OR Bodily Injury&Property $1,000,000 each occurrence Damage Single and combined In addition to the above insurance coverage,the ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, and without naming OWNER as an additional insured, professional errors and omissions coverage as follows: Professional Errors&Omissions: $ 1,000,000 per claim and aggregate each occurrence 9.9 ENDORSEMENT The ENGINEER shall place his endorsement on all drawings and other data furnished by him. 10 9.10 OWNERSHIP OF DOCUMENTS The parties admit and agree the documents produced under this agreement are not intended or represented to be suitable for reuse by OWNER or any other individual on any other project. Any reuse without written verification or adaptation by ENGINEER will be at OWNER's sole risk and without liability or legal exposure to ENGINEER, or to ENGINEER's independent professional associates or consultants. Files in electronic media format of text, data, graphics, or of other types that are furnished by ENGINEER to OWNER are only for convenience of owner. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. 9.1 I PUBLIC INFORMATION The ENGINEER shall not issue any statements,releases or information for public dissemination without prior approval of the OWNER. 9.12 PROPRIETARY RIGHTS If patentable discoveries or inventions should result from work required herein,all rights accruing from such discoveries or inventions shall be joint property of the ENGINEER and the OWNER. Provided that the OWNER, state agencies or political subdivisions and the United States Government shall have the irrevocable, nonexclusive, nontransferable and royalty-free license to use each invention in the manufacture, use and disposition, according to law, of any article or material,and in the use of any method that may be developed as part of the work described and contemplated herein. 9.13 RECORDS The ENGINEER shall maintain accounting records and other evidence pertaining to the cost incurred and to make the records available at all reasonable times during the Contract term and for one (1) year from the date of final payment. Such accounting records and other evidence pertaining to the cost incurred will be made available for inspections by OWNER. 9.I4 SUCCESSORS IN INTEREST The covenants, agreements and all statements in this Contract apply to and shall be binding on the heirs, personal representatives,successors and assigns of the respective parties. 9.15 ATTORNEY'S FEES AND COSTS That in the event it becomes necessary for either Party of this Contract to retain an attorney to enforce any of the terms or conditions of this Contract or to give any notice required herein,then the prevailing Party or the Party giving notice shall be entitled to reasonable attorney's fees and costs, including fees, salary, and costs of in-house counsel to include City Attorney. 11 9.16 MODIFICATIONS AND AMENDMENTS That any amendment or modification of this Contract or any provisions herein shall be made in writing or executed in the same manner as this original document and shall after execution become a part of this Contract. In witness Whereof,the Parties hereto do make and execute this Agreement. CITY OF BOZEMAN,MONTANA ENGINEER N 4 BY: 3aaBY: .L/. (City Manager) (Presid- t) DATE: I — 1 f DATE: /-27%,2/4( ATT 'S• ` 4 e f Llf n 1erk) ` n 12 EXHIBIT A SCOPE OF SERVICES FOR PRE-DESIGN INVESTIGATION PHASE The work items for the Pre-Design Phase are described below: 1. Project Management and Meetings. This work item includes overall project management and meetings. Meetings shall include a project kick-off meeting, a meeting to discuss review comments for the Preliminary Pre-Design Report, and progress monthly progress meetings or teleconferences. 2. Consult with Owner and Review Existing Information. This work item includes obtaining and reviewing existing project documentation from the Owner or others including previous reports, plans and specifications for the new water treatment plant and existing survey data. 3. Review MDEQ Requirements and Meet with MDEQ if Required. The current CT requirements for the treated water from the new water treatment plant will be reviewed and the effect of the new storage tank on the CT requirements will be evaluated. The requirements in the current edition of Circular DEQ 1 for storage tanks will be followed. 4. Review Zoning Requirements for the East Parcel at the new water treatment plant site. The existing zoning requirements will be reviewed and their impact on the construction of a new storage tank will be evaluated. 