The URL can be used to link to this page

Home My WebLink AboutJ.J. Henderson & Son Wastewater Reclamation Facility Project - Bidder InformationF ,f !- _ ~l a ~~ ~~ JOSEPH J. HENDERSON & SON INC. GENERAL CONTRACTOR ESTABLISHED 1928 October 9, 2008 City of Bozeman 121 North Rouse Avenue Bozeman, MT 59715 Attn: Office of City Clerk Re: Wastewater Reclamation Facility Phase 1 Improvements Bidder Qualifications Bozeman, MT To Whom It May Concern: 4288 Old Grand Avenue P.O. Box 9 Gurnee, Illinois 60031-0009 Phone: 847-244-3222 Fax: 847-244-9572 Joseph J. Henderson & Son, Inc. would like to thank you for the opportunity to submit our qualifications for the Bozeman Wastewater Reclamation Facility project. Enclosed is Section 00480 "Information Required of Bidders" along with attachments. We urge you to contact our references that have been provided for verification of our qualifications and past history. Should you have any questions or need additional information, feel free to call me. Sincerely, ~~~~~ David A. Henderson President /lz SECTION 00480 INFORMATION REQUIRED OF BIDDERS The undersigned certifies that Joseph J. Henderson & Son, Inc. (Bidder} is regularly engaged in the general class and type of work called for in the City of Bozeman WRF Phase 1 Improvements Project at the Wastewater Reclamation Facility and that Bidder has the appropriate knowledge, skills, experience, resources, and licenses to successfully complete the work. The undersigned further acknowledges that Bidder is awaze that there are certain pecniiar anti inhPrPnt renditions existent in the construction or installation of the work, which may create unusual or peculiar unsafe conditions hazardous to persons and property and that Bidder has the skills and experience to foresee and to adopt protective measures to adequately and safely perform the work with respect to such hazards associated with work at a municipal wastewater treatment plant. The Bidder shall provide complete and accurate information to the following requests as specified in the Instructions to Bidders. Failure to do so may render the Bid unresponsive and may result in rejection of the Bid. Use additional sheets if necessary. A. BIDDER (CONTRACTOR) INFORMATION 1. rirm Name: Joseph J. Henderson & Son, Inc. Check One: ~ Corporation (as it appears on license} ^ Partnership ^ Sole Prop. 2. Contact Person: David A. Henderson 3. Address: 4288 Old Grand Avenue, Gurnee, Illinois 60031 4. Phone: (847) 244-3222 Fax: (847) 244-9572 If firm is a sole proprietor or partnership: Not applicable 5. Owner(s) of Company Contractor's License Number(s) (License No. /Class /Type /Categories): 6. Name of Contractor(s) representative who inspected the City of Bozeman WRF site as part of the mandatory pre-bid conference. Mike Shelley, Ken Kreason, Josh Little, David Henderson Date of Inspection: September 3, 2008 7. Name, address, and telephone number or surety company and agent who wilt provide required bonds for this Contract: Travelers Casualty & Surety Company Agent: Hilb Rogal & Hobbs 215 Shuman Blvd., Naperville, IL 60563 333 E. Butterfield (630) 961-7037 Lombard, IL 60148 (630)324-2500 OD...60746 Dozeman WRF Phase 1 Improvements Project 7~gnDOg 00480 - 1 8. Name of the proposed project superintendent: Ken Kreason 9, The Bidder shall list below the name, business address, and contractor(s)'s1icense number, if any, of each subcontractor who will be working on this project with a minimum value of the subcontract of $50,000 or greater, in addition to the nature and value of work assigned to each subcontractor, No changes or substitutions will be allowed without written approval of the Qwner. Name: Williams Plumbing and Heating #8395 2360 North 7th Avenue Bozeman MT 59715 Name: Grizzly Fence #53648 1720 South 3rd Street West Missoula MT 59801 Name: Gallatin Asphalt #10604 6465 River Road Bozeman, MT 59718 Name: Structural Steel Erectors #2366 734 South First West Missoula, MT 59806 Name: Anderson Masonr 7393 Hiahway 35 Bie Fork, MT 59911 Name: Quality Roofing & Sheet Metal #7353 490 Cobb Hill Road Bozcman MT 59718 Name: Tri Jack #11513 P.O. Box 20364 Billings, MT 59718 Value: $7,833,472.00 Value: $80,265.00 Value: $172,523.00 Value: $652,000.00 Value: $760,051.00 Value: $504,291.00 Value: $120,842.00 Name: _ All City Glass #156201 Value: 128 Timberline Drive #1 Bozeman, MT 59718 Namc: Niles Industrial Registration Number to be Obtaine~alue: 201 S. Alloy Drive Fenton, MI 48430 Name: Morton Buildings #21399 P.O. Box 1067 Belgrade, MT 59714 Name: Mountain States Electrical #1532 1220 E. 1st Avenue Spokane, WA 99202 00...60746 Value: Value: $799,000.00 $1,313,245.00 $7,672,000.00 Bozeman WRP Phase 1 Improvements Project 004130 - 2 , $116,780.00 7/28/2008 B. ESSENTIAL REQUIREMENTS FOR DETERMINATION OF RESPONSIBILITY Contractor shall provide satisfactory responses to the following questions to be considered for the City's use in determining the lowest responsible bid: 1. Contractor has appropriate technical experience with at least three comparable projects within the past 10 years. involving rehabilitation or modifications of water and/or wastewater mechanical treatment plants with capacities of 5 mgd or greater and a minimum construction cost of $10 million or greater. See Article D of this Section. Yes ^ No 2. Contractor possesses a valid and current public works Contractor's license for the project or projects for which it intends to submit a bid. ~ Yes ^ No 3. Contractor has a liability insurance policy with a policy iimit of at least $5,000,000 per occurrence and $5,000,000 aggregate. ~ Yes ^ No 4. Contractor has current workers' compensation insurance policy as required by the Chapter 39-71 MCA. ®{ Yes ^ No ^ Contractor is exempt from this requirement, because it has no employees 5. Contractor has attached their latest copy of a reviewed or audited financial statement with accompanying notes and supplemental. information. Yes ^ No G. Contractor has attached a notarized statement from an admitted surety insurer authorized to issue bonds in the State oFMontana, which states: {a) that Contractor's current bonding capacity is sufficient for the project; {b) Contractor's current available bonding capacity? ,~ Yes ^ No NOTE: Notarized statement must be from the surety company, not an agent or broker. 7. Has your contractor's license been revoked at any time in the last five years? ^ Yes ~ No 8. Has a surety firm completed a contract on your behalf, or paid for completion because your firm was default terminated 5y the project owner within the last five (S) years? ^ Yes ~ No 9. At the time of submitting this pre-qualification form, is your firm ineligible to bid on or be awarded a public works contract, or perform as a subcontractor on a public works contract? ^ Yes ~ No if the answer is "Yes," state the beginning and ending dates of the period of debarment: 10. At any time during the last five years, has your firm, or any of its owners or officers been convicted of a crime involving the awarding of a contract of a government construction project, or the bidding or performance of a government contract? ^ Yes ~ No C. HISTORX OF THE BUSINESS AND ORGANIZATIONAL PERFORMANCE - LNFORMATIONAL QUESTIONS Has there been any change in ownership of the firm at any time during the last five years? 00...60746 Bozeman WRF Phase l Improvements Project 7/2gl2t}Og 00480 3 NOTE: A corporation whose shares are publicly traded is not required to answer this question. ^ Yes ~ No If "yes," explain on a separate signed page. 2. Is the firm a subsidiary, parent, holding company or affiliate of another construction firm? NOTE: Include information about other firms if one firm owns 50 per cent or more of another, or if an owner, partner, or officer of your firm holds a similar position in another firm. ^ Yes ~C No If "yes," explain on a separate signed page. 3. Are any corporate officers, partners or owners connected to any other construction firms. NOTE: Include information about other firms i# an owner, partner, or officer of your firm holds a similar position in another firm. ^ Ycs ~ No If"yes," explain on a separate signed page. 4. State your firm's gross revenues for each of the last three years: (2007) $63,567,457 (2006) $79,443,662 (2005) $73,940,980 5. List all construction license numbers, including Montana license numbers, classifications, type, category, and expiration dates of the Montana contractor licenses held by your firm: Secretary of Slate Certificate #F-46977-309044 (MT); State of Montana Contractor Registration #158491 (09/14/10)• IL-Dept of Rev Registration #1067-8247 (03/3]./12); IL-Chicago GC License #063735-3 (05/19/09; IlrChicago Ltd Business License #59235 (04/15/09); IL-Will Co GC License #200001335 (12/31/08); IL-Huntley Registration #08-0491 (12/3]/08); IL-Gurnee Business License #GBL-2008-152 (12/31/08)• IL-Cook Co Registration #31638 (11/30/08) 6. If any of your firm's license(s) arc held in the name of a corporation or partnership, list below the names of the qualifying individual(s) listed on the state licensing board records who meet(s) the experience and examination requirements for each license. David Henderson 7. IIas the Applicant changed names or license number in the past five years? ^ Yes ~ No If "yes," explain on a separate signed page, including the reason for the change. 8. Has any owner, partner or (for corporations) officer of your firm operated a construction firm under any other name in the last five years? ^ Yes ~ No If "yes," explain on a separate signed page, including the reason for the change. 