Loading...
HomeMy WebLinkAbout04- Fire Station Addition and remodel agreement with Ingram & Prugh1997 Edition - Electronic Format AIA Document A101 -1997 Standard Form of Agreement .Between Owner and Contractor where th basi of payment is a STIPULATED SLIM AGREE ME NT made as of the ,,?q . day of M„44-ty�- in the year of Two THIS DOCUMENT HAS IMPORTANT LEGAL Thousand Four (2004). CONSEQUENCES. CONSULTATION WITH (In words, indicate day, .month and year) AN ATTORNEY 15 ENCOURAGED WITH RESPECT TO ITS COMPLETION OR BETW E E N the Owner: MODIFICATION. AUTHENTICATION OF (Name, address and otherinfonnation) THIS ELECTRONICALLY DRAFTED AIA City/ of Bozeman DOCUMENT MAY BE MADE BY U51NG AIA P.O. Box 1230 DOCUMENT D407. Bozeman, MT 59771 -1230 AIA Document A201-1997, General Conditions of the Contract for and the Contractor: Construction, is adopted in this document by reference. Do not use with other (Name, address and other information) general conditions unless this document is Ingram - Clevenger, Inc. modified. P.O. Box 5387 Helena, MT 59604 This document has been approved and 406.442.5102, Fax 406.442.5105 endorsed by The Associated General Contractors of America. The Project is: (Name and location) Bozeman Fire Station Addition & Remodel 34 North Rouse, Bozeman, Montana The Architect is: (Name, address and otherinformation) Pru h & Lenon Architects, P.G. 27 East Main Street, Suite D Bozeman, Montana 59715 405,587.1255, Fax 406.587.1819 The Owner and Contractor agree as follows. ARTICLE 1 THE CONTRACT DOCUMENTS The Contract Documents consist of this Agreement, Conditions of the Contract (General, � ,-w Supplementary and other Conditions), Drawings, Specifications, Addenda issued prior to 'g;'' " execution of this Agreement, other documents listed in this Agreement and Modifications EMEEM issued after execution of this Agreement; these form the Contract, and are as fully a part of the Contract as if attached to this Agreement or repeated herein. The Contract represents the 07997 AAA® AIA DOCUMENT A10 entire and integrated agreement between the parties hereto and supersedes prior negotiations, OWNER-CONTRACTOR -CONTRACTOR AGR AGREEMENT representations or agreements, either written or oral. An enumeration of the Contract Documents, other than Modifications, appears in Article 8. The American Institute of Architects 1735 New York Avenue, N.W. ARTICLE 2 THE WORK OF THIS CONTRACT Washington, D.C. 20006 -5292 @ 1915, igig, 1925, 1937, 1951, 1958, 961, 1963, 1967, 1974, 1977, 1987, (D 199 b Th e American Institute of Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the united States and will subject the violator to legal prosecution, WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below, User Document: bfslol.aia -- 3/3112004. AIA License Number 1212466, which expires on 12/31/2004. The Contractor shall fully execute the Work described in the Contract Documents, except t the extent specifically indicated in the Contract Documents to be the responsibility of others. ARTICLE 3 DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 3.1 The date of commencement of the Work shall be the date of this Agreement unless a different date is stated below or provision is made for the date to be fixed in a notice to proceed issued by the Owner. (Insert the date ofromniericement ifit differs from the date of this Agreement or, ifapplicqble, state that the date will be fixed ib a notice to proceed.) The Date of Commencement shall be fixed by a Notice to Proceed issued by by the Owner. If, prior to the commencement of the Work, the Owner requires time to file mortgages, mechanic's liens and other security interests, the Owner's time requirement shall he as follows: 3.2 The Contract Time shall be measured from the date of commencement. THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES, CONSUL TATION WITH ANA TTORNEY IS ENCOURAG wITH RESPECT TO ITS COMPLETION OR MODIFICATION. AUTHENTICATION Or THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE By U511VG AIA DOCUMENT D407, 3.3 The Contractor shall achieve Substantial Completion of the entire Work not later than AIA Document A201-1997, G enera l days from the date of commencement, or as follows: 158 calendar days following Notice Conditions of the Contract for to Proceed. Construction, is adopted in this document (Insert number 01'calendar days Alternatively, a calendar date may be used when coordinated with the date of by reference. Do not use with other commencement Unless stated elsewhere in the Contract Documents, insert any requ for earlier Substantial general conditions unless this document is Completion ofcolain1wr6ons ofthe Work,) modified. by August 6, 2004 This document has been approved and subject to adjustments of this Contract Time as provided in the Contract Documents, endorsed by The Associated General (Insert provisions, if any, for liquidated damages relating to failure to complete on time or for bonus payments far Contractors of America, eadr completion of th e Work,) The Contractor agrees that the Owner may deduct from the amount otherwise due the Contractor, Five Hundred Dollars ($500.00) per day for each calendar day the work has not been completed, and also agrees that to the extent that if it is not possible to make such deduction from the amount due the Contractor, the Contractor, will pay the Owner the amount written above for each day the work has not been completed past the date agreed to achieve Substantial Completion, This amount is agreed upon as liquidated damages and not as a penalty, because it would be extremely difficult to establish actual damages. ARTICLE 4 CONTRACT SUM 4.1 The Owner shall pay the Contractor the Contract Sulu in current funds for the Contractor's performance of the Contract. The Contract Sum shall be One Hundred t�_ Twenty-five Thousand, Two Hundred Seventy -One Dollars (s 125,271.00 ), subject to additions and deductions as provided in the Contract Documents. 4.2 The Contract Sum is based upon the following alternates, if any, which are described in the Contract Documents and are hereby accepted by the Owner (State the numbers or otheridentification ofacceptedaharrtares 1fdecisions on other alternates are to he made by the Owner subsequent to the execution of this Agreement, attach a schedule ofsuch otheraltarn8tes shoKMg the amount OD1997 AIM foreach and thedate when that amount expires) AIA DOCUMENT A101-1997 NIA OWNER-CONTRACTOR AGREEMENT 4.3 Unit prices, if any, are as follows: The American Institute of Architects NIA 1735 New York Avenue, N.W. Washington, D.C. 20006-5292 (D 1915, 1918, 1925, 1937, 1951, 1958, 1961, i963, 1967,1974,1977, 1987, (D 1997 by The American Institute of Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the dale of expiration as noted below. expiration as noted below. User Document: bfslol.aia -- 3/2412004. AIA License Number 1212466, which expires on 12/31/2004. ARTICLE 5 PAYMENTS 5.1 PROGRESS PAYMENTS 5.1.1 Based upon Applications for Payment submitted to the Architect by the Contractor and Certificates for Payment issued by the Architect, the Owner shall make progress payments on account of the Contract Sum to the Contractor as provided below and elsewhere in the Contract Documents.. 51.2 The period covered by each Application for payment shall be one calendar month ending on the last day of the month, or as follows: One day prior to the last Wednesday of each month. 