5. Public involvement. This work item will include a presentation to the public on the findings in the pre-design report and meeting with nearby property owners to obtain their input and comments. 6. Preliminary Hydraulic Modeling. This work item will include an evaluation of the effect of the new storage tank on the hydraulic profile between the new water treatment plant and the distribution system. It will also include preliminary calculations to determine tank floor and overflow elevations. 7. Evaluate Storage Tank Alternatives. This work item will include an alternatives screening step. Alternatives that will be evaluated in this screening step include: a. The construction of one 5.3 million gallon tank vs the construction of two 2.6 million gallon tanks. b. Comparison of a poured-in-place concrete tank (no pre-stressing)vs a pre-stressed concrete tank. Alternatives that will be evaluated in detail will include at a minimum: a. 5.3 million gallon tilt-up pre-stressed tank b. 5.3 million gallon poured-in-place pre-stressed tank 8. Prepare Cost Estimates for Each Alternative Evaluated in Detail. A planning level cost estimate will be prepared for each alternative that is evaluated in detail. 9. Select the Preferred Alternative. Criteria for selecting the preferred alternative will at a minimum include capital cost,annual operation and maintenance cost,constructability, and public acceptance. 10. Prepare a Preliminary Pre-Design Report for City Review. A Preliminary Pre-Design Report will be prepared and submitted to City staff. Included in the report will be the alternatives screening process, detailed alternatives analysis, cost estimates for the alternatives evaluated in detail, preliminary site selection, preliminary site map and comments from the public (if any). 11. Prepare a Final Pre-Design Report. A Final Design Report will be prepared incorporating City staff comments. 12. Complete Field Design Survey, Survey Reductions and Calculations. A design survey of the selected tank site will be completed. Reductions of collected survey data and calculations needed to develop a site map and complete the design of the selected storage tank alternative will be completed. This work item does not include a property boundary survey of the water treatment plant site. 13. Prepare a Tank Site Base Map from the Survey Data. A base map of the tank site will be prepared for use in the final tank and tank piping design phase. EXHIBIT B FEE PROPOSAL ROBERT PECCIA&ASSOCIATES City of Bozeman 5.3 MG Concrete Water Storage Reservoir CIVIL ENGINEERING SERVICES CONTRACT Bozeman,Montana SCHEDULE OF ESTIMATED COSTS PRE-DESIGN INVESTIGATION PHASE City of Bozeman RPA Project No. 14702.000 Date: December 9,2014 Person Days President Project Project Project Strucl. Survey Surveyor Survey Crew Accountant CADD CADD Admin. Total Work item/Subtask Manager Engineer Engineer Engineer Manager Chief Manager Operator Person 581.03 $50.37 545.50 $32.20 048.41 $40.47 $34.23 $28.58 $31.35 $31.55 $25.62 $22.00 Days TASK 1:PRELIMINARY DESIGN PHASE Project Management and Meetings 4 00 1 00 5 50 Consult with Owner and Review Existing Information 0 50 0 50 Review MDEQ Requirements and Meet with MDEQ rf Required 0 60 1 00 1 60 Review Zoning Requirements for East Parcel 1 00 1 00 Public Involvement 1 00 0 50 1 50 Preliminary Hydraulic Modeling 2.50 2 50 Evaluate Storage Tank Alternatives Two vs One Tank Alternative 0 50 0.50 5 3 MG Tilt-up Pre-Stressed Tank 0 50 0 25 0 75 5 3 MG Poured-in-Place Pre-Stressed Tank 0 12 0 50 0.25 0 67 0 00 Prepare Cost Estimates for Each Alternative 1 20 0 50 0 50 2 20 Select Preferred Alternative 0 25 0 25 0 50 Prepare Preliminary Pre-Design Report for Cay Review 300 2.00 0 50 0 50 1 00 0 50 7 50 Prepare Final Pre-Design Report 1 00 0 50 1 00 0 50 3 00 Complete Field Design Survey 2 25 2 20 Survey Redugions and Calalahons 2 20 2.00 Prepare Tank Base Map from Survey Data 3 00 3 00 QA/OC 0 50 0 50 TOTAL PERSON-DAYS: 0.50 12.67 0.75 0.00 1.50 5.20 2.25 0.00 1.00 0.50 2.00 1.00 35.37 TOTAL PERSON-HOURS: 4.0 101.4 70.0 0.0 12.0 41,8 18.0 0.0 8.0 4.0 16.0 8.0 283.0 LABOR COST PER EMPLOYEE: $244.12 $5,105.50 03,255.00 $0.00 $558.92 51,883.55 $618.14 00.00 $250.80 $126.20 $409.92 $176.00 $12,424.15 DIRECT EXPENSES Assumptions I Exclusions: Equipment(Survey GPS$400/day) S1,200 00 -Assumes that a detailed hydraulic anaiyss will not be required.and only one tank will be constructed Equipment(Computers) $621 26 Equipment(Survey Robotic$200/day) SO 00 Per Diem-Day 050 00 Per Diem•Overnight 5200 00 Mileage $440 00 Telephone and Fax 030 00 Printing 5200.00 Misc.Supplies $20.00 Total: 92,76126 SUMMARY OF ENGINEERING SERVICES Loaded Labor Cost $37,61136 Direct Expenses 52.76126 (Total Engineering Fee: 540,573