9. Is our firm currently the debtor in a bankruptcy case? Yes ~ No If "yes," please attnoh a copy of the bnnlcruptoy petition, showing rho once number, and the date on tivhich the petition was filed. 10. Was your firm in bankruptcy at any time during the last five years? (This question refers only to a 00...60746 Bozeman WRF Phase i Improvements Project 7/28/2008 00480 - 4 bankruptc action that was not described in answer to question 10, above) ^ Yes ~ No if "yes," please attach a copy of the bankruptcy petition, showing the case number and the date on which the petition was filed, and a copy of the Bankruptcy Court's discharge order, or of any other document that ended the case, if no discharge order was issued. 11. Has any state license held by your firm or its Responsible Managing Employee (RME) or Responsible Managin Officer (RMO} been suspended within the last five years? ^ Ycs c~ Nv If "yes," please explain on a separate signed sheet. 12. At any time in the Last 10 years has your firm been assessed and paid liquidated damages after completion of a project under a construction contract with a public owner? ^ Yes ~ No if yes, explain on a separate signed page, identifying all such projects by owner, owner's address, the date of completion of the project, amount of liquidated damages assessed and all other information necessary to fully explain the assessment of liquidated damages. 13. In the last 10 years has your firm, or any firm with which any of your company's owners, officers or partners was associated, been debarred, disqualified, removed or otherwise prevented from bidding on, or completing, any government agency or public works projecl for any reason? NOTE: "Associated with" refers to another construction firm in which an owner, partner or officer of your firm held a similar position, and which is listed in response to question lc or ld on this form. ^ Yes ~ No if "yes," explain on a separate signed page. State whether the firm involved was the firm applying for pre- qualification here or another firm. Identify by name of the company, the name of the person within your firm who was associated with that company, the year of the event, the owner of the project, the project and the basis for the action. 14. In the last 10 years has your firm been denied an award of a public works contract based on a finding by a ublic agency that your company was not a responsible bidder? Yes ~ No If "yes," explain on a separate signed page. Identify the year of the event, the owner, the project and the basis for the finding by the public agency. 15. In the past 10 years has any claim a ainst your firm concerning your firm's work on a construction project been filed in court arbitration or mediation? Yes ^ No If "yes," on separate signed sheets of paper identify the claims} by providing the project name, date of the claim, name of the claimant, a brief description of the nature of the claim, the court in which the case was filed and a brief description of the status of the claim (pending or, if resolved, a brief description of the resolution). 16. In the past 10 years has your firm made any claim against a project owner concerning work on a project or a meat for a contract and filed that claim in eoar,~arbitration or mediation? Ycs ^ Nu If"yes," on separate signed sheets of paper identify the claim by providing the project name, date of the claim, name of the entity {or entities) against whom the claim was filed, a brief description of the nature of the claim, 00...60746 Bozeman WRF Phase i Improvements Project 7/28/2005 ooat3o - s the court in which the case was filed and a brief description of the status of the claim {pending, or if resolved, a brief description of the resolution). 17. At any time during the past 10 years, has any surety company made any payments on your firm's behalf as a result of a default, to satisfy any claims made against a performance or payment bond issued on your firm's behalf, in connection with a construction project, either public or private? ^ Yes ~ No If "yes," explain on a separate signed page the amount of each such claim, the name and telephone number of the claimant, Qta Jatc of the claim, the grounds for the claim, the present status of the ciaun, the date of resolution of such claim if resolved, the method by which such was resolved if resolved, the nature of the resolution and the amount, if any, at which the claim was resolved. 18. Has your firm or any of its owners, officers or partners ever been found liable in a civil suitor found guilty in a criminal action for making any false claim or material misrepresentation to any public agency or entity? ^ Yes ~ No If "yes," explain on a separate signed page, including identifying who was involved, the name of the public agency, the date of the investigation and the grounds for the finding. 19. Has your firm or any of its owners, officers or partners ever been convicted of a crime involving any federal, state, or local law related to construction? ^ Yes ~ No If "yes," explain on a separate signed page, including identifying who was involved, the name of the public agency, the date of the conviction and the grounds for the conviction. 20. Has your firm or any of its owners, officers or partners ever been convicted of a federal, state or local crime of fraud, theft, or any ocher act of dishonesty? ^ Yes ®No If "yes," identify on a separate signed page the person or persons convicted, the court (the county if a state court, the district or location of the federal court), the year and the criminal conduct. 21. During the last five years, has your firm ever been denied bond coverage by a surety company, or has there ever been a period of time when your firm had no surety bond in place during a public construction project when one was required? ^ Yes c~ No If yes, provide details on a separate signed sheet indicating the date when your firm was denied coverage and the name of the company, or companies, which denied coverage; and the period during which you had no surety bond in place. 22. Has any s[a[e OSHA or federal OSHA cited and assessed penalties against your firm for any "serlous,'° "willful" or "repeat" violations of its safety or health regulations in the past five years? (NOTE: If you have filed an appeal of a citation, and the Occupational Safety and Health Appeals Board has not yet ruled on your appeal, you need not include information about it.) ^ Yes ~ No If "yes," attach a separate signed page describing the citations, including information about the dates of the citations, the nature of the violation, the project on which the citation(s) was or were issued, the amount of penalty paid, if any. If the citation was appealed to the Occupational Safety and Health Appeals Board and a decision has been issued, state the case number and the date of the decision. 00...60746 Bozeman WRF Phase 1 Improvements Project 7!28/2008 00480 - ti 23. Has the EPA or any State or Local regulatory agency (Air Quality Management District, state Department of Environnicntal Quality, ctc.) citad and assessed penalties for any environmental regulation against either your firm or the owner of a project on which your firm was the contractor, in the past five years? (NOTE: If you have filed an appeal of a citation and the Appeals Board has not yet ruled on your appeal, or if there is a court appeal pending, you need not include information about the citation.) ^ Yes ~ No If "ycs," attach a scparata sigucd paga describing each citation. 24 Within the last 1 fl vearc hat rt,PfP P.,e.1.nP.......,~:...J ...~.......__._ r...__ ,__ ~ _.__ _, ... - - ~ --- - r----- •• ---•- ~ `-_• -••••• ••~~ ..,,,r....~ wu vu,. rraa witltVUt WUfKCfS compensation insurance or state-approved self-insurance or was exempt? ^ Yes c~ No If "yes," please explain the reason for the absence of workers' compensation insurance on a separate signed pagc. If"No," please provide a statement by your current workers' compensation insurance carrier that verlfles periods of workers' compensation insurance coverage for the last five years. (If your firm has been in the construction business for less than five years, provide a statement by your workers' compensation insurance carrier verifying continuous workers' compensation insurance coverage for the period that your firm has been in the construction business.) D. RECENT CONSTRUCTION PROJECTS COMPI,,ETED 1. Contractor shall provide information about its three comparable municipal mechanical water and/or wastewater treatment plant projects completed within the last five years, with capacities of 5 mgd or greater and a minimum construction cost of $10 miIIion or greater. Names and references must be current and verifiable. Use separate sheets of paper that contain all of the following information for each reference project and use as many sheets as needed: a. Project Name: Clavey Road Sewage Treatment Plant Improvements Location: Highland Park, IL Owner: North Shore Sanitary District Owner Contact (name a, id currant phuue cumber): Brian Dorn (847)623-6060 Architect or Engineer Donohue & Associates Architect of Engineer Contact (name and current phone number): Craig Holmes (920) 208-0296 Construction Manager (name and current phone number): Not applicable 00...60746 Bozeman wRF Phase 1 Improvements Project 7/28/2008 00450 - 7 Description of Project, Scope of Work Performed: Replacement of the odor control system at the raw sewage pump station, primary clarifiers and anaerobic digesters, integrating the plant's wide programmable logic controller system, converting gravity thickeners to sludge storage tanks, adding primary clarifiers, as well as adding a sludge dewatering