5.1.3 provided that an Application for Payment is received by the Architect not later than the one day prior to the last Wednesday of each month day-44 mE q j th, the Owner shall make payment to the Contractor ne 4aler4han4he within two weeks 4ay -444+e month. If an Application for Payment is received by the Architect after the application date fixed above, payment shall be made by the Owner not later than three weeks days after the THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES, CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION, AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D401. Architect receives the Application for payment. AIA Document A201 -1997, General Conditions of the Contract for 5.1.4 Each Application for payment shall be based on the most recent schedule of values Construction, is adopted in this document submitted by the Contractor in accordance with the Contract Documents. The schedule of by reference. Do not use with other values shall allocate the entire Contract Sum among the various portions of the Work. The general conditions unless this document is schedule of values shall be prepared in such form and supported by such data to substantiate its modified. accuracy as the Architect may require. This schedule, unless objected to by the Architect„ shall This document has been approved and be used as a basis for reviewing the Contractor's Applications for payment. endorsed by The Associated General 5.1.5 Applications for payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for payment. 5.1.6 Subject to other provisions of the Contract Documents, the amount of each progress payment shall be computed as follows:. 1 Take that portion of the Contract Sum properly allocable to completed Work as determined by multiplying the percentage completion of each portion of the Work by the share of the Contract Sum allocated to that portion of the Work in the schedule of values, less retainage of five percent ( 5 %). pending final determination of cost to the Owner of changes in the Work, amounts not in dispute shall be included as provided in Subparagraph 7.3.8 of AIA Document Ami - i997 , .2 Add that portion of the Contract Sum properly allocable to materials and equipment delivered and suitably stored at the site for subsequent incorporation in the completed construction (or, if approved in advance by the Owner, suitably stored off the site at a location agreed upon in writing), less retainage of five percent ( 5 %)„ .3 Subtract the aggregate of previous payments made by the Owner; and .4 Subtract amounts, if any, for which the Architect has withheld or nullified Certificate for Payment as provided in Paragraph 9.5 of AIA Document A2or -1 - 997. Contractors of America. i ®1997 AIAO 5.1.7 The progress payment amount determined in accordance with Subparagraph 5.1.6 AIA, DOCUMENT Alol -1997 shall be further modified under the following circumstances, OWNER - CONTRACTOR AGREEMENT .1 Add, upon Substantial Completion of the Work, a sum sufficient to increase the total The American Institute of Architects payments to the full amount of the Contract Sum, less such amounts as the Architect 1.735 New York Avenue, N.W, Washington, D.C. 20006 -5292 (D 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1 9T7, 1987, tD 1997 y The American Institute of Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. User Document: bfslol.aia -- 312412004. AIA License Number 1212466, which expires on 1213112004. shall determine for incomplete Work, reLainage applicable to such work and unsettled claims; and (Subf-ragriph 9.8.5 ofAIA Document A201 -1_W,7 requires release of applicable Petatnage upon Substantial Completion of Work with consent of surety, if ang) .2 Add, if final completion of the Work is thereafter materially delayed through no fault of the Contractor, any additional amounts payable in accordance With Subparagraph 9.10.3 of AIA Document A 5.1.8 Reduction or limitation of retainage, if any, shall be as follows: (Ifil is intended prior to Substantial Completion Of the entire Work, to reduce orAmit the retarnw resulting from the percentages inserted M Clauses 5_1.6.1 and 5.1,6.2 above, and this is not explained elsewhere in the Contract Documents, inserthereprovisronsforsuch reduction orlimitatioll) 5.1.10 Each Application, for Payment shall indicate a sum of one percent, (11%), of the gross amount of each payment to be subtracted from the new payment and to be retained by the Owner to pay the State of Montana Gross Tax Receipt Tax as required by State Statute. THIS DOCUMENT HA5 IMPORTANT LEGAL CONSEQUENCES. CONSULTATION WITH AN ATTORNEY IS ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION. AUTHENTICATION OF TH15 ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA DOCUMENT MI. A1-1997 Ge 5.1.9 Except with the Owner's prior approval, the Contractor shall not make advance Conditions of AIA Document the 20 Contra , ct f neral or payments to suppliers for materials or equipment which have not been delivered and stored at Construction, is adopted in this document the site. by reference. Do not use with other general conditions unless this document is 5.2 FINAL PAYMENT modified, 5.2.1 Final payment, constituting the entire unpaid balance of the Contract Sum, shall be made by the Owner to the Contractor when: the Contractor has fully performed the Contract except for the Contractor's responsibility to correct Work as provided in Subparagraph 12.2.2 of AIA Document A2oi-1997, and to satisfy other requirements, if any, which extend beyond final payment-, and .2 a final Certificate for Payment has been issued by the Architect. 5.2.2 The Owner's final payment to the Contractor shall be made no later than 3o days after the issuance of the Architect's final Certificate for Payment, or as follows. ARTICLE 6 TERMINATION OR SUSPENSION 6.1 The Contract may be terminated by the Owner or the Contractor as provided in Article 14 of AIA Document A201-1997. 6.2 The Work may be suspended by the Owner as provided in Article 14 of AIA Document Awi-i997• ARTICLE 7 MISCELLANEOUS PROVISIONS 7.1 Where reference is made in this Agreement to a provision of AIA Document A2o1 -1997 or another Contract Document, the reference refers to that provision as amended or supplemented by other provisions of the Contract Documents. This document has been approved and endorsed by The Associated General Contractors of America. 7.2 Payments due and unpaid under the Contract shall bear interest from the date 01997 AIAO payment is due at the rate stated below, or in the absence thereof, at the legal rate prevailing AIA DOCUMENT AIOI-1997 from time to time at the place where the Project is located. OWNER-CONTRACTOR AGREEMENT (Insert rate ofinterestagpeed upon, ifany.) The American Institute of Architects 1735 New York Avenue, N,W, Usurylaws andrequirements undertheFederal Truthin LendipgAct, similarstate 2ndlocalconsumercredit laws and Washington, D.C. 20006-5292 otherregul3tions 81 the Owner's and Contnqctor'spiincipalpfaces ofbusiness, thelocadon ofthePro)ect and elsewhere 0 19T5, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1967, 1974, 1977, 1987, 0 1997 By The American _J­n­s­ff1tu­te_oT Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below, expiration as noted below. User Document: bfslol.aia -- 3/24/2004, AIA License Number 1212466, which expires on 12/3112004, may affect the validity of this pro vision. Legal advice should be obtained with respect to deletions ormodifications, and also regarding requirements such as ) , Tilten disclosures Or waivers. ) 7.3 The Owner's representative is: (Name, address and otberintomiation) James Goehrung, Superintendent of Lands and Facilities City of Bozeman P.O. Box 1230 Bozeman, MT 59771-1230 406.582.3200, Fax 406.582.3201 7,4 The Contractor's representative is: (Name, address and other information) Joe Petrini, Project Manager Ingram Clevenger, Inc. P.O. Box 5387 Helena, MT 59604 406.442.5102, Fax 406.442.5105 7.5 Neither the Owner's nor the Contractor's representative shall be changed without ten days written notice to the other party. 7.6 Other provisions: ARTICLE 8 ENUMERATION OF CONTRACT DOCUMENTS 8.1 The Contract Documents, except for Modifications issued after execution of this Agreement, are enumerated as follows-, 8.1.1 The Agreement is this executed 1997 edition of the Standard Form of Agreement Between Owner and Contractor, AIA Document Aioi-i997. 