system and three new gravity belt thickeners. Twenty programmable logic controllers for all process sytems were added to fully automate the plant. ~ Original Total Bid Price: $19,150,000 Total Value of Construction (including changc o--dcrs): $19,528,404 Original Scheduled Completion Date: May 1, 1999 Time Extensions Granted (number of days): 334 calendar days Actual Date of Completion: April 1, 2000 b. Project Name: Owner: ~:x~~* Gurnee Sewage Treatment Plant Modifications & Additions Location: Gurnee, IL North Shore Sanitary District Owner Contact (name and current phone number): Brian Dorn (847)623-6060 Architect or Engineer: Donohue & Associates Architect or Engineer Contact (name and current phone number}: Craig Holmes (920) 208-0296 Not applicable Construction Manager (name and current phone number): Description of Project, Scope of Work Performed: This project consisted of major improvements to the plant's operation which included replacement of the odor control system at the raw sewage pump station, primary clarifiers and anaerobic digester integrating the plant wide programmable logic controller system, converting gravity thickeners to sludge storage tanks, adding primary clarifiers, as well as adding a third belt press and three new gravity belt thickeners. The plant expansion was from 15 MGD to 18MGD, adding primary and secondary clarifiers, primary and secondary aeration tanks. To fully automate the plant, 16 PLC's were installed for all process systems and integrating Original Total Bid Price: $26,450,000 all systems for a plant wide control system. Total Value of Construction (including changc orders): $27,624,874 Original Scheduled Completion Date: February 1, 2000 OD...6074G Bozeman WRF Phase t Improvements Project 7/2812008 00480 - 8 Time Extensions Granted (number of days): 275 calendar days Actual Datc of Completion: November 2000 ••~~x~ CLCJAWA Phase 2 Water Treatment Plant & Pumping Station c. Owner: Protect Name: Location: Lake Bluff, IL Central Lake County Joint Action Water Agency (CLCJAWA) Owner Contact (name anri rnrrenr nhnnP m~mi.>r~• Mr. Ed Glatfelter (847)295-7788 Architect or Engineer: Camp Dresser & McKee, Inc. Architect or Engineer Contact (name and current phone number): Cuneyt Feizoulof (312) 346-5000 Construction Manager (name and current phone number): Not applicable Description of Project, Scope of Work Performed: Improvements at Paul M. Neal Water Treatment Plant include installation of new residual solids processing facilitis, new ultraviolet light disinfection facilities, new clearwell, new building addition, new power generation facilities, replacing existing finished water pumps and installation of a new security system. Improvements at Raw Water Pump Station incude new seal water system and installation of new security system. Improvements at Booster Pump Station include the installation on new security systems. Original Total Bid Price: $26,864,803 Total Vaiue of Construction (including change orders): $27,319,876.02 Original Scheduled Completion Date: February 21, 2005 Time Extensions Granted (number of days}: 457 calendar days Aetunl Dntc of Completion: May 24, 2006 ***~*s* I, the undersigned, certify and declare that I have read all the foregoing answers to this request for information and know their contents. The matters stated in the request answers are true of my own knowledge and belief, except as to those matters stated on information and belief, and as to those matters I believe them to be true. I declare under penalty of perjury under the laws of the State of Montana that the foregoing is correct. SIGNED this 8th day of October , 2008. 00...60746 Bozeman WRF Phase 1 Improvements Project 7/28!2008 00480 - 9 Joseph J. Henderson & Son, Inc. ame o' Compa~ " :----~.. Sio re of Certifying Official David A. Henderson Name of Certifying Official President 'T'itle OO...b0746 Bozeman WRF Phasc 1 Improvements Project 7/28/2008 00480 -10 .- ' ,' ~.: EnglneerS...VVorking Wonders With Wafer` October 8, 2008 To Whom It May Concern: Carollo Engineers has been providing planning, design, and construction management services for municipal clients since 1933. We are the largest consulting firm in the United States that is dedicated solely to water and wastewater treatment. This status has allowed us to experience a diverse group of Veneral contractors across the nation. Carollo Engineers performed design, and on-site inspection for the City of Lake Forest Illinois, Water Treatment Plant -Membrane Rehabilitation Project. Joseph J. Henderson & Son, Inc. performed the $20 million construction of the new membrane filtration facilities. The project also included replacing the existing 1950's high service pumping facility with new high service facilities having a design capacity of 14 million gallons per day including, repair and reconstruction of existing improvements affected by the work, and incidentals for a complete and usable facility. The overall project was completed after 26 months of construction, on-time and under the City's budget with Change Orders -including owner-requested additions to the Scope -averaging less than 1 percent of the initial bid amount. I highly recommend Joseph J. Henderson & Son, Inc. for your treatment plant construction needs. I can truly say that working with them has been a rewarding professional experience. Sincerely, CAROLLO ENGINEERS, P.C. (~- w° ~~ Vincent Roquebert Project Manager 12592 W Explorer Dr., Suite 200, Boise, Idaho 83713 P. 208.376.2288 F. 208.376.2251 carollo.com ~. _ .~ _ ;k;~i ~" To V4'hom It May Concern: DuPage County Illinois (www.dupa 7cco.or ~) operates Wastewater Treatment at a normal capacity of 20 Million Gallons per Day. As the retired Chief Operating Ofticcr of DuPage County, I have had the pleasure of working with Joseph J. Henderson & Son, Inc. (JJH) over the past 10 years. During that period, JJH has completed over S45 Million Dollars of construction upgrades to the existing facilities. Joseph J. Henderson & Son, Inc. has provided the County with many years of successful Design/Bid/Build and Design/Build Wastewater Treatment projects. These projects included; Bar Screen modifications, 125' Diameter Excess Flow Clarifiers, Grit Tanks, Aeration Tanks, Sphtter Structures, Mechanical Upgrades including Pumps and Clarifier Equipment, Electrical Upgrades including MCC installations, SCAUA [Ipgrades, Digester Improvements including new Covers and Mixing Systems, Belt Press Installations, and all aspects of the Wastewater Treatment Process. Currently, I am working with Joseph J. Henderson & Son, Inc. on a Wastewater Treatment DesignlBuild project to upgade the Grit Removal capabilities for DuPage County. "fhis project required a coordinated effort between JJH and DuPage County to help solve the Grit Removal needs within the budget constraints. Joseph J. Henderson & Son, Inc was successful in redesigning this grit facility originally designed by Fortune 500 design firm, to address the County's requirements and stay within the allotted budget. 1 highly recommend Joseph J. I-Ienderson & Son, Inc. for all of your Wastewater Treatment plant needs. I can truly say that working with them over the years has been a rewarding professional experience Igor me. Very truly yours, t1.~<~ Gregory W. VGileox, P.E. Vice-President . _ ~.. .. .. ..: t~+ I . V I October 9,, 2008 Mr. David Henderson Joseph J. Henderson & San, Inc, 4288 Old Grand Avenue Gumee, IL 60031 Hello Dave: I have seen representatives from JJH at several functions over the last few years and I always told them the same thing: Despite a rather challenging an,d complicated project, I was very impressed and grateful for the commitment shown by you and yowr staff on our project. We had some very interesting "curves" thrown at us during the Phase Two construction project and JJH remained dedicated to completing the project while continuing a strong conunitment to the quality of the workmanship and final product. I hope we have an opportunity to work with you again on a future project. Sincerely, ~L~-ems. William D. (Burr) T~oepsel, Jr. Director of Operations Central Lake County Joint Action Water Agency OCT-09-2008 04:04PM From: 8472957788 ID:JJ HENDERSON Paee:001 R=95% TRAVELERS ,1 Brenda D. Hockberger Underwriter, Construction Services, Travelers Bond 215 Shuman Blvd., Naperville, IL 60563 Telephone: (630)961-7012 Fax: (630)961-7020 September 26, 2008 City of Bozeman 411 E. Main Street Bozeman, MT 59771 RE: PREQUALIFICATION PACKAGE: CONTRACTOR: Joseph J. Henderson & Son, Inc. 4288 Old Grand Avenue, Gurnee, Illinois 60031 Project: Water Reclamation Facility Phase 1 Improvements To Whom It May Concern: TRAVELERS CASUALTY AND SURETY COMPANY, a Connecticut Corporation, is the surety company for JOSEPH J. HENDERSON & SON, INC. At the present time, we are providing JOSEPH J. HENDERSON & SON, INC., with a single project limit of $75,000,000 and a total bond program in excess of $150,000,000. We consider them to be a high quality construction organization and a very valuable client/partner and wouldn't hesitate to recommend JOSEPH J. HENDERSON & SON, INC., to any owner or architect on any construction contract. We may comment only favorably on the ability of JOSEPH J. HENDERSON & SON, INC., to push a project through to completion on or before the deadline set by the owner, architect or engineer. Indeed, during the time we have serviced this account, JOSEPH J. HENDERSON & SON, INC. has consistently met all its obligations and the company's excellent track record has resulted in many repeat contracts. In closing, we have the utmost confidence in the integrity and ability of JOSEPH J. HENDERSON 8 SON, INC. They have been extremely successful in developing a strong organization from both a management and financial standpoint. TRAVELERS CASUALTY AND SURETY COMPANY hereby agrees if JOSEPH J. HENDERSON & SON, INC., is awarded the contract for the above captioned job, we are prepared to underwrite the required Performance and Payment bond, subject to acceptable contract details and bond forms. TRAVELERS CASUALTY AND SURETY COMPANY is authorized to transact business in all fifty (50) states with a Treasury Listing of $348,511,000 and is rated A+ XIII by A.M. Best Company. Should you desire more information on our bonding relationship with JOSEPH J. HENDERSON & SON, INC., please do not hesitate to contact us. Yours truly, TRAVELERS C UALTY AND SURETY COMPANY Brenda D. Hockberger Attorney-In-Fact WARNING: THIS POWER OF ATTORNEY IS INVALID WITHOUT THE RED BORDER ~~=-- '~ POWER OF ATTORNEY TRAVELERS ~ Farmington Casualty Company St. Paul Guardian Insurance Company Fidelity and Guaranty Insurance Company St. Paul Mercury Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. Travelers Casualty and Surety Company Seaboard Surety Company Travelers Casualty and Surety Company of America St. Paul Fire and Marine Insurance Company United States Fidelity and Guaranty Company Attorney-In Fact No. 2201 l0 Certificate No. 0 0 2 4 4 7 9 4 3 KNOW ALL MEN BY THESE PRESENTS: That Seaboard Surety Company is a corporation duly organized under the laws of the State of New York, that St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company and St. Paul Mercury Insurance Company are corporations duly organized under [he laws of the State of Minnesota, that Farmington Casualty Company, Travelers Casualty and Surety Company, and Travelers Casualty and Surety Company of America are corporations duly organized under the laws of the State of Connecticut, that United States Fidelity and Guaranty Company is a corporation duly organized under the laws of the State of Maryland, that Fidelity and Guaranty Insurance Company is a corporation duly organized under the laws of the State of Iowa, and that Fidelity and Guaranty Insurance Underwriters, Inc. is a corporation duly organized under the laws of the State of Wisconsin (herein collectively called the "Companies"), and that the Companies do hereby make, constitute and appoint Dwight F. Miller, Carol F. Tasciotti, Evonne Brown, Adele M. Korczak, Grace Villarreal, Gail Schroeder, Cindy Genslinger, Gina M. Damato, Thomas A. Pictor, Erik Janssens, Jane Bronson, Michael Damewood, Rosemary Muliere, Kathleen M. Anderson, Vaenessa Sims, Luisa Catalano, Marva Miller, Thomas N. Tague, Brenda D. Hockberger, Meredith Day, Carlina A. Jewell, Tara S. Petersen, Todd D. Baraniak, Dale F. Poquette, Oscar F. Rincon, Heather Meyer, Moises Alcantar, James P. Fagan, Amar Patel, Heather J. Meneghetti, John C. Redding, Stephanie Miller, Phil Horvath, Grace Lawrence, David Letcher, Andrew S[ontz, and Jennifer Seppi of the Ciry of Naperville/Chicago ,State of Illinois their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign, execute, seal and acknowledge any and all bonds, recognizances, conditional undertakings and other writings obligatory in the nature thereof on behalf of the Companies in Cheir business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. IN WITNFJuS n~VHEREOF, the Compat~~~ave caused this instrument to be signed and their corporate seals to be hereto affixed, this 17th day of Farmington Casualty Company Fidelity and Guaranty Insurance Company Fidelity and Guaranty Insurance Underwriters, Inc. Seaboard Surety Company St. Paul Fire and Marine Insurance Company St. Paul Guardian Insurance Company St. Paul Mercury Insurance Company Travelers Casualty and Surety Company Travelers Casualty and Surety Company of America United States Fidelity and Guaranty Company r u~ a pry~~If jL ~16 Stlttrl e ,tRE~~ ' QQ~TN....NSG9 ~~pj~ NSUq~tw,~ JP~(v 4NO SG l~1>~ -"~Y~ ~Y't~ S ~ () rt ~. ~~ f'OR FryR ~'~ O FPORR N'. 0 u ~ROttU •[~ z aic ~>f.y /e: ~os s Q Sy'^.FCN as ~ 1~7~I ~ l 1.727 ~ ~. C~ iv:00ry~rF~.~~ i 19Jr 7 F E n; a P HARTFORD < ~H1fiFOR0. ~ c ~~'~tD n ~ ~ ~ 9 # eti o ~tSEALjo% ~`:S8AL3 CONN. n ~~ ~ 7896 -~ ~ N a ~., d ~ n•'CFNEW~ bx~,~~~~E !S N~a{ o.•.... .~a '`s aac ~y, ,gyp ,,;Mr's ~r .... ~ 1 '~ '4t ~ v''! 'All ANtS`" State of Connecticut City of Hartford ss. By: Georg Thompson, enior ice President 17th June 2008 On this the day of ,before me personally appeared George W. Thompson, who acknowledged himself to be the Senior Vice President of Farmington Casualty Company, Fidelity and Guaranty Insurance Company, Fidelity and Guaranty Insurance Underwriters, Inc., Seaboard Surety Company, St. Paul Fire and Marine Insurance Company, St. Paul Guardian Insurance Company, SL Pau] Mercury Insurance Company, Travelers Casualty and Surety Company, Travelers Casualty and Surety Company of America, and United States Fidelity and Guaranty Company, and that he, as such, being authorized so [o do, executed the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. ~G.T~ In Witness Whereof, I hereunto set my hand and official sea]. TAI) My Commission expires the 30th day of June, 2011. ~'OIIBUG$ 58440-5-07 Printed in U.S.A. WARNING: THIS POWER OF ATTORNEY IS INVALID aru,~- C . ~.~'wr~~ Marie C. Tetreault, Notary Public THE RED BORDER Qualification Statement Item Nos. 15 & 16 (Cases were filed in Lake County, Illinois Circuit Court unless otherwise noted.) Following a termination for convenience at approximately 99% completion, the client delayed payment for contract sum and extras causing the subcontractors to file suit to preserve their lien rights. All suits have been dismissed. In the following cases, a Subcontractor's employee was allegedly injured on our jobsite and filed suit. Defense was picked up by our Subcontractor: Blayne Prassel v. Joseph J. Henderson & Son, Inc. (Lake County, IL case was dismissed, plaintiff refiled in Cook County -pending); Howard Biederer v Joseph J. Henderson & Son, Inc. and Benson Electric (pending). A Subcontractor's employee had a heart attack and died on our jobsite and the estate has filed suit: Estate of Dale Swick v Joseph J. Henderson (pending). The following cases were contract actions: Asra Technologies, Inc. v Joseph J. Henderson and Travelers Casualty and Surety Co. (judgment against the plaintiff); Chenoa Welding & Fabricating, Inc. v Joseph J. Henderson (Filed in McLean County, Illinois -settled and dismissed) Claimant alleged that JJH failed to protect their building from rain and other damaging weather conditions: Transfiguration Church v Joseph J. Henderson (voluntarily dismissed). In the following cases a Subcontractor's subcontractor (second tier) filed a lien and suit to collect alleged extras from the Subcontractor (first tier) and named JJH in the proceeding: Hicks Excavating v Joseph J. Henderson and Central Lake County Joint Action Water Authority (dismissed); Steiner Electric Co, v Aldridge Electric, Inc., Joseph J. Henderson and Travelers Casualty and Surety Co.(dismissed); Vulcan Construction Materials, LP v Terra Cotta Trucking and Joseph J. Henderson (filed in McHenry County, IL Circuit Court -dismissed) Subcontractor's supplier alleges they were not paid for all materials supplied by our paid subcontractor and filed claim against the bond and suit: Great Falls Sand & Gravel v Joseph J. Henderson, Travelers Casualty and Surety Co., and Robec Navajo Construction LLC (Filed in Great Falls, Montana -settled); Patrick Construction Inc. aka TP Construction, Inc. vRobec-Navajo Construction LLC, Ro-Bec Companies, LLC, Travelers Casualty & Surety Co. of America and Joseph J. Henderson & Son, Inc. (Filed in U.S. District Court of Montana -pending) Subcontractor's employee alleges they were misciassified and has made a claim under Davis-Bacon for wages: Brian Vislay v Leroy Tift dba Four Seasons Siding Contractors, Tift Enterprises dba Four Seasons Siding Contractors, and Joseph J. Henderson (Filed in Cascade County, Montana -pending) Joseph J. Henderson & Son, Inc. General Contractor Established 1928 JOSEPH J. HENDERSON & SON, 1NC. BALANCE SHEET DECEMBER 31, 2007 ASSETS CURRENT ASSETS Cash and cash equivalents $ 2,277,803 Certificates of deposit 49b,634 Contract receivables 11,903,007 Other receivables 40,496 Costs and estimated earnings in excess of billings on uncompleted contracts 718,455 Inventory 26,013 Prepaid expenses 44b,802 15,909,210 PROPERTY AND EQUIPMENT 4,b73,911 Less: Accumulated depreciation 3,4]2,564 ],261,347 OTHER ASSETS 73,208 $ 17,243,765 Page 2 LIABILITIES AND STOCKHOLDERS' EQUITY CURRENT LIABILITIES Accounts payable including retainages of $4,716,190 $ 8,699,930 Current portion of long-term debt 89,088 Billings in excess of costs and estimated earnings on uncompleted contracts 1,566,516 Accrued liabilities: Income taxes 7,586 Other 19,47 i 10,3 82,59 LONGTERM DEBT 159,936 10,54"L,527 STOCKHOLDERS` EQUITY Common stock - $100 par value; Authorized - 20,000 shares; Issued and outstanding - 75 shares 10,000 Retained earnings 6,691,238 6,701,238 $ ! 