8.1.2 The General Conditions are the 1997 edition of the General Conditions of the Contract for Construction, AIA Document A2oi-2997• 8.1.3 The Revised Supplementary General Conditions, dated 03124104, and other Conditions of the Contract are those contained in the Project Manual dated January 2004 and are as follows: Document Building Permit Invitation for Bids Instructions to Bidders Bid Proposal Agreement, General Conditions Bonds, & Affidavit A312,13onds AIA G706 - Contractor's Affidavit Revised Supplementary General .Conditions, dated 3124104 AIA Al 01 -Agreement Title Pages Same Building :Permit Same Invitations for Bids-1 Same Instructions to Bidders 14 Same Proposal 1-2 Same I Performance Bond/ 1-6 Payment Bond Same 1-2 Same SGC-1 - SGC-3 Same 1 -6 - 0 1915, - 1918, 1925, 1937,1951 1958, 1961, 1963, 1967, 1974, 1977, 1987, 0 19 by The American - Institute of Architects, Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United Slates and will subject the violator to legal prosecution, WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below. expiration as noted below. User Document: bfslol.aia -- 3/2412004. AIA License Number 1212466, which expires on 12/31/2004. THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES. CONSULTATION WITH AN ATTORNEY Is ENCOURAGED WITH RESPECT TO ITS COMPLETION OR MODIFICATION, AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D407, AIA Document A207-7997, General Conditions of the Contract for Construction, is adopted in this document by reference. Do not use with other general conditions unless this document is modified. This document has been approved and endorsed by The Associated General Contractors of America. R 01997 AIAQD AIA DOCUMENT A101-1997 OWNER-CONTRACTOR AGREEMENT The American Institute of Architects 1735 New York Avenue, N.W. Washington, D.C. 20006-5292 Montana Prevailing Wage Rates Same 1-32 8.1.• The Specifications are those contained in the Project Manual dated as in Subparagraph 8,1.3, and are as follows: (Eitherlist the Speci6cadons hereorrefei- to an exhibit attached to this A Section Title Pages Sections in Divisions 1 -10 and Divisions 15 & 16 as listed in the Project Manual Index. See Exhibit A attached hereto. 8,1,5 The Drawings are as follows, and are dated unless a different date is shown below: (Either list the Drawingshare or Peter to an exhibit attached to thisAgreeinent) Number Title For Drawing Index refer to Exhibit B attached hereto. 8.1.6 The Addenda, if any, are as follows: Number Date Addendum No.1 6 February 2004 Date THIS DOCUMENT HAS IMPORTANT LEGAL CONSEQUENCES, CONSULTATION WITH AN ATTORNEY IS ENCOURAGED wtTH RESPECT TO ITS COMPLETION OR MODIFICATION. AUTHENTICATION OF THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USINGAIA DOCUMENT D401, AIA Document A201-1997, General Conditions of the Contract for Construction, is adopted in this document Pages by reference. Do not use with other general conditions unless this document is 1-5 modified. Portions of Addenda relating to bidding requirements are not part of the Contract Documents unless the bidding requirements are also enumerated in this Article 8. 8.1.7 Other documents, if any, forming part of the Contract Documents are as follows: (List here any additional documents that are intended to form part of the Contract Documents. AIA Document A.2oi- i_w7provides that bidding requirements such as advertisement or im4tation to bid, instructions to Bidders, sample forms and the Contractor's bid are not pan of the Contract Documents unless enumerated in this Agreement. They should be listed here only ifktended to bepart of the Contract Documents,) The following documents bound in or referred to in the Project Manual shall be incorporated into the Contract Documents: Invitation for Bids Instructions to Bidders Proposal Farris AIA - A312 - Performance & Payment Bond AIA - G706 - Affidavit for Payment of Debts and Claims This Agreement is entered into as of the day and year first written above and is executed in at least three original copies, of which one is to be delivered to the Contractor, one to the Architect for use in the administration of the Contract, and the remainder to the Owner. 0 W _N E R (Si 4 — Ron Brey, Acting q! Manager (Printed name and title) This document has been approved and endorsed by The Associated General Contractors of America, a IS CONTRACTOR (Signature) 01997 ATAO AIA DOCUMENT AIOI-1997 OWN ER- CON TRACTOR AGREEMENT 4. �_'�'­Lahe American Institute of Architects (Ptintednameand title) 1735 New York Avenue, N.W. Washington, D.C. 20006-5292 5 1915, 1918, 1§25, 1937, 1951, 1958, 1991, 1963, 1967, 1974, 1977, 1987, 0 1997 by The American — 15's — ti — tu — te -- oT Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates US copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below, expiration as noted below. User Document: bfsl01,aia -- 312412004. AIA License Number 1212466, which expires on 1213112004, EXHIBIT A SPECIFICATIONS Division 'I - GENERAL REQUIREMENTS 01100 SUMMARY 01250 - CONTRACT MODIFICATION PROCEDURES 01290 - PAYMENT PROCEDURES 01310 - PROJECT MANAGEMENT AND COORDINATION 01330 - SUBMITTAL PROCEDURES 01500 - TEMPORARY FACILITIES AND CONTROLS 01524 - CONSTRUCTION WASTE MANAGEMENT 01600 - PRODUCT REQUIREMENTS 01700 - EXECUTION REQUIREMENTS 01731 - CUTTING AND PATCHING 01732 - SELECTIVE DEMOLITION 01770 - CLOSEOUT PROCEDURES 01781 - PROJECT RECORD DOCUMENTS 01782 - OPERATION AND MAINTENANCE DATA 01820 - DEMONSTRATION AND TRAINING DIVISION 2 SITE WORK 02300 - EARTHWORK 02751 - CEMENT CONCRETE PAVEMENT 02920 - LANDSCAPING DIVISION 3 - CONCRETE 03300 - CAST -IN -PLACE CONCRETE DIVISION 4 - MASONRY 04810 - UNIT MASONRY ASSEMBLIES DIVISION 5 - METALS 05210 - STEEL JOISTS 05310 - STEEL DECK 05400 - COLD- FORMED METAL FRAMING 05500 - METAL FABRICATIONS DIVISION 6 - PLASTICS & WOOD 06105 - MISCELLANEOUS CARPENTRY 06200 - FINISH CARPENTRY DIVISION 7 - THERMAL & MOISTURE PROTECTION 07210 - BUILDING INSULATION 07531 - EPDM MEMBRANE ROOFING 07620 - SHEET METAL FLASHING AND TRIM 07920 - JOINT SEALANTS DIVISION 8 - DOORS & WINDOWS 08110 - STANDARD STEEL DOORS AND FRAMES 08711 - DOOR HARDWARE (SCHEDULED BY NAMING PRODUCTS) 08800 - GLAZING DIVISION 9 - FINISHES 09253 - GYPSUM SHEATHING 09260 - GYPSUM BOARD ASSEMBLIES 09511 - ACOUSTICAL PANEL CEILINGS 09652 - SHEET VINYL FLOOR COVERINGS 09653 - RESILIENT WALL BASE AND ACCESSORIES 09912 - PAINTING (PROFESSIONAL LINE PRODUCTS) DIVISION 10 -SPECIALTIES 10155 -TOILET COMPARTMENTS 10265 - WALL SURFACE PROTECTION SYSTEMS 10801 - TOILET AND BATH ACCESSORIES DIVISION 15 - MECHANICAL 15010 - GENERAL PROVISIONS 15020 - DEMOLITION 15060 - PIPE AND FITTINGS 15050 - PIPE AND DUCT SUPPORTS, SLEEVES AND SEALS 15101 -VALVES 15220 - OUTSIDE UTILITIES 15350 - NATURAL GAS PIPING SYSTEM 15401 - DOMESTIC WATER SYSTEM 15405 - SOIL, WASTE, ROOF AND AREA DRAINAGE SYSTEM 15450 - PLUMBING FIXTURES AND SPECIALTIES 15500 - FIRE SPRINKLER SYSTEM 15801 - AIR DISTRIBUTION SYSTEM 15820 - EXHAUST AND VENTILATION FANS 15910 - TEMPERATURE CONTROLS SEQUENCES DIVISION 16 - ELECTRICAL 1601 - GENERAL PROVISIONS 1611 RACEWAYS AND FITTINGS 1612 - CONDUCTORS 1613 - BOXES 1614 - WIRING DEVICES 1615 - MOTOR CONTROL DEVICES 1616 - GROUNDING SYSTEM 1617 - DISTRIBUTION BOARDS, PANELBOARDS AND SAFETY SWITCHES 1618 - FUSES 1651 - LIGHTING FIXTURES 1675 - TELEPHONE/DATA ROUGH -1N I ARCHITECTURAL T1 Title Sheet SD1 Site Plan Al Floor Plan & Roof Plan A2 Elevations A3 Building/Wall Sections A4 Door & Window Details A5 Interior Elevations STRUCTURAL so Structural Notes S1 Foundation Plan S2 Roof Framing Plan S3 Structural Details S4 Structural Details S5 Structural Details MECHANICAL Mi Mechanical Demolition Plan & Below Grade Piping Plan M2 Main Floor Piping Plan & Air Distribution Plan M3 Schedules & Details ELECTRICAL ES1 Electrical Site Plan El Lighting Floor Plan E2 Power Floor Plan E3 Legends & Schedules REVISED SUPPLEMENTARY GENERAL CONDITIONS 3124104 The Supplementary General Conditions contain changes and additions to the AIA General Conditions (AIA Document A201). Where any part of the AIA General Conditions is modified or voided by the Supplementary General Conditions, the unaltered provisions shall remain in effect. 