7,243,765 1 ' 1 ' 1' 1 ' i l' ~ 1 ~ • ' ~ j ~ I 1 ' 1 1 ~ STATE Of MONTANA DEPARTMENT OF LABOR 8c INDUSTRY CONSTRUCTION CONTRACTOR REGISTRATION UNIT CERTIFICATE OF CONTRACTOR 12EGISTRATiON RE~i1STRATION N~8491 JOSEPH J HENDERSON & SON 1NC 2713 IVY DR GREAT FALLS, MT 59404 Effective Date: Sep 15, 2008 Expiration Date: Sep 14, 2010 Employer Additional information on back. F'leuse not:fy this agency of any changes within ~o days. SECRETARY OF STATE STATE OF MONTANA BRAD JOHNSON T 8 M w JOSEPH J. HENDERSON AND SON, INC. PO BOX 9 GURNEE IL 60031-0009 October 12, 2005 Dear Sir or Madam: Montana State Capitol PO BOX 202801 Helena, MT 59620-2801 (406)444-3665 http://www.sos.mt Qov RE; JOSEPH J. HENDERSON AND SOLI, ~+C: CERTIFICATE OF ll:3'Tf~.ORH'Y ~ling.Date October ll. 2005 Filing 1Vurr;iber: F-4r~977 - 309044 I've approved the filing of the documents for the above named entity. The document number and filing date have been recorded on the original document. This letter serves as your certificate of filing and should be maintained in your files for future reference. Thank you for giving this office the opportunity to serve you. If you have any questions in this regard, or need additional assistance, please do not hesitate to contact the Business Services Bureau professionals at (406) 444-3665. Sincerely, l ,i~~ BRAD JOHNSON Secretary of State You can correspond with our office via facsimile. Our fax number is (406) 444-3976. You can now fax in Your search, copy. and certificate requests. Water & Wastewater Treatment Plant Projects Qualification StalemeN Item No. 1 PROJECT OWNER WAS'tF.WA7~ER'IREATMIN'f PLANT Flagg ('reek Water Reclamation District Flagg Creek Water Reclamation District 700] Frontage Road 2007 Wastewater'freatment Plain Improvements Burr Ridge, 11.60527 Project Contract 2008-001 Burr Ridge, lI. WASTEWA'T'ER "TREATMENT PLANT City of Marseilles North Wastewater Treatment Plain Improvements 209 Lincoln Street Marsei0es, IL Marseilles, iL 61341 WATER RECIAMATION CENTER Biosolids Thickening and Digester Aeration Additions and Improvements Springbrook Water Reclamation Center Naperville, II- City of Naperville 400 South Fagle Street Naperville, II.. 60566 WATER'IRF?ATMENT PLANT Antioch Water Treatment Facility Antioch, IL. WATER'TRP.ATMEN'T PLAN"C bake in the Hills Pollution Control Facility bake in the Hills, II. WAS'T'EWATER TREATMENT PLANT Huntley Wastewater Treatment Plant -Phase 3 Huntley, IL WA7~1i12 RECLAMATION FAC11,1'1'Y Ogden Dunes Water Reclamation Facility Chemical Facilities Improvements Portage, IN IRRIGATION PUMP STATION Huntley Irrigation Pumping Station No. 2 Huntley, IL WASTL:WA'I'ER'TREA"1'MENT PLAN"f Antioch Wastewater "treatment Plant Improvements Antioch, IL WATER TREATMENT PLANT River Grange Water System River Grange, IL WATER TREATMENT PI.AN'f Bloomington Normal Water Reclamation Plant Bloomington, IL WA'fE12 TRIA1'MEN"t PLAN7~ Premom Schools Water'freatment Plant Upgrades Mundelein, II, W AS71 W A'f ER TREATMENT PLANT Mundelein Clarifier Equipment Mundelein. 11, W ASTIi W A"f F.R TREATMENT PLAN'P Bowes Creek Country Club Litt Station lilgin, II, WASTEWATER TREA1'MEN1' PLANT Valparaiso Pollution Control Facility Valparaiso, IN WAS"1'fi W A"TER TREAT MEN'1' Knullwood Gri[ Removal Burr Ridge, IL ARCHITECT Consoer Townsend Environmental 303 E. Wacker Drive Chicago, IL 60601 312-938-0300 Baxter & Woodman, Inc 8678 Ridgefield Road Crystal Lake, IL 60012 815-459-1260 Earth Tech, Inc. 4135 Technology Parkway Sheboygan, WI 53083 CONTRACT comPLF'rloN AMOUNT DAl h $ 7,155,000.00 under construction $ 5,377,000.00 under construction $ 10,995,000.00 under construction Neumann Homes Smith Engineering Consultants, Inc. 4355 Weaver Parkway 4500 Prime Parkway Warrenville, ll. 60555 McHenry, IL 60050 Bill Booker 630-669-8641 Kevin Flood R15-385-1778 Lake in the Hills Sanitary District Wight Consulting 515 Plum Street 234 James Street, Suite 100 lake in the 1-tills, IL 60102 Barrington, H. 60010 Village of Huntley Baxter & Woodman, Inc. $ 1133 Kiley Drive 8678 Ridgefield Road Huntley, IL 60142 Crystal Lake, IL 60012 815-459-1260 Indiana American Water I,intech Engineering $ 650 Madison Street 1496 Merchant Drive Gary, IN 46401-0486 Algonquin,lL 60102 VillageolHuntley Baxter&Woodman,Inc. $ 1133 Kiley Drive 8678 Ridgefield Road Huntley, IL 60142 Crystal take, IL 60012 815-459-1260 Village of Antioch Applied 'T'echnologies, Inc. $ 874 Main Street 16815 West Wisconsin Avenue Antioch, IL 60002 Brookfield, WI 53005 American Water Company American Water Company $ 1000 Internationale Parkway 1000 Internationale Parkway Woodridge, IL 60517 Woodridge, IL 60517 Bloomington-Normal Water Reclamation District Farnsworth Group, inc. $ R.R. 7 W. Oakland Avenue Road 2709 McGraw Drive Bloomington, IL Bloomington, IL Fremont School District 79 PSA Dewberry, Inc. $ 28855 N. Fremont Center Road 40 Shuman Blvd, Suite 175 Mundelein, IL 60060 Naperville, IL 60563 Village of Mundelein Baxter & Woodman, Inc. $ 440 East Crystal Street 3I South Seymour Mundelein, IL 60060 Grayslake, IL 60030 Paul Cacioppo (847) 949-3276 Michael DeBennette (847) 223-5088 'l'oll Brothers Cemcon, Ltd. $ 1153 W. llundee Road 2280 White Oak Circle, Suite 1.00 Arlington Heights, IL 60004 Aurora, IL 60504-9675 Leah Noparski(847)590-5100 (630)862-2100 Valparaiso City Utilities Malcolm Pirnie, Inc. $ 205 Billings Street 5975 Castle Creek Parkway, North Drive Valparaiso, IN 46383 Suite 355 Indianapolis, IN 46250 ('amp Dresser & McKee DuPage County Procurement Division $ 125 S. Wacker Drive, Suite 600 421 North County Farm Road Chicago, IL 60606 Wheaton, IL 60187 312-346-5000 Page 7 3,357,183.00 under construction $ 10,156,744.00 under construction 14,320,000.00 under construction 2,646,245.00 under construction 402,000.00 under construction 13,700,000.00 under construction 330,701.00 under construction 5,861,393.00 under construction 747,925.00 under construction 698,300.00 under construction 1,718,387.00 under construction 7,220,705.00 under construction 4,049,000.00 under construction Joseph J. Henderson Son, Inc. General Contractor Established 1928 Water & Wastewater Treatment Pl t P Quali(ica(ion Statement Item No. I an r ojects PROJECT wATER'rREA"rn-IEN'r PLANT OWNER ARCHITECT CONTRACT coMPI.E7'lox Contract A.4 Wells #]0 ] 1 Water'I'reatment Plant Kimball Hill Homes,LLC 5999 New Wilke Road S i Engineering F,nterprises, Inc. $ AMOUNT DATE 4 669 50 Sugar Grove, IL , u te 504 Rolling Meadows IL 60008 52 Wheeler Road , , 9.00 Jan-O8 , Sugar Grove, IL. 60554 630-466-93550 WASTEWATER TREATMENT YLAN'I' Wonder lake W WTP -Unit 2 W Neumann Homes 4355 Weaver Parkway Manhard Consulting Ltd. $ 2 087 9] 1 00 onder lake, IL Warrenville, II, 60555 900 Woodlands Parkway , , . Dec-07 lloug Nataluk 630-281-2012 Vernon Hills, IL 60061 Rick Leber 847-634-5550 WASTF;WA'rER TRFA'CMF,Nr YL/WT Hebron Wastewater Treatment Plant Village of Hebron 12007 Prairie Av Applied Technologies, Inc. $ 4 52 Hebron, ll. enue Hebron, IL 60034 16815 W. Wisconsin Avenue , 3,557.00 Dec-07 Brookfield, WI 53005 608-251-4813 W AS'f P; W ATER TREA"I'M ENT YI ANT ' , ']'horn Creek Basin L"ift Station thorn Creek Aasin Saintary llistrict ' Greeley & Hansen I LC Chicago Heights, 11, 700 West E nd Avenue Chica> ],o Heights, II, 604]1 , - $ ]00 South Wacker Drive, Suite 1400 3,915,805.00 Dcc 07 Chicago, IL 60606 Dave Hobbs W ASTIi W ATER 'PREA'rMEN"r PLANT Lakewood Wastewater Treatment Plant Village of Lakewood 2500Iake Avenue Aaxter & Woodman, Inc. $ 11 384 938 00 Lakewood, IL Lakewood, IL 60014 8678 Ridgefield Road , , . Dec-07 Crystal lake, IL 60012 815-459-1260 WATER TREATMENT YIr1N'r North Side Potable Water Aooster Station R Village of Rosemont 9501 W. Devon Avenue Christopher B. Burke Engineering, Ltd. $ 1 206 400 00 osemont, Il, Rosemont, IL 60018 9575 West Higgins Road, Suite 600 , , . Dec-07 Rosemont, IL" 600]8-4920 WAS'r1WATER TREATMENT PLANT Minooka W W'I'P Expansion 2005 Village of Minooka ]21 E. McEvilly Road Robert E. Hamilton Consultin Fn moors g g~ $ 7 823 649 00 Minooka, II. Minooka, IL 60447 3230 Executive Drive , , . Nov-07 Joliet, IL 6043] Joc Regis 815-722-3444 WA"1'ER "TREATMENT PLANT Volo South Water Treatment Ylant The Ryland Group, Inc, 1141 East Main Street Suite 108 Manhard Consulting, Ltd. $ 2 082 894 00 Volo, IL , Bast Dundee, IL 60118 900 Woodlands Parkway , , . Nov-07 John Luczynski Vernon Hills, IL 60061 Lee Melchor WATER 'rR1ATMENT PLANT Village of Bannockburn Bannockburn Reservoir and Pump Station 2275 Telegraph Road Gewalt Hamilton Associates, Inc. $ 2 600 D00 00 Bannockburn, IL Bannockburn, IL 60015 850 Forest Edge Drive , , . Nov-07 Vernon Hills, IL 60061 WATER 7'REATMEN"r PLANT Fox River Water Reclamation District Skyline WTP E Fox River Water Reclamation District Raymond Street & Purif Drive Baxter & Woodman, Inc. $ 2 354 511 00 S lgin, IL y Elgin, IL 60121 8678 Ridgefield Road , , . ept-07 847-742-2068 Crystal lake, IL 60012 815-459-1260 WASTEWATER TRIIATMEN'I' PLANT Pox River Water Reclamation District Ammonia Removal Fox River Water Reclamation District Raymond Street & Purif Drive Greeley & Hansen $ 1 497 994 00 J l FJgin, II. y Elgin, 11" 60127 100 S. Wacker Drive, Suite ]400 , , . u -07 847-742-2068 Chicago, IL 60606 312-558-9000 WA"I'ER "I'RF>ATMf:NT PL.AN'I' ' American Water Santo F e Water Reclamation Facility Filter Press W 1000 Internationale Parkway Lintech Engineering LI"C $ 1,126,789.00 lun-07 oodridge, IL Woodridge, IL 60517 ]496 Merchant Drive Bob Khan 630-739-8827 Algonquin, IL 60102 Jeremy Lin 847-960-7150 WATER TREA'rMEN'r PLANT Neumann Homes Wonder Lake WTP -Unit 1 Wonder Lake, IL 4355 Weaver Parkway Manhard Consulting Ltd. $ 900 Woodlands Parkway 2,931,988.00 May-07 Warrenville, IL 60555 Vernon Hills IL 60061 Doug Nataluk 630-281-2012 , Rick Leber847-634-5550 WASTEWATER TREATMENT PLANT Terra Cotta Realty Terra Cotta W WTP P i i 3703 S. Route 31 Lintech Engineering, LLC $ 9,031,340.00 Feb-07 ra r e Grove, IL Crystal lake, IL 500 Coventry Lane, Suite 270 Bob Eck 815-333-8235 Crystal Lake, IL 60014 Jeremy Lin 815-479-5180 WA"CEI2 & WASTEWATER TREATMENT PLANT llRH Cambridge Homes Inc Yingree Grove W WTP &WTP Pingree Grove, IL , . 