3.4 LABOR & MATERIALS 3.4.4 Wage Requirements. On projects exceeding a total cost of $25,000, the Contractor shall pay the Montana Prevailing Wage Rates in accordance with State law, A copy of the minimum wage rates is bound herein; however, it shall be the Contractor's responsibility to secure and comply with the most recent publication of wage rates from the Dept. of Labor and Industry. Labor Standards Division, Helena, Montana, (406) 444 -2430 or (800) 541 - 3904. When required to pay the Prevailing Rates,. the Contractor shall furnish the Owner with the weekly payroll reports of all persons employed by the Contractor on this project within twelve (12) days of the end of each payroll week. 3.4.5 Products manufactured or produced in the State of Montana by Montana industry and labor shall be preferred for use in this project and in all materials, supplies and equipment procured if such products, materials, equipment and supplies are comparable in price and quality as prescribed in 18- 1 -112, MCA. 4.4 RESOLUTION OF CLAIMS AND DISPUTES 4.4.9 Attorney's Fees: In the event it is necessary for either of the parties hereto to bring any action to enforce the terms and covenants of this agreement, it is agreed that the prevailing party shall be entitled to reasonable attorney's fees including fees and salary paid to the City Attorney or other in -house counsel. 3.7 PERMITS FEES & NOTICES 3.7.1.1 The Contractor shall secure the indicated permits but will not be required to pay any fees to the City of Bozeman for permits. 8.2 PROGRESS AND COMPLETION 8.2.4 A date of commencement will be established in the Contract and as herein set forth. It is intended that a Notice to Proceed will be issued March 1, 2004, within 20 days of bid opening. Substantial Completion shall be achieved no later than August 6, 2004, (158) calendar days following the date of the Notice to proceed. Partial occupancy by Owner and interim completion dates are described in Section 01100 Summary. 8.2.5 The Contractor agrees that the Owner may deduct from the amount otherwise due to the Contractor, five hundred dollars ($500) per calendar day for each day the Work has not been completed, and also agrees that to the extent that it is not possible to make such deductions from the amount due the Contractor, the Contractor will pay the Owner the above amount for each calendar day the work has not been completed. It is understood that such deductions or payments will be taken as liquidated damages and not as a penalty. 9..6 PROGRESS PAYMENTS 9.6.8 Prior to Substantial Completion of each portion of the Work, the Owner will pay the Contractor 95 %n of the approved total on each Progress Payment Request for work completed and materials and equipment received and suitably stored during the period. 9.6.9 In accordance with state law governing Gross Receipts Withholding, the Owner will withhold 1 %0 of the amount due on each payment and transmit such amount withheld to the State Department of Revenue. SGC -1 9.0.1O Initial applications for progress payments shall be made one day prior to the last Wednesday of each mnnth will be reviewed at each monthly progress meeting and adjustments = made. Final applications for payment shall be submitted om later than 7 days following the ° a of initial application. Payment vv�msmtavviU be approved monthly. 10.1 SAFETY PRECAUTIONS & PROGRAMS 10.1.2 Add the following: All materials, products or equipment used for the construction of this Work shall be totally frees of asbestos, The Contractor shall uartU �in writing at completion uf the Work that materials, �teria|u pnoduot and equipment installed du not contain asbestos, It will be the Contractor's responsibility to ascertain from rnanufootunere, suppliers and subcontractors that all mehsha|o products, and equipment used are asbestos �o. ` 10.2 SAFETY OF PERSONS AND PROPERTY � 1O.2.4 Delete in its entirety and substitute the following: No explosives are to be a||cmved or stored on site without prior written notice and written acceptance bv Architect and Owner. 10.2.6 The Contractor shall maintain occupational health and safet at least to the extent required by the applicable Federal and K8omtanmState e�tutes.standards, rules and regulations. 11.0 INSURANCE AND BONDS - Proof of all required insurance will precede issuance of the Contract. 11.1 CONTRACTOR'S LIABILITY INSURANCE 11 1 1 9 Liability Insurance shall include all major divisions Vf coverage and be on aoomprehemskm basis including: .1 Premises Operators NnuyudingX-C/U as applicable) .2 Independent Contractor Protective .3 Products and Completed Operations .4 Personal Injury Liability with Employment Exclusion deleted .5 Cemtnao[ua[ - imdudimg specified provision for the Contractor's obligations under paragraph 3.18 .6 Owned, non-ow and hired motor vehicles .7 Broad Form Property Damage including Completed Operations .B Employer's liability (stop gap) .9 All Contractor's insurance policies shall name the Architect and the Owner as additional insureds. 11.1.2.1. The insurance required by Subparagraph 11.1.1 shall be written for not less than the follow or greater if required bvlaw .1 VVndkonan'o Compensation --Statutory .2 Comprehensive General Liability (including Premises-Operations; Independent Contractors Protective; Products and Completed Operations; Board Form Property Damage); .2.1 Bodily Injury andPnopertx[}anmage, $1.000,0DO per occurrence. .2.2 Bodily Injury andPrnpertyDamage: $1.O8O.00O general aggregate. 2.3 Products and Completed Operations: $1,000,000 general aggregate. .2.4 Products and Completed Operations Insurance to be maintained for 3 years after final payment, .2.5 Property Damage Liability Insurance shall provide X, C and U coverage. .3 Contractual Liability: .3.1 Bodily Injury: $1,000,000,00 each occurrence. .3.2 Bodily Injury and Property Damage: $1,000,000.00 annual aggregate. A Personal Injury, with Employment Exclusion deleted: $1,000,000.00 annual aggregate. .5 Comprehensive Automobile Liability: 5.1 Bodily Injury and Property Damage: $1,000,000.00 combined single limit. .5.2 Note: The Contractor shall be certain this insurance conforms to the specific stipulations of governing Montana statues. .6 Employers Liability. $1,000,000 annual aggregate, 11.4 PROPERTY INSURANCE 11.4.1.1 The form of policy for this coverage shall be Completed Value. 11.4.1.6 If by the terms of this insurance any mandatory deductibles are required, or if the Owner should elect to increase the mandatory deductible amounts or purchase this insurance with voluntary deductible amounts, the Owner shall be responsible for payment of the amount of the deductible in the event of a paid claim. EE SGC-3 THE AMERICAN INSTITUTE -OF ARCHITECTS rmi I on No. FS 167,5589 A/A Document A372 Any singular reference io Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): Ingram-Clevenger, Inc. P. O. Box 5387 Helena, NIT 59601 SURETY (Name and Principal Place of Business): Great American Insurance Company 580 Walnut Street Cincinnati, OH 45202 OWNER (Narne and Address) City of Bozeman 41 East Main Street Bozeman, NIT 59715 COUNTERSIGNED: FLYNN INSURANCE AGENCY 02-) CONSTRUCTION CONTRACT Date: md4. -? �' 'wa'l' Arnount: ONE III INDRED'I'MIENTY-FIVE *I'IIOLISAND'FWO 111INDRED SEVENTY-ONE AND NO/100 Dollars (;125.271.00) Description (Name and Location): Bozeman Fire Station Addition & Remodel, 34 North Rouse, Bozeman, Montana BOND Date (Not earlier than Construction Contract Date): galzk '?c"o Amount. ONE HIINDRED'FNVENTY-FIVE'ftlOtJSAND'I'WO HIJNDREDSFVENTY-ONE AND NO/100 Dollars ($125,271.00) Modifications to this Bond: V None F See Page 3 CONTRA,C"TOP AS PRINCIPAL Company: Ingram-Clevenger, Inc. (Corporate Seal) SURETY Company: Great American (Corporate Seal) Insurance Company Signature: Name and Title: 7 7' . r "� (Any additional signatures appear on page 3) Signature:( Name an Ti Beth A. Windom, Attorney-In-Fact (FOR INFORMATION ONLY—Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or Flynn Insurance Agency other party): P.O. Box 711 Great Falls, MT 59403 (406) 453-1464 AIA DOCL)MENT A312 • PERFORM\NCE BOND AND PAYMENT 8OND • DIUMBER 19&4 ED, • AIA •- 1H! Axit$:�( A', (Y ARO!; FECTS, 1735 NEW YORK AVE., N.W., WASHINGTON, D.C. 20006 A312-1984 1 1 The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference, 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except to participate in conferences as provided in Subparagraph 3.1. 3 If there is no Owner Default, the Surety's obligation under this Bond shall arise after; 3.1 The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 below that the Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Construc- tion Contract. If the Owner, the Contractor and the Surety agree, the. Contractor shall be allowed a reason- able time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default, and 3.2 The Owner has declared a Contractor Default and formally terminated the Contractor's right to complete the contract. Such Contractor Default shall not be de- clired earlier than twenty day; after the Contractor and the Surety have received notice as provided in Sub- paragraph 3,1; and 3.3 The Owner his agreed to pay the Balance of the Contract Price to the Surety in accordance with the terms of the Construction Contract or to a contractor selected to perform the Construction Contract in accor- dance with the terms of the contract with the Owner, 4 When the Owner has satisfied the conditions of Para- graph 3, the Surety shall promptly and at the Surety's ex- pense take one of the following actions: 4.1 Arrange for the Contractor, with consent of the Owner, to perform and complete the Construction Contract; or 4.2 Undertake to perform and complete the Construc- tion Contract itself, through its agents or through inde- pendent contractors; or 4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Con- struction Contract, arrange for a contract to be pre- pared for execution by the Owner and the contractor ,selected with the Owner's concurrence, to he secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 6 in ex- cess of the Balance of the Contract Price incurred by the Owner resulting from the Contractor's default; or 4.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is deter- mined, tender payment therefor to the Owner; or .2 Deny liability in whole or in part and notify the Owner citing reasons therefor. 5 If the Surety does not proceed as provided in Paragraph 4 with reasonable promptness, the Surety shall be deemed to be in default on this Bond fifteen days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Subparagraph 4.4, and the Owner refuses the payment tendered or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. 6 After the Owner has terminated the Contractor's rift to complete the Construction Contract, and if the Surety elects to act under Subparagraph 4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract, To the limit of the amount of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs and damages on the Construction Contract, the Sure- ty is obligated without duplication for; 6.1 The responsibilities of the Contractor for correc- tion of defective work and completion of the Construc- tion Contract; 6.2 Additional legal, design professional and delay costs resulting from the Contractor's Default, and re- sulting from the actions or failure to act of the Surety under Paragraph 4; and 6.3 Liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual dam- ages caused by delayed performance or non-perlor- mance of the Contractor. 7 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Con- struction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators or successors. 8 The Surety hereby waives notice of any change, in(Jud- ing changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obliga- tions. 9 Any proceeding, legal or equitable, Linder this Bond may be instituted in any court of competent jUriscliaon in the location in which the work or part of the work is located and shall be instituted within two years after Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever oc- curs first. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation avail- AIA DOCUMENT A3i2 PrRIORMANCE HOND AND PAYN SOND MCF 1 ED. • AJA r l -4t A', A', I ()I ';'F JT CTS, 1735 NEW YORK A\'!. N, tVASIL I INGION, D.C. 20006 A312-1984 2 able to sureties as a defense in the jurisdiction of the suit shall be applicable. 10 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the sig- nature page. 11 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions con- forming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12 DEFINITIONS 12.1 Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Con- MODIFICATIONS TO THIS BOND ARE AS FOLLOWS- tractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, re- duced by all valid and proper payments made to or on behalf of the Contractor under the Construction Con- tract. 12.2 Construction Contract: The agreement between the Owner and the Contractor identified on the sig- nature page, including all Contract Documents and changes thereto. 12.3 Contractor Default, Failure of the Contractor, which has neither been remedied nor waived, to per- form or otherwise to comply with the terms of the Construction Contract, 12.4 Owner Default; Failure of the Owner, which has neither been remedied nor waived, to pay the Con- tractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Sea[) Signature: Name and Title: Address: Signature: Name and Title: Address: AAA DO wNilENT A31: • PI BOND AND FAY.Mt,,, !!. JN) 1 tD. - A'IA T Trl� X,KICAN INS'T{t'4. 1735 NEW YO; :fi ! ',i., NAN., Oti +�.wtiltiC;'ti7:�., D.C.20006 A312 -1984 3 TWRD V RINTINC • MAR' 198v7 THE AMERICAN INSTITUTE CAF ARCHITECTS Bond No. FS 1625589 AIA Document A312 Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): Ingram-Clevenger, Inc. P. O. Box 5387 Helena, MT 59601 SURETY (Name and Principal Place of Business): Great American Insurance Company 580 Walnut Street Cincinnati, OH 45202 OWNER (Name and Address): City of Bozeman 411 East Main Street Bozeman, NIT 59715 COUNTERSIGNED: FLYNN INSURANCE AGENCY MAPK'.�,' Nwwni i q CONSTRUCTION CONTRACT Date: A )� Amount: ONE ITUNDREDTWENTY-FIVE'rtiouSAND TWO HUNDRED SEVENTY-ONE AND NO/100 Dollars (5125,271.00) Description (Name and Location): Bozeman Fire Station Addition & Remodel, 34 North Rouse, Bozeman, Montana BOND Date (Not earlier than Construction Contract Date): Am o u rit: ONE 11 UNDRE D TWENTY-FIVE THOU SAND TWO HUN DRED SEVENTY -ONE AND N0 /100 Dol ($125,271.00) Modifications to this Bond: [X None El See Page 6 CONTRACTOR AS PRINCIPAL Company: Ingram-Clevenger, Inc, (Corporate Sea]) 61 Name and Titl,-: e 7KIA, (Any additional signatures appear on page 6) SURETY Company: Great American Insuranc�Co rpo rate Seal) Company Signature: /4 xz_z() DZ - A't Beth A. Windom Name and Tit Attorney-In-Fact (FOR INFORMATION ONLY—Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or Flynn Insurance Agency other party): P.O. Box 711 Great Falls, NIT 59403 (406) 453-1464 AIA DOCUMENT A312 • PFRFORMANCE BOIND AND PAYMENT BOND - DECEMBER 1985 ED. • AIA RiF AMIRIC W AN i IT!JTL Of AKICHITE�7TS, 1735 NEW YORK AVE_ NAN_ JJN WA�HINGTO, D.C. 20006 A312-19&4 4 T � 11 HD PR1',T iN ; - 19,V I The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for Use in the perfor- mance of the Construction Contract, which is incorpo- rated herein by reference. 