800 S. Milwaukee Avenue Linteech Engineering LLC $ 500 Coventry Lane Suite 270 14,397,963,Op Sept. 06 Libertyville, IL, 60048 , Crystal I-ake IL 60014 Erik Sandstedl 847-984-4444 , Jeremy Lin 815-479-5180 WASTEWATER TREATMENT PLANT Hinsdale Sanitary District _ Hinsdale Digester M4 Rehabilitation Hi 6975 Commonwealth Highway Lintech Engineering LLC $ 1,106,588.00 Sept O6 nsdale, lt. Hinsdale, II.6052] ]496 Merchant Drive 630-323-3299 Algonquin, IL 60102 Jeremy Lin 847-960-7150 Joseph J. Henderson Son, Inc. Page 2 General Contractor Established 1928 Water & Wastewater Treatment Plant P t QusliCcation Statement Item No. 1 rojec s PROJECT ' ' ' OWNER WAS 1 EWAI ER TREATMENT PLANT D Downers Grove Sanitary District owners Grove Wastewater'freatment Plant 2710 Cuniss Street Downers Grove, II, Downers Grove, IL 60515 WATER "fREA"fMIiNT YL.ANT 'full Brothers Inc Woods of South Barrington South Barrington, 11' , . Applied Water Management, Inc. Mark Strauss 908-43]-7002 WAS'I'L'WA'fFR TRF:A"1'MEN'f PLANT Noah Shore Sanitary District NSSD Sludge Recycle Facility Wm. Koepsel Drive 7,ion, IL .Gurnee, IL 60031 Jai Gupta 847-623-6060 WATER 7REA"1'MEN"f PLANT Central Lake County Joint Action Central lake County Joint Action Water Agency Water Agency (CLCJAWA) Phase 2 Water Treatment Plant & Pumping Station 200 Rockland Road lake Bluff, IL Lake Bluff, IL 60044 Ed Glatfelter 847-295-7788 WA"I1:!R'IREATMEN'I' PLANT City of Waukegan Fountain Square Pumping Station 100 Martin Luther King Avenue Waukegan, IL Waukegan, II.60085 WATER'fREATMENI' PLANT Village of Lake Zurich Lake %urich W'I'P Well #10 505 Tesler Road lake 7,u rich, IL lake Zurich, IL 60047 Victor Ramirez 847-540-1696 WA"I'ER'I'RIiATMENT PLANT W d Kennedy Homes Limited Partnership oo s Creek -Wonder lake WTP 14 Executive Court Wonder lake, IL South Barrington, IL 60010 Jed Davis847-756.2100 WATER TREATMENT PLANT Lennar Corporation Ravenna Water Supply System P.O. Box 12010-LC Long Grove, IL Hemt, CA 92546 991-766-2274 WATER'fRL'ATMEN'I' PLANT City of Batavia Batavia W'fY 200 N. Raddanl Road Ratavia, IL Batavia, IL 60510 John Dillon 630-879-1424 WATER TREA"I'Mf?N"I' PLANT 1'asyuinelli Development Group Inc Wells #8 & #9 Well House & Treatment Faci]itY , . 535 Plainfield Road Suite E Yorkville, IL , Willowbrook, IL 60527 Jason Nijim 630-325-4500 WATER'fRF.ATMIiN"f PLANT Village of Glenview Rugen Road Pump Station & Reservoir 1225 Waukegan Road Glenview, II. Glenview, IL 60025 William Sarley 847-904-431) WASTEWA"I'ER TREATMENT PLANT Village of Fox Lake Fox Lake UV & Odor Control 66 Thillen Drive f'oz Lake, II. Fox Lake, IL 60020 Steve Vella 847-587-3694 WATER TREATMENT 1'I,AN'f Illinois American Water Company Illinois American Water -Nettle Creek 1000 Internationale Parkway Morris, IL' Woodridge, IL 60157 MattLasecki630-739-8810 WASJ'ISWA'fER'fRF.A'fMENT PLANT Village of Huntley Huntley East W WTP 11704 Coral; P.O. Box 1018 Huntley, IL Huntley, 11.60142 Jim Swartz 847-669-9600 WATfiR TREA'T'MENT PLANT City of Lake Purest Lake Forest WTP -Membrane Rehab. 220 East Deerpath Lake Forest, IL Lake Forest, IL 60045 Roger McCarran 312-207-1769 ARCHITECT Baxter & Woodman, Inc. 8840 W. 192nd Street Mokena, IL 60448 Lintech Engineering LLC 1496 Merchant llrive Algonquin, IL 60102 7eremy Lin 847-960-7150 Donohue & Associates, inc. 4343 S. Taylor Drive Sheboygan, WI 53081 Dave Speth 920-208-0296 Camp llresser McKee, Inc. 125 S. Wacker Drive, Suite 600 Chicago, IL 60606 CuneytFeizoulof312-346-5000 Clark Dietz, Inc. 5017 Green Ray Road, Suite 126 Kenosha, WI 53144 262-657-1550 Baxter& Woodman 8678 Ridgefield Road Crystal Lake, IL 60012 Jim F'ruit815-459-1260 Lintech Engineering .500 Coventry Lane Crystal Lake, IL 60014 Jeremy Lin 815-479-5180 Bloodgood,Sharp & Buster 847-705-2200 Odell Engineering, Inc. 760 Heartland Drive, Unit 2 Sugar Grove, IL 60554 Lee Odell 630-466-8670 Engineering Enterprises, Inc. 52 Wheeler Road Sugar Grove, IL 60554 Tim Farre11630-466-9350 Consoer Townsend Environmental 303 E. Wacker Drive Chicago, 11.60601 Michael Winegard 312-938-0300 Clark Dietz, Inc. 4235 Green Bay Road, Suite 100 Kenosha, WI53144 Greg Droessler 262-657-1550 Lintech Engineering, LLC 500 Coventry Lane, Suite 270 Crystal Lake, IL 60014 <'.S. Lin 815-479-5180 Lintech Engineering, LLC 500 Coventry Lane, Suite 270 Crystal Lake, IL 60074 Jeremy Lin 815-479-5180 Carollo Engineers, P.C. 12592 Wesl Explorer Drive, Suite 200 Boise,ID 83713 Vincent Roquebert208-376-2288 CONTRACT coMPI.ETIDN AMOUNT A-1 „ $ 960,700.00 Sept. 06 $ 4,873,409.00 Sept. 06 $ 29,882,369.00 lul-06 $ 27,326,375.00 Jun-06 ~ 1,843,787.00 May-O6 $ 1,202,820.00 Dec-OS $ 1,454,358.00 Nov-OS $ 1,018,553.00 Sept-OS $ 3,029,255.00 Sept-OS ~ 3,0]1,092.00 Jul-OS ~ 6,442,45].00 Jul-OS $ 1,645,046.00 Apr-OS $ 64Q388.00 Jan-OS $ 4,630,996.00 Oct-04 $ 19,988,530.00 Nov-04 Joseph J. Henderson Son, Inc. Pege 3 General Contractor Established 1928 Water & Wastewater Treatment Plant P Qualification Statement Item No. 1 roj ects PROJECT ' ' OWNER CONTRACT coMPLETICN wAS t EwnTER TRJ:A'rMEN'r PLANT ' Village of Fampshire ARCHITECT AMOUNT DATE Hampshire W W rP Expansion H 234 South State Street Engineering Enterprises, Inc. $ 5,934,924.56 Sept-04 ampshire, 11, Hampshire, IL 60140-0457 52 Wheeler Road John Bidinger 847-683-2181 Sugar Grove, 11.60554 Jeff Freeman 630-466-9350 WAS"I'EWATFR'tREA"rMF,NT PLANT Village of Cary Cary WWTP Cary, IL 655 Village Hall Drive Baxter& Woodman, Inc. 8678 Ridgefield Road $ (,,406,839.00 Sept-04 Cary, IL 60013-2599 Crystal take IL 60012 Brad Fleck 847-639-0003 , Jim Frui[815-459-1260 WASTF,'WATER 7REA'I'MIiN"1' PLANT' Village of Bensenville Bensenville WWTP Sand Filter 735 Jefferson Street Lintech Engineering, I,LC $ 1,148,140.00 Jun-04 Bensenville, II. Bensenville, IL 60106 500 Coventry Iane, Suite 270 Paul Quinn 630-350-3431 Crystal lake, IL 60014 C.S. Lin 815-479-5180 RESERVOIR & PUMP STATION Village of Lisle Contract A-03, Forbes Drive Reservoir & Yum Station P ~ 1040 Burlington Avenue Alvord, Burdick & Howson, LI,C $ ],902,909.00 May-04 Lisle, Il, Lisle, Il, 60532 20 N. Wacker Drive Ray Petersen Chicago, IL 60606 William Meinholz 312-236-9147 WASTIiWATER'IREATMI?NT PLANT City of Waukegan Waukegan WWTP W k 360 Seahorse llrive Strand Associates, Inc. Engineers $ 2,140,]59.00 May-04 au egan, II. Waukegan, IL 60085 910 West Wingra Drive Jeff Musinski 847-599-2987 Madison, WI 53715 Steven Kluesner 608-251-4843 WAS'11:WATER TREATMENT PLANT Village of Plainfield Plainfield W W'I'P Improvements 530 West Lockport Street Baxter & Woodman, Inc. $ 16,188,873.00 Apr-04 Plainfield, IL Plainfield, IL 60544 8678 Ridgefield Road Allen Persons 815-436-3577 Crystal Lake, IL 600014 Jim Fruit 815-459-1260 WATER TREATMENT PLANT H Consumers Illinois Water Com an p y awthorn Woods WTP & Reservoir 1000 S. Schuyler Avenue Burke Engineering $ 2,126,399.00 Feb-04 Hawthord Woods,Il Kankakee, IL 60901 9575 W. Higgins Road, Suite 600 Terry Rakocy 217-442.0142 Rosemont, IL 60018 Mark Emory 847-823-0500 WAS'rF.WATER'I'REA'1'MENTPI,ANT L Glenbard WastewaterAuthorit y ombard CSO 21 W 551 Bemis Road Waller E. lleuchler Associates, Inc. $ 641,001.00 Feb-04 Lombard, IL Glen Ellyn, IL 60]37 230 Woodlawn Avenue William Kuzia 630.790_1y01 Aurora, IL 60506 William Nelson 630-897-4651 WAS71:?WATER TREATMENT PLANT Village of Carol Stream Carol Stream WRC Improvements 124 Gerzevske lane Lintech Engineering $ 6,639,753.00 Jan-04 Carol Stream, IL Carol Stream IL 60]88 S00 Covemry lane, Suite 270 Al turner 630-871-6260 Crystal lake, li, 60014 C.S. Lin 815-479-5180 WAS'I'}WA'rER TREATMENT PI,AN1' City of Woodstock Woodstock WWTP 326 Washington Street Baxter & Woodman, Inc. $ ],471,530.00 Jan-04 Woodstock, IL Woodstock, IL 60098 8678 Ridgefield Road Johnlsbell Crystal Lake, IL 60012 Paul Ruscko 815-459-1260 WATER & WASTEWATER TREATMENT PLANT Ryland Homes Gilberts WTP &WWTP 1051 Perimeter Drive Suite 400 B&W DesignBuild, LLC $ 12,113,135.00 Jan-04 Gilberts, Il. , Schaumburg, lI, 60]73 500 Coventry lane, Suite 270 John Luczynski847-995-9900 Crystal Lake, IL 60014 C.S.I,in 815-479-5180 WATIiR 7REATMEN'1' PLANT' Village of Elwood lilwood Water Treatment Plant D P.O. Box 435, 201 E. Mississippi Baxter & Woodman, Inc. $ 1,781,091.00 Jun-03 eer Run Industrial Park P,lwood IL 60421 8840 West 192nd Street Elwood, IL , 815-423-5011 Mokena, IL 60448 708-478-2090 WAS'1'}iWATER'rR1iATMI?NT PLANT ' Hinsdale Sanitary District }> Hinsdale W W1 Y.O. Box 179 Hinsdale Sanitary District $ 1,223,276.00 Mar-03 Sand Filter Rehabilitation }linsdale, II, 60522-0179 P.O. Box 179 Hinsdale, Il. Edward Kokat630-323-3299 Hinsdale, IL 60522-0179 Edward Kokat630-323-3299 WASTEWATER TREATMENT PLANT Village of Huntley Huntley West Phase II Improvements 11704 Coral Lintech Engineering, LLC $ 2,450,000.00 Mar-03 Huntley, IL Huntley, IL 60142 500 Coventry Lane, Suite 270 Jim Swartz 847-669-9600 Crystal Lake, IL 60014 C.S. Lin 815.479-5180 WASTEWATER TREATMENT PLANT ~ North Shore Sanitary District Sludge Drying/Melting Project - Wauke an g " P.O. Box 750; Wm. Koepsel Drive Donohue & Associates $ 49,158.00 Mar-03 Sewage treatment Plant Gurnee, II, 60031 4343 S. Taylor Drive Waukegan, IL Brian Dorn 847-623-6060 Sheboygan, WI 53081 David Froh 920-208-0296 Joseph J. Henderson Son, Inc. Page 4 General Contractor Established 1928 Water & Wastewater Treatment Plant Projects Qualification Statement Item No. 1 PROJECT WASTEWATfiR'I-RI:A'1-ML:NT PLAN"f Des Plaines River W W'1'P Sludge Thickening and Misc. Improvements Deer[ield, IL WA7BR'fREATMENTPLANT Roseland Freshwater Distribution & Pumping Station Chicago, IL WATER "fRF,ATMENT PLANT Lynch Avenue Water Booster Station Beach Park, IL WA"CIR TRE'ATMEN'T PLANT Lakemoor Well #3 Water 7-reatment Plant Lakemoor, IL WASTEWATER TREATMENT PLANT Hinckley Was(ewaterTreatment Plant Hinckley, II. WASTEWATER TREATMEN'T' PLANT Sludge Management Modifications Streator. IL WASTEWATER TREATMENT PLANT Humley Wust WWTP (Phase I) Huntley, II. WATER PUMPING STATION lake Water Supply lmprovements Citizens Utilities -Homer Township Homer Township, IL WA'T'ER RECLAMATION CENTER Carol Stream WRC Improvements Carol Stream, II. WASTEWATER TREATMENT PLANT Stormwater Clarifier & Appurtenances for Woodridge-Greene Valley STP Bid 00-081 Greene-Valley Sewage Treatment Nlant WASTEWATER "fREATMEN"I' PLANT Huntley East Wastewater Treatment Plant Huntley, IL WATER RECLAMATION FACILI"fY West Side Water Reclamation Facility Expansion Phase 2 SL Charles, IL WASTEWA'T'ER TREATMEN'T' YLAN'f Odor Control Improvements Citizens Utilities - Bolingbrook/S.F. Bolingbrook, II. WATER TREATMENT PLANT North Chicago WTP Improvements North Chicago, II. WA'ITiR 7RIA'fMIiNT PLANT Huntley Water'1'reatmem Plant Well No. 10 IlunOey, fl, OWNER lake County Central Services Dept. 18 North County Street, 7th Floor Waukegan, Il- 60085-4350 Charles Degrave 847-680-1600 City of Chicago Room 401 -City Hall Chicago, IL 60602 312-744-4000 llRH Cambridge Homes, Inc. 800 South Milwaukee Avenue, Ste 280 Libertyville, II, 60048 Erik Sandstedt 847-362-9100 William Ryan homes 948 N. Ylum Urove Road, Suite G Schaumburg, IL 60773 Jim Espersen 847-995-8700 Village of Hinckley 131 East Lincoln Avenue, P.O. Box ] 203 Hinckley, IL 60520 Steve Mathis 630-461-5530 Village of Streator 204 S. Bloomington Street Streator, IL 61364-0517 Paul Nicholson 815-672-2517 Del Webb Communities 1800 Factory Shop Blvd. Huntley, IL 60142 Bob Eck 847-669-77]2 Citizens Utilities Company of Illinois 1000 International Parkway Woodridge, IL 60517 Bob Khan 630-739-8827 Village of Carol Stream 124 Genzevske lane Carol Stream, IL 60188 John Turner 630-668-7050 DuPage County 421 Nonh County Farm Road Wheaton, Il, 60187-3978 Amy Beyer 630-682-7527 The Kirk Corporation 207 Juniper Circle Streamwood, IL 60107 I,on Marchel 847-669-6389 City of SL Charles 2 East Main Street St. Charles, II, (,0174 Cliff White 630-377.4400 Citizens Utilities Company of Illinois 1000 International Parkway Woodridge, 1L 60517 Barry Klepp 630-739-8827 City of North Chicago ]850 Lewis Avenue North Chicago, IL 60064 Bruce Burris 847-578-7780 Wing Point LLC 201 Juniper Circle Streamwood, II. 60107 I,on Marchel 847-669-6389 ARCHITECT lake County Central Services Dept 18 Noah County Street, 7th Floor Waukegan, 1I.60085-4350 Charles Degrave 847-680-1600 CONTRACT COMPLETION AMOUNT nTE $ 1,703,058.00 Oct-02 Greeley & }iansen Engineers $ 100 S. Wacker Drive Chicago, IL 60606 312-578-2409 Trotter & Assoc. Consulting Engineers $ 16 North First Avenue Sl. Charles, IL 60174 Scott Trotter 630-587-0470 Limech Engineering, I,LC $ 500 Coventry Lane, Suite 270 Crystal Lake, IL 60014 Jeremy I_in 815-479-5180 Limech Engineering, LLC $ 800 Coventry Iane, Suite 270 Crystal Lake, IL 60014 C.S. Lin 815-479-5180 Limech Engineering, LLC $ 500 Coventry Lane, Suite 270 Crystal Lake, IL 60014 C.S. Lin 815-479.5180 Baxter& Woodman $ 8678 Ridgefield Road Crystal Lake, IL 60012 C.S. Lin 815-489-1260 Applied Technologies $ 16815 W. Wisconsin Avenue Brookfield, Wf 53005 Frank Tiefen 262-784-7690 Limech Engineering, LLC $ 500 Coventry Iane, Suite 270 Crystal Lake, IL 600]4 C.S.Lin SIS-479-5180 Christopher B. Burke Engineering, Ltd. $ 9576 W. Higgins Road, Suite 600 Rosemon[,IL 60018 Mark Emory 630-572-1550 B&W Design/BuiId,LLC $ 800 Coventry Lane, Suite 270 Crystal Lake, II 60014 C.S. Lin 875-479-5180/5185 Robert H. Anderson & Associates $ 220 W. River Drive St. Charles, IL 60174 Anthony Malone 630-584-3530 B&W Design Build, LLC $ 800 Coventry Lane, Suite 270 Crystal Lake, IL 60014 Jeremy Lin 815-479-5180 McNamee Porter & Seeley, Inc. $ 3131 S. State Street Ann Arbor, MI 48108 734-665-6000 S&W Design/Build, LLC g 500 Coventry Lane, Suite 270 Crystal Lake, II 60014 Jeremy Lin 815-479-5180 7,888,476.00 Aug-02 488,099.00 Jul-02 806,306.00 Apr-02 777,667.00 Apr-02 814,600.00 Dec-Ol 4,823,960.00 Aug-O] 1,254,648.00 Aug-01 1,068,877.00 Aug-Ol 1,R72,7S9.00 Jun-O1 4,478,C,9G.00 tun-O] 6,483,134.00 May-O] 1,933,000.00 May-Ol 1,124,748.00 May-Ol 1,479,589.00 Apr-O] Joseph J. Henderson Son, Inc. Page 5 General Contractor Established 1628 Water & Wastewater Treatment Plant Projects Qualification Statement Item No. ] CONTRACT coMPLe"noN PROJECT ' ' OWNER ARCHITECT AMOUNT UATIi WAS1 I:WATFR IREATMENT PLANT Citizens Utilities Company of Illinois B&W Design Build, LLC $ 712 913 00 Mar-O] Citizens Odor Control Improve. Phase III 1000 International Parkway 500 Coventry Lane, Suite 270 , . Bolingbrook, Il. Woodridge, IL 60517 Ctysta] Lake, IL 60014 Barry Klepp 630-739-8827 Jeremy Lin 815-749-5180 WASTEWA"IER TREATMENT PLANT Village of Libertyville Rezek, Henry, Meisenheimer & Gende $ 1 290 730 00 Feb-01 Libertyville Wastewater Treatment Plant 118 West Cook Avenue 162 East Cook Avenue , , . Year 2000 Improvements Libertyville, IL 60048 Libertyville, IL 60048 1"ibertyville, IL Steven Magnusen 847-918-2000 William Rickert 847-362-5959 WEI,I. HOUSE Village of Volo Greenberg Farrow Architectural Engineer $ 804 592 00 llec-00 Volo Wellhouse 27273 Volo Village Road 3455 Salt Creek lane , . Volo, IL Volo, IL 60073 Arlington Heights, 1L Nancy Harbottle Don llixon 847-788-9200 WATIiR TRF.ATME3NT PLANT Citizens Utilities Company of Illinois B&W Design/Build, LI"C $ 1 467 806 (]0 Nov-00 Citizens Utilities -Oak Valley Water 1000 International Parkway 500 Coventry Lane, Suite 270 , , . Lockport, IL Woodridge, II. 60517 Ctysta] lake, IL fi0014 Bob Khan 630-739-8810 C.S. Lin 815-479-5180 WASTEWATER TREATMENT PLANT North Shore Sanitary Dist. Rust Environ. & Infrastructure $ 27,643,539.00 Sept-00 N.S.S.D. - STP Modifications & Box 750/Wm. Koepsel Dr. 4738 N. 40th Street Additions -Gurnee Plant Gurnee, IL 60031 Sheboygan, WI 53083 Gurnee, IL Brian Jensen 847-623-6060 414-458-8711 WASTEWATER TREATMENT PLANT City of Elmhurst B&W DesignBuild, LLC $ 991,020.00 Sept-00 Berkley & Adams / Harrison Storm Station 209 N. York Street 500 Coventry Lane, Suite 270 Improvements Project 99-14 D/B Elmhurst, IL 60126 Crystal Lake, IL 600]4 llmhurst, II. Dennis Stretcher 708-530-3020 Jeremy Lin 815-479-5180 WA'rP,R TREATMENT PLANT Citizens Utilities Company of Illinois Baxter & Woodman, I".L.C. $ ],334,232.00 Sept-00 Chickasaw Hills Water Reclamation 1000 Internationale Parkway 8678 Ridgefield Road Facility Improvements Excess Flow Woodridge, IL 60517 Crystal Lake, IL 600]2 Lockport,Il. Bob Khan 630-739-8810 C.S. Lin 815-459-1260 WAS"fEWATER TRLATMIiNT PLAN"f Cily of Elmhurst B&W Design/Build, L.L.C. $ 1,489,872.00 Sepl-00 Anaerobic lligester Modifications 209 N. York Street 500 Coventry lane, Ste. 270 Elmhurst, II. Elmhurst, iL 60126 Crystal Lake, II. 60014 Dennis Stretcher 708-530-3020 C.S. Lin 815-479-5180 WATER'IRF;ATMEN'F PLANT ~ City of Naperville Clark llietz $ 8,932,163.00 Sept-00 Springbrook Water Reclamation Expansion 400 S. Eagle Drive 1817 . Neil, Suite 100 18.75 to 22.50 MGD (Phase 2) Naperville, IL 60566-7020 Champaign, IL 61820 Naperville, IL Joe Renn 630-420-6122 Charlie Park 217-373-8900 WASTEWATER "I'REATMEN"I' P1.AN'r City of Elmhurst B&W Design/Build, LLC $ 512,000.00 Aug-00 Wastewater Treatment Plant Improvments 209 N. York Street 500 Coventry Lane, Suite 270 Sludge Handling Facility Improvements Elmhurst, IL 60126 Crystal Lake, IL 60014 tamhurst, (L Dennis Stretcher 708-530-3020 C.S. i_in 815.479-5180 WAS'1'}?~VA1'ER'FREATMENT PLANT Village of Carol Stream B&W Design/Build, LLC $ 1,425,085.00 Aug-00 Carol Stream Clarifier 124 Genzevske Lane 500 Covemry Lane, Suite 270 Carol Stream, IL Caro] Stream, IL 60188 Crystal Lake, II 60014 John Turner C.S. Lin R15-479-5180 WASTE- WATER 1'REA'FMENT PLAN"F Village of Fox River Grove B&W Design/Build, LLC $ 971,758.00 Aug-00 Fox River Grove -Solids Handling 408 Northwest Highway 500 Coventry Lane, Ste. 270 Fox River Grove, IL. Fox River Grove, II. 60021 Crystal Lake, IL 60014 Dan Hughes C.S. Lin 815-479-5180 WATER TREATMENT PLANT JRC Lakemoor Investments Eagle Environmental Company $ 1,236,953.00 Aug-00 Sullivan Lakes Potable Water System Limited Partnership / ]RC Devel. 251 Eas[ Dundee Road,lf9 Improvements Company, I.,L.C Wheeling, IL 60090 Iakemoor,ll- 919 North Michigan Avenue,#1500 Chicago,ll_ 60611 WAS"FEWA1'P.R TREATMENT PLANT' North Shore Sanitary Dist. Rust Environ. & Infrastructure $ 19,52A,405.00 Jul-00 N.S.S.D. -Sewage Tr. Plant Box 750/Wm. Koepsel Dr. 4738 N. 40th Street Improvements-Clavey Road Gurnee, IL 60031 Sheboygan, W! 53083 Highland Park, IL Brian Jensen 847-623-6060 414-458-8711 WAS"1'EWA'I'ER TREATMI;N'F PLANT North Shore Sanitary llistrict Donohoue & Associates $ t,317,852A0 May-99 UV Disinfection Facilities for the P.O. Box 750, W m. Koepsel Dr. 818 North 8th Street Noah Shore Sanitary District Gurnee, IL 60031 Sheboygan, WI 53081 Clavey S1'P/Gurnee STYlWkgn STY Brian Jensen 847-623-6060 920-208-0296 Page 6 Joseph J. Henderson Son, Inc. General Contractor Established 1928 Water & Wastewater Treatment Plant Proje Q lifi i cts ua cat on Statement Ilan No. 1 PROJECT OWNER WASTEWATER TREATMENT PLANT Island Lake Sanitary District Island Lake W WTP 420 Timber Trail Island lake, IL Island Lake, 11. 