2 With respect to the Owner, this obligation shall be null and void if the Contractor: 2.1 Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2 Defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits by any person or entity whose claim, demand, lien or suit is for the payment for labor, materials or equipment fur- nished for use in the performance of the Construction Contract, provided the Owner has pro no tifi e d the Contractor and the Surety (at the address described in Paragraph 12) of any claims, demands, liens or suits and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety, and provided there is no Owner Default, 3 With respect to Claimants, this obligation shall be null and void if the Contractor promptly makes pay- ment, directly or indirectly, for all sums due. 4 The Surety shall have no obligation to Claimants under this Bond until 41 Claimants who are employed by or have a direct contract with the Contractor have given notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2 Claimants who do not have a direct contract with the Contractor, .1 Have furnished written notice to the Con- tractor and sent a copy, or notice thereof, to the Owner, within 90 days after having last performed labor or last furnished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed; and .2 Have either received a rejection in whole or in part from the Contractor, or not received within 30 days of furnishing the above no- tice any communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly; and .3 Not having been paid within the above 30 days, have sent a written notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice furnished to the Contractor. 5 If a notice required by Paragraph 4 is given by the Owner to the Contractor or to the Surety, that is suffi- cient compliance. 6 When the Claimant has satisfied the conditions of Paragraph 4, the Surety shall promptly and at the Surety's expense take the following actions: 6.1 Send an answer to the Claimant, with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed 6.2 Pay or arrange for payment of any undisputed amounts. 7 The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 8 Amounts owed by the Owner to the Contractor Under the Construction Contract shall be used for the perfor- mance of the Construction Contract and to satisfy claims, if any, under any Construction Performance Bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond, subject to the Owner's prior- ity to use the funds for the completion of the work. 9 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelat- ed to the Construction Contract- The Owner shall not be liable for payment of any costs or expenses of any Claim- ant under this Bond, and shall have Linder this Bond no obli- gations to make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. 11 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent juris- diction in the location in which the work or part of the work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Subparagraph 41 or Clause 4,23, or (2) on which the last labor or service was performed by anyone or the last mate- rials or equipment were furnished by anyone under the Con- struction Contract, whichever of (1) or (2) first occurs. If the provisions of this Paragraph are void or prohibited b law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable 12Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions con- forming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this AJA DOCUMENT A312 • PERYORMAN(E BOND AND PAYMENT BOND • DECEMBER 1984 FD AW ITU Al. R.::, 1, CTS 173 N! WYORK A\ A312-1984 5 Bond shall be construed as a statutory bond and not as a common law bond. 14 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15 DEFINITIONS 151 Claimant: An individual or entity having a direct contract with the Contractor orwith a subcontractor Of the Contractor to furnish labor, materials or equip- ment for use in the performance of the Contract. The intent of this Bond shall be to include without limita- tion in the terms "labor, matehals or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 15.2 Construction Contract: The agreement between the Owner and the Contractor identified on the sig- nature page, including all Contract Documents and changes thereto. 15.3 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Con- tractor as required by the Construction Contract or to per , form and complete or comply with the other terms thereof. (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: — Name and Title: Address: Signature: Name and Title: Address - AIA DOCUMENT A312 • PLPFORMANCE BOND AND PAYMENT BOND • DECEMBER 1964 ED. - AIA ;i THE &MERICAt INS'NIFUIE W AKCHITECTS, _1 Nl',% YORK AVE_ NW VASHl D.C. 200% A312-I9 6 7a,IRD PRINTING • NWa C�i I'Jb,- GREAT AMERICAN INSURANCE COMPANY& Administrative Office: 580 WALNUT STREET a CINCINNATI, OHIO 45202 a 513-369-5000 e FAX 513-723-2740 The number of persons authorized by this power of attorney is not more than THREE No.O 14092 POWER OF ATTORNEY KNOW ALL MEN BY THESE PRESENTS. That the GREAT AMERICAN INSURANCE COMPANY, a corporation organized and existing under and by virtue of the laws of the State of Ohio, does hereby nominate, constitute and appoint the person or persons named below its true and lawful attorney- in-fact, for it and in its name, place and stead to execute in behalf of the said Company, as surety, any and all bonds, undertakings and contracts of suretyship, or other written obligations in the nature thereof, provided that the liability of the said Company on any such bond, undertaking or contract of suretyship executed under this authority shall not exceed the limit stated below. Name Address Limit of Power JOHN D. LEAF ALL OF ALL BETH A. WINDOM GREAT FALLS, UNLIMITED JENNY TAUB—SMITH MONTANA This Power of Attorney revokes all previous powers issued in behalf of the attorneys) -in -fact famed above, IN WITNESS WHEREOF the GREAT AMERICAN INSURANCE COMPANY has caused these presents to be signed and attested by its appropriate officers and its corporate seal hereunto affixed this 14TH clay of May, 2002 Attest GREAT AMERICAN INSURANCE COMPANY STATE OF OHIO, COUNTY OF HAMILTON - ss: On this 14th day of May, 2002 before me personally appeared DOUGLAS R. BOWEN. to me known, being duly swom, deposes and says that he resides in Cincinnati, Ohio, that he is the Divisional Senior Vice President of the Bond Division of Great American Insurance Company, the Company described in and which executed the above instrument; that he knows the seal of the said Company; that the seal affixed to the said instrument is such corporate seal; that it was so affixed by authority of his office under the By-Laws of said Company, and that he signed his name thereto by like authority. This Power of Attorney is granted by authority of the following resolutions adopted by the Board of Directors of Great American Insurance Company by unanimous written consent dated March 1, 1991 RESOLVED: That the Division President. the several Division Vice Presidents and Assistant Vice Presidents, or any one of them, be and hereby is authorized, from time to time, to appoint one or more Attorneys -in -Fact to execute on behalf of fire Company, as surety, any arid all bonds, undertakings and contracts ofsureryship, or other written obligations in the nature thereof to prescribe their respective duties and the respective limits of their authority: and to revoke any such appointment at any time. RESOLVED FURTHER: That the Company seal and fire signature of any v of the aforesaid officers and any Secretary or Assistant Secretary of the Company may be affixed byjacsimile to any power of attorney certificate cecate of either given for the execution of any bond, undertaking, contract or suretyship, or other written obligation in the nature thereof, such signature and seal when so used being hereby adopted by the Company as the original signature of such of and the original &,-a[ of the Company, to be valid and binding upon the Company with the same force and effect as though manually affixed, CERTIFICATION 1, RONALD C. HAYES, Assistant Secretary of Great American Insurance Company, do hereby certify that the foregoing Power of Attorney and the Resolutions of the Board of Directors of March 1, 1993 have not been revoked and are now in full force and effect. Signed and sealed this 1?14t day of X417-1-1— S 1029T (11/01) 7[ERRORKSM COVERAGE RIDER NOTICE-DISCLOSURE OF?ERROfISM COVERAGE AND PREMIUM The Terrorism Risk Insurance Act u[2002 establishes uprogrann within the Department of the Treasury, under which the federal government shares, with the insurance industry, the risk o[loss from future terrorist attacks. The Act applies when the Secretary oftile Trnnxurycnrt its, that an event xocots the definition ofan Act ofTerrorism, The Act provides that, to be certified, an Act of Terrorism must cause losses of at least five million dollars and must have been committed by an individual or individuals acting on behalf oIany foreign person or foreign interest to coerce the government or population of the United States. Tubt attached to and form part n[ Bond No. FS 1625589 ,eQeobvc________ In accordance with the Terrorism Risk Insurance Act of2002,vveare pnovidhngdb/a disclosure notice for bonds on which Great American Insurance Company, its affiliates (including, but not lbndicd to Great /\nmoriomn Alliance louocmuoe Cnn`pmuy_ (}ruo1 American Insurance Cornpany of New York and Great American Assurance Insurance Conipany) is the surety. The Uoitcd States Government, Department ofthe Treasury, will pay a share o[terrorism losses insured under the terms of the Act. The federal share equals 9O 9 /6of that ooili000f ti amount of such insured losses that exceeds theappheable insurer retention. This Coverage Part/Policy covers certain losses caused by terrorism. In accordance with the Federal Terrorism Risk luourmocc Act of 2002, we are required to provide you with m onliuc disclosing the portion of your premium, ifany, attributable tn the coverage arising from losses for Terrorist Acts Certified tinder that Act. The portion of your annual premium that isattributable tu coverage for Terrorist Acts Certified under the Act is : S:00, R , CERTIFICATE OF LIABILITY INSURANCE D3 %26%2004 PRODUCER (406) 542 -5126 FAX (406) 542 -5647 Flynn Insurance Agency 2445 S. Third St. W. Suite B P.O. Box 3868 Missoula, MT 59801 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIL # INSURED Ingram - Clevenger, Inc. P 0 Box 5387 Helena, MT 59604 uNSURERA Montana State Fund PO Box 1230 INSURER B: GENERAL LIABILITY COMMERCIAL GENERAL LIABILITY CLAIMS MADE D OCCUR INSURER C: INSURER D: EACH OCCURRENCE INSURER E. DAMAGE TQ RENTE rr�tiFCOArcc THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDIN ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR 13D' TYRE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS PO Box 1230 OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES. GENERAL LIABILITY COMMERCIAL GENERAL LIABILITY CLAIMS MADE D OCCUR Bozeman, MT 59771 -1230 EACH OCCURRENCE S DAMAGE TQ RENTE MED EXP (Any one person) S PERSONAL & ADV INJURY S GENERAL AGGREGATE S GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO- LOC JECT PRODUCTS - COMP /OP AGG S AUTOMOBILE LIABILITY ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS HIRED AUTOS NON•OM1NNED AUTOS COMBINED SINGLE LIMIT (Ea acotc ent) 5 BODILY INJURY (Per person) S BODILY INJURY (Per accoderil) S PROPERTY DAMAGE (Per accident) S GARAGE LIABILITY ANY AUTO AUTO ONLY - EA ACCIDENT S OTHER THAN EA ACC AUTO ONLY: AGG S $ EXCESSPUMBRELLA LIABILITY OCCUR FI CLAIMS MADE DEDUCTIBLE RETENTION S EACH OCCURRENCE $ AGGREGATE $ S S 5 A WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETORIPARTNEPJEXECUTIVE OFFICERIMEMBER EXCLUDED? If yes, describe under SPECIAL PROVISIONS below 03- 161580 -0 01/01/2004 01/01/2005 X I WCSTATJU 111TH- E.L. EACH ACCIDENT S 1 1 000 , 000 E.L. DISEASE - EA EMPLOYEE S 1 ,000,000 E.L. DISEASE . POLICY LIMIT S 1,000,000 OTHER DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS Project: Bozeman Fire Station Addition & Remodel, 34 North Rouse, Bozeman, Montana r•cc��.- icrr+ATC urir III rAN1r1ZT I ATI' ACORD 25 (2001108) ®ACORD CORPORATION 1988 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 10 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT„ Ci of Bozeman BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY PO Box 1230 OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES. AUTHORIZED REPRESENTATIVE. Mark Nicholls, C I C/'RS Bozeman, MT 59771 -1230 ACORD 25 (2001108) ®ACORD CORPORATION 1988 If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. AGORD 25 (2001108) 0, CERTIFICATE OF LIABILITY INSURANCE a3jzs/2004 PRODUCER (40...6)542 -5126 FAX (406)542 -5647 Flynn Insurance Agency 2445 S. Third St. W. Suite B P.O. Box 3868 Missoula, MT 59801 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE NAIL # INSURED Ingram Clevenger, Inc. P 0 Box 5387 Helena, MT 59604 INSURERA: Continental West Ins. Co. POLICY EFFECTIVE INSURER B: LIMITS INSURER C. INSURER D: CWP 2397336 - 30 ... 01/01 . /2004 INSURER E. 01/01/2005 rn% /=PAr".'GC THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDIN ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR DD' TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIMITS AUTHORIZED REPRESENTATIVE Mark. Nicholls, C I C /RS Ad S GENERAL LIABILITY CWP 2397336 - 30 ... 01/01 . /2004 01/01/2005 EACH OCCURRENCE $ 1 �( COMMERCIAL GENERAL LIABILITY DAMAGE TO RENTED PREMISES (En $ 100, 000 CLAIMS MADE � OCCUR MEO EXP (Any one person) $ 5,000 A X Bl anket A dd it i onal PERSONAL & ADV INJURY S 1,000,000 Insured CG 2 033 GENERAL AGGREGATE S 2 1 000,000 GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS • COMP/0P AGG S 2, 000 , 000 X, POLICY . LOG AUTOMOBILE INABILITY ANY AUTO CWP 2397336 - 30 01/01/2004 01/01/'x2005 COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 A ALL OWNED AUTOS SCHEDULED AUTOS HIREDAUTOS NON•OWNEDAUTOS BODILY INJURY (Per person) $ X X BODILY INJURY (Peramdent) $ X PROPERTYDAMAGE (Per accrdenl) 5 GARAGE LIABILITY AUTO ONLY • EA ACCIDENT S OTHER THAN FA ACC $ -- ANY AUTO S AUTO ONLY AGG EXCESSIUMBRELLA. LIABILITY #804032606240 03/26/2004 01/01 EACH OCCURRENCE S 1, a00, 000 OCCUR CLAIMS MADE AGGREGATE $ 1,000,000 A *SEE BELOW REGARDING s DEDUCTIBLE LIMITS & DATES' s X RETENTION S 10,00 S WORKERS COMPENSATION AND WCY LIMIT 0TH - EMPLOYERS' LIABILITY ANY PROP RIFTOR/PARTNER/EXECUTIVE EL EACH EACH ACCIpFNT S E.L. DISEASE - EA EMPLOYE S OFFICER/MEMBER EXCLUDED? if yes, describe under SPECIAL PROVISIONS below E.L. DISEASE - POLICY LIMIT 1 $ A OTHER ;:Excess /Umbrella Liability CU2.412075 -21 01/01/2004 01/12/2004 01/12/2004 03/26/2004 $4,000,000 Each Occurrence $4,000,000 Aggregate NO COVERAGE DESCRIPTION OF OPERATIONS i LOCATIONS 1 VEHICLES I EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS Project: Bozeman Fire Station Addition & Remodel, 34 North Rouse Bozeman, Montana City of Bozeman is named an Additional Insured per attached form CG 20 33 03 97 CERTIFICATF HOLDER CANCELLATION ACORD 25 (2001108) (DACORD CORPORATION 1988 SHOULD ANY OFTHE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILLENDEAVOR TO MAIL. 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, City of Bozeman BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY PO Box 1230 OF ANY KIND UPON THE INSURER, ITS AGENTS OR REPRESENTATIVES, Bozeman, MT 59771- .1230 AUTHORIZED REPRESENTATIVE Mark. Nicholls, C I C /RS Ad S ACORD 25 (2001108) (DACORD CORPORATION 1988 CLIP 2397335 - 20 01/01/03 SLG 12/10/02 CG 20 33 07 98 TRIS ENDORSEMUT CE&UGES THE POLICY. PLEASE MAD IT CAR SFULLY , ADDITIONAL INSURED - OWNERS, LESSEES OR CONTRACTORS - AUTOMATIC STATUS WHEN REQUIRED IN CONSTRUCTION AGREEMENT WITH YOU This endorsement modifies insurance provided under the following CTMMERCIAL GENSRAL LZAMLITY COVEPOGE PART A. Section IT - Who is An Insured is amended to include as an insured any person or ?r9anization for whom yca are performing operations when you and such person or organization have agreed in writing in a contract or agreement that such person or organi- zation be added as an additional insured on your policy. Such person or organization is an additional in- sured only with respect to liability arising out of your ongoing opera- tions performed for that insured. A person's or organizatioals status as an insured under this endorsement ends when your operations for that insured are kmmleted. B. With respect to the insurance af- forded these additional insureds, the following additional exclusion ap- plies. This insurance does not appl t "Bcd±ly - 4 njurv", "Properly damage o 11 pysonal aid adv ertising in3u=7" arising out of the rendering of, o the failure to render, any p7ofes- sional architectural, englueer;ng or surveying services, incluai 1. The preparing, approving, or fail- ing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change or- ders or drawings and specifica- lions; and 2. Supervisory, inspection, architec- tnial or engineering activities. Copyright, Insurance Services office, Inc., 1997 CG 20 33 07 98 IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). if SUBROGATION |8 WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. /\ statement on1hisoortificmtednommtoonforhghts to the certificate holder in lieu cf such endummment(s). DISCLAIMER The Certificate of Insurance om the reverse side of this form does not constitute u contract hekmaoo the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. ACORD 25 (2001108) ,4Ct)� D , INSURANCE BINDER COVERAGEIFORMS DEDUCTIBLE 03/26/2004 THIS BINDER IS A TEMPORARY INSURANCE CONTRACT, SUBJECT TO THE CONDITIONS SHOWN ON THE REVERSE SIDE OF THIS FORM, PRODUCER C Ezt: (406)542-5126 COMPANY BINDER# FAX (4 )542-5647 Continental Western Ins Co B04032606240 Flynn Insurance Agency DATE EFFECTIVE TIME DATE XPIRATIO I TIME 03/26f2004 r12 :01 X AM 05/26/2004 X 1201 AM 2445 S. Third St. W. Suite B PERSONAL & ADV INJURY S P.O. Box 3868 GENERAL AGGREGATE S PM NOON Missoul MT 59801 AUTOMOBILE THIS BINDER IS ISSUED TO EXTEND COVERAGE IN THE ABOVE NAMED COMPANY PER EXPIRING POLICY #: CODE: SUB CODE: AGENCY 00002203 CUSTOMER ,,0 0002203 DESCRIPTION OF OPERATIONSIVEHICLEWPROPERTY (including Location) Building Contractor: Ingram- Clevenger, Inc. S 7000 Green Meadow Drive, Helena, Montana P 0 Box 5387 Helena, MT 59604 $ COVERAGES LIMITS TYPE OF INSURANCE COVERAGEIFORMS DEDUCTIBLE COINS I AMOUNT PROPERTY CAUSES OF LOSS BASIC BROAD 1:1 SPEC LOAN # AUTHORIZED REPRESENTATIVE � p Mark Nicholls, C I C /RS /U! X/4 i]:::::: GENERAL LIABILITY COMMERCIAL GENERAL LIABILITY CLAWS MADE � OCCUR RFTRO DATE FOR CLAIMS MADE. EACH OCCURRENCE S FIRE DAMAGE (Anyone Eire) $ AHED EXP (Any one person) S PERSONAL & ADV INJURY S GENERAL AGGREGATE S PRODUCTS - COMP/CP AGO S AUTOMOBILE LIABILITY ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS HIREDAUTOS NON -OWNED AUTOS COMBINED SINGLE LIMIT S BODILY INJURY (Per person) S BODILY INJURY (Per accriden4) S PROPERTY DAMAGE $ MEDICAL PAYMENTS $ PERSONAL INJURY PROT $ UNINSURED MOTORIST $ S AUTO PHYSICAL DAMAGE DEDUCTIBLE COLLISION: OTHER THAN COL ALL VEHICLES SCHEDULED VEHICLES ACTUAL CASH VALUE $ '.. STATED AMOUNT 1. OTHER. GARAGE LIABILITY ANY AUTO AUTO ONLY - EA ACCIDENT $ OTHER THAN AUTO ONLY: EACH ACCIDENT S AGGREGATE IS EXCESS LIABILITY X UMBRELLA FORM OTHER THAN UMBRELLA FORM RETRO DATE FOR CLAIMS MADE: EACH OCCURRENCE S 1, 000,000 AGGREGATE $ 1,000,000 SELF- INSURED RETENTION S 10 ,000 WORKER'S COMPENSATION AND EMPLOYER'S LIABILITY WC STATUTORY LIMITS E.L. EACH ACCIDENT S E.L. DISEASE - EA EMPLOYEE $ E.L. DISEASE- POLICY LIMIT S SPECIAL CONDITIONS! OTHER COVERAGES FEES S TAXES $ ESTIMATED TOTAL PREMIUM S NAME & ADDRESS AL;URU 15-5 (1/9tI) NU I t: IMI'UK I AN I S I A I Iw INFURMATIUN UN REVERSE SIDE OACORD CORPORATION, 1993 MORTGAGEE LOSS PAYEE ADDITIONAL INSURED LOAN # AUTHORIZED REPRESENTATIVE � p Mark Nicholls, C I C /RS /U! X/4 AL;URU 15-5 (1/9tI) NU I t: IMI'UK I AN I S I A I Iw INFURMATIUN UN REVERSE SIDE OACORD CORPORATION, 1993 This Company binds the kind(s) of insurance stipulated on the reverse side. The Insurance is subject to the terms, conditions and limitations of the policy(ies) in current use by the Company. This binder may be cancelled by the Insured by surrender of this binder or by written notice to the Company stating when cancellation will b* effective. This binder may bm cancelled by the Company bynotice to the Insured in accordance with the policy conditions. This binder is cancelled when replaced by a policy. If this binder is not replaced by a policy, the Company is entitled to charge a premium for the binder according to the Rules and Rates in use by the Company. Applicable in California When this form is used to provide insurance in the amount of one million dollars ($1,000,000) or more, the title of the form is changed from "Insurance Binder" to "Cover Note". Applicable in Delaware The mortgagee or Obligee of any mortgage or other instrument given for the purpose of creating a lien on real property shall accept as evidence of insurance a written binder issued by an authorized insurer or its agent if the binder includes oriv accompanied by the name and address o[ the borrower: the name and address ufthe lender as loss payee; a description of the insured real property; a provision that the binder may not be canceled within the term of the binder unless the lender and the insured borrower receive written notice of the cancel- lation ut/eaoi{on(1O)dmyophnrtotheoonceUxd|on; except in the case ofo renewal pfe policy subsequent $n the closing of the loan, a paid receipt of the full amount of the applicable premium, and the amount of insurance coverage. Chapter 21 Title 25 Paragraph 211O /\omik:ob|einFlorida Except for Auto Insurance coverage, no notice of cancellation ormmrennwa|ofa binder is required unless the duration of the binder exceeds 60 days, For auto insurance, the insurer must give 5 days prior notice, unless the binder im replaced bya policy nr another binder im the same company. Applicable in Nevada Any person who refuses to accept a binder which provides coverage of less than $1,000,000,00 when proof is required. (A) Shall be fined not more than $5UUI0. and (B) isliable to the party presenting the binder aoproof of insurance for actual damages sustained therefrom. Bozeman Fire Station Addition &Remodel Bozeman, Montana To: Ingram-Clevenger, Inc. P.[L Box 5387 Helena, MT 58804 Project Bozeman Fire Station Addition& Romode[ 34N Rouse Avenue Bozennan, MT 59715 Contract: General Construction Dated: March 7.2OO4 You are hereby notified that your bid dated February 10 2004 for the above Contract has been considered by the City of Bozemon, hereinafter called the Owner. You are the apparent Successful Bidder and have been awarded the Contract for Bozeman Fire Station Addition & Remodel. The Contract Price of your contract is Base Bid: One Hundred Twenty-five Thousand, Two Hundred Seventy-one Dollars and no/1100's_W25,271.0011. Total Contract Award: _ i sets of Contract Drawings and Specifications will be made available to you immediately. You must comply with the following conditions precedent within fifteen days of the date that you receive the contract, You must deliver to the Owner 3 fully executed counterparts of the Contract included in the Contract Documents. Each of the Contracts must bear your signature on page 6 , 2, You must deliver with the executed Contract, the Contract Bond as specified in the Contract Documents. 3 You must deliver with the executed Contract, Certificates of Insurance for coverages as specified in the Contract Documents. NoticeofAward -1- Within ten days after you comply with the above conditions, the Owner will return to you one fully signed counterpart of the Contract. The date of Substantial Completion will change as follows. Upon receipt of the Notice to Proceed the contract time of (158) calendar days will commence. City of Bozeman Owner By: Ron Brey, Actirig, ACCEPTANCE OF AWARD Ingram-Clevenaer. Inc. Bye Title Aj Copy to Architect by Regular Mail. Notice of Award -2-