60042 Mark Higby 847-526-3300 RF;SL'RVOIR ' "fheLales Company Gregg s landing Potable Water 100 Lexington Dtive Ste 100 Storage Reservoir & Pump Station , . Buffalo Grove, 1L 60089 Vernon Hills, II- Gordon White 847-247-8503 WA"I'LR TRF;A'fMEN"f PLANT Del Webb Communities Huntley We11 No. 9 1800 Factory Shop Blvd. Huntley, IL Huntley, IL 60142 Bob Eck 847-699-7712 WAS'1'I:WATER TRI:ATMEN'f PLANT Fox Metro Water Rec District Aurora Wastewater Treatmem Plant . 682 Rt. 31 Aurora, IL Oswego, IL 60543 847-362-2430 WATER TREATMENT PLANT Village of Tower Lakes Tower Lakes Pumping Station 400 N. Route 59 & Reservoir ' ' Tower Lakes, II. 60010 l ower lakds, II_ 847-526-0488 WATER llIS'1'RIBU'f10N SYSTEM " Terra Coua Realty Company terra Coua Industries P.O. Box 477 Prairie Grove WeII NI Crystal Lake IL 60039-0477 1 Well house & Iron Removal , Kathy Martinez 815-459-2400 Prairie Grove, IL. WASTIiWA'f1iR "I'REA"1'MIiNT PLANT' Citizens Utilities Company o(IL Gravity Bch Thickener ]000 Internationale Parkway Ilolingbrook, IL Woodridge IL 60517 1 , 630-739-8810 WASTEWATER TREATMENT PLANT City of McHenry McHenry W WTP 333 S. Green Street B McHenry, IL McHenry, IL 60050-5495 8 C 815-363-2100 8 WASTEWATER TRI.iATMEN'f PLANT United Homes Brooks Farm Iron Removal Facility 2100 Golf Road Suite 110 Round lake, 11. , Rolling Meadows, IL 60008 9 V Alan Erikkson 847-427-2450 WASTIiWATERTREA'I'MF;NT PLANT Village of Libertyville Libertyville WW'fP - 11R W. Cook Avenue R Libertyville, IL I 'b t 'll WA'fI:R'fREATMENT PLANT' Armour Swift-Eckrich St. Charles, IL WASTEWATER TREATMENT PLANT Des Plaines Mobile Park W W'fP Des Plaines, II, W ASTI: W ATER 'f REATM F.N'I' PLANT' Final Clarifier Weir'frough Mod. Glen Ellyn, [L WAS'CEWA'fER TREA'fMEN'f PLANT Santa Pe Water Reclamation Woodridge, IL WATER 'CREATMENT PLANT Elgin Airlite WTP Lime Sludge Handling Facility F.Igin, IL _r er yvt e, IL 60048 847-362-2430 Armour Swift Eckrich Brown & Serve 3625 Illinois Avenue St. Charles, IL 60174 630-512-1000 Calvin Leung 1503 S. Coast llrive., Ste 211 Costa Mesa, CA 92626 Glenbard Wastewater Authority 21 W551 Bemis Road Glen Ellyn, IL 60137 Ycggy Orr630-790-1901 Citizens Utilities Co. of IL 1000 Internationale Parkway Woodridge, ll. 60517 Barry Klepp 630-739-8810 City of Flgin 150 Dexter Court Elgin, IL 60120-5555 Peter Bityou 847-931-5615 Page 7 ARCHITECT Baxter & Woodman 8678 Ridgefield Road Crystal Lake, II, 60012 Jeff Mholer 815-459-1260 Christopher B. Burke Engincer 9575 West Higgins Rd., Sre. 600 Rosemont, IL 60018 Mark Emory 847-823-0500 B&W Design/Build, L.L.C. 500 Coventry Lane, Ste. 270 Crystal Lake, II, 60014 C.S. I.in 815-479-5180 Walter E. Deuchler 230 S. Woodlawn Avenue Aurora, IL 60506 Bob Bauer 630.897-4651 W VP Corporation 2625 Butterfield Rd., Ste.301E Oak Brook, IL 60521-1920 630-574-7707 Yaul R. Glenn Architects, Inc. 0105 Alden Road Harvard,IL 60033 815-648-4657 Applied Technologies, Inc. 6815 West Wisconsin Ave. Brookfield, WI 53005 axter& Woodman 678 Ridgefield Road rystal Lake, IL 60012 15-459-1260 Manhard Consulting Engineers 00 Woodlands Parkway ernon Hills, II. 60061 Wally Stilz 847-634-5.550 ezek, Henry, Meisenheimer & Gende 2 F.. Cook Avenue bertyville, I1. 60048 7-362-5959 A Baxter & Woodman 8678 Ridgefield Road Crystal Lake, IL 60012 Jeremy Lin 815-459-1260 Baxter& Woodman 86778 Ridgefield Road Crystal Lake, IL 60012 Jeremy Lin 815-459-]260 Applied Technologies 16815 W. Wisconsin Ave. Brookfield, WI 53005 414-784-7690 Black & Veatch 8400 Ward Parkway Kansas City, MO 64114 John Pruss 913-339-2000 CONTRACT COMPLE"f]ON AMOUNT DATE $ 4,717,422.00 Dec-99 $ 1,126,307.00 Dec-99 ~ ],609,046.00 Jul-99 S 8,346,952.00 Sep-99 S 1,023,268.00 ]un-99 $ 458,618.00 Feb-99 $ 381,690.00 Oct-97 $ 3,174,366.00 Sep-98 $ 552,487.00 Apr-99 $ 1,049,964.00 Dec-98 S 386,573.00 Oc[-98 $ 389,425.00 Sep-98 ~ 186,662.00 Aug-9R $ 909,778.00 Aug-I8 $ 717,242.00 Aug-98 Joseph J. Henderson Son, Inc. General Contractor Establis hed 1928 Water & Wastewater Treatment Plant Projects Qualification Statement Item No. 1 PROJECT ' " " OWNER W AS f1iWA fl?R "1'RfiATMEN"1'PLAN7~ City of.Woodstock Woodstock W WTY F,xpansion 121 West Calhoun Street Woodstock, II. Woodstock, IL 60098 John Isbell R 15-338-43pp WASTEWATER TRFA1-MEN'I PLANT City of F,Imhurst McKinley Stormwater 209 N. York Street Elmhurst, 11- I'slmhurst, IL 60726 Dennis Streicher 847-530-3020 WAT1iR TREA"fMENI' PLANT Village of Cary Water System Improvements 25S Stonegate Well #4 Iron Removal facility Cary, IL 60013 Cary, IL 847-639-0003 WATER TREATMENT PLANT Burnside Construction Company Iakemoor Water Treatment Plant 2400 Wisconsin Avenue Iron Removal Facility Downers Grove, IL Iakemoor, 11' Joe Chiczewski 630-515-9999 WATER TREATMF.N"I' YLAN'1' Cambridge Homes Inc Southwind Water Treatment Plam , . 800 S. Milwaukee Ave. Suite 250 Barium Removal facility , Libertyville, IL 60(148 Iiuntlcy, IL John Scapin 847-362-7085 WASTEWATER TRHA'I'MIINT PIANT Wheaton Sanitary District Wastewater "I'r. Plant Slud ~ g~ 15649 Shaffner Road Storage Building Wheaton, IL 60189-0626 Wheaton,Il" 630-668-7515 WASTF.WATkiRTREA'PMFNTPL.AN"f Glenbard Wastewater Authority Glenbard W WTP Clarifier Trough 2] W551 Bemis Road Glen Ellyq IL Glen EIIyn,IL 60137 8 Peggy Orr630-790-1907 g WASTEWATERTRF..ATMEN'fPLANT CiryofJoliet Joliet Westside WWTP 150 W. Jefferson 7oliet, IL Joliet IL 60431 1 , Rich Clark 815-740-2372 C 2 WASTF.WA'FIiR TREATMENT PLANT Downers Grove Sanitary District Downers Grove Sanitary llistrict 2710 Curtiss Street B Wastewater Treatment Center llowners Grove IL 8 Improvements tixcess Flow T'r. , Ralph Smith 630-969-0664 C System 1996 8 Downers Grove, II. RESERVOIR Cambridge Homes C Brickton Place Stormwater Vault 800 S. Milwaukee Ave Suite 250 t York Ridge, IL ., Libertyville 11, 55 , Ban Stimac 847-362-7085 C WATER TREATMENT PLANT Village of Lake In The Ills Lake In The Hills Well No. 6 1115 Crystal Lake Road R Iron Removal Facility Lake In The Hills, IL 60102 IS Su Lake In The Hills, IL Dave Thoman 708-658-4213 Sc 84 PUMPING 59'ATION Village of Oswego Oswego Pumping Station I ] 3 S. Main Street W Oswego, 11, Oswego, IL 60543 24 llorothy Strong Au 63 PUMPING S'I'AT]ON City of Elmhurst Elmhurst Pump Station 209 N. York Road Ba Secondary EfOuem Elmhurst IL 60126 86 llmhurst, IL. , Dennis Streicher 847-530-3000 CrY 815 WASTEWATER TREA7-MEN'f PLANT Glenbard Wastewater Authority M Glenbard W WTY 21 W55] Bemis Road c Glen F,llyn, IL Glen Ellyn, IL 60137 137 Me 630-790-1907 414 PUMPING STATION Village of Addison Con Addison Pump Station 131 W. Lake Street 303 Addison, IL Addison, IL 60101 Chi 708-279-2140 B Page 8 ARCHITECT Baxter & Woodman 8678 Ridgefield Road Crystal Lake, ]L 60014 815-459-1260 Baxter & Woodman 8678 Ridgefield Road Crystal Lake, IL 60014 815-459-1260 Baxter& Woodman 8678 Ridgefield Road Crystal Lake, IL 60012 815-459-1260 Baxter& Woodman 8678 Ridgefield Road Crystal Lake, IL 60012 SIS-459-1260 Manhard Consultants 900 Woodland Parkway Vernon Hills, IL 60061 847-634-5550 axter & Woodman 8678 Ridgefield Road Crystal lake, II. 60012 815-459-1260 Baxter& Woodman 678 Ridgefield Road Crystal Lake, IL 60012 1S-4S9-1260 Clark Dietz, Inc. 817 Neil, Suite 100 hampaign,IL 61820 17-373-8900 axter & Woodman 678 Ridgefield Road rystal Lake, lI. 60012 15-459-1260 orba Group, Inc. 07 N. Cumberland Avenue hicago,IL 60656 Lori Summer 773-775-4009 ust Environmental O1 Woodfield Road ite 200 East haumburg,IL 60173 7-605-8800 alter E. Ducchler 0 S. Woodlawn Avenue rora,IL 60506 0-897-4651 xter& Woodman 78 Ridgefield Road stal Lake, IL 60012 -459-1260 Mahon Associates 7 Midway Road pasha, WI -739-0351 Boer Townsend Envir. E. Wacker Drive cago,IL 60601 938-0300 CONTRACT COMPLETION AMOUNT DATE S 5,020,779.00 Jul-98 $ 405,575.00 Jun-98 $ 761,794.00 Mar-98 $ 778,864.00 Jan-98 S 774,399.00 Jan-9R $ 541,206.00 Nov-97 $ 198,162.00 Oct-97 $ 414,214.00 Oct-97 $ 737,404.00 Oct-97 $ 1,034,800.00 Sep-97 $ 1,018,487.00 Sep-97 $ RI0,920.00 Jul-97 8 383,556.00 May-97 $ 3,300,420.00 Apr-97 $ 626,165.00 Mar-97 Joseph J. Henderson Son, Inc. General Contractor Established 1928 Water & Wastewater Treatment Plant Projects Qualification Statement Ilcm No. 1 PROJECT OWNER CONTRACT coMPLeT1oN PUMP ST'AT'ION City of Elmhurst ARCHITECT AMOUNT DATF. Randolph Bc West Station 209 N. York Road Harza Environmemal $ 4]8,118.00 Apr-97 Stormwater Pumping Improve. Elmhurst IL 60]26 233 S. Wacker Drive Phase II , 847-530-3000 Chicago, IL 60606 Elmhurst, IL 312-8313000 RESERVOIR 2.0 MG Freshwater Reservoir Village of Lincolnshire One Olde Hall Day Road Alvord, Burdick & Howson $ 1,253,922.00 Apr 97 Lincolnshire, IL Lincolnshire IL 60069 20 N. Wacker Drive , 847-883-8600 Suite 1401 Chicago, [L 60606 312-236-9147 WASTEWATER TREATMENT PLANT' Ciiy of Joliet Joliet F.astside W WTP - II 150 W. Jefferson Street Clark Dietz, Inc. $ 1,283,543.00 Mar-97 Joliet, IL 1817 S. Neil, Suite 100 ]oliet, 11. 60437-1 ]44 Champaign, II. 61820 815-740-2372 217-373-8900 WAS"fEWA'fER "fREAT'MENI'PI-ANT VillageotCarpenteraville Carpemcrsville W W'CP - ll 1200 L.W. Besinger llrive Strand Associates $ 419,189.00 Mar-97 Carpentersville, IL. Carpentersville IL 601]0 910 W. Wings Drive , Madison, WI 53715 847-426-3439 60R-281-4843 WASTTiWA'fER'1'RHA'CMEN'1' YL,ANT' Wheaton Sanitary District Wheaton Preliminary Improv. 1 S 649 Shaffner Road Baxter & Woodman $ 178,442.00 Jan-97 Whcaton,IL Wheaton IL 60189-0626 8678 Ridgefield Road , Crystal Lake, IL 60012 630-668-1515 815-489-1206 WAST'F,WATER TREATMENT PLANT Thorn Creek Basin Sanitary Dist Thorn Creek Bar Screens . 700 W. End Avenue Thorn Creek Basin Sanitar Dist. y $ 110,550.00 Jan-97 Chicago Fleights, IL Chicago Heights IL 60411 700 W. End Avenue , Chicago Heights, IL 60411 708-754-0525 708.754-0525 WATER TREATMENT PLANT Village of Glencoe Glencoe Water Filtration Plant 675 Village Court Village of Glencoe $ 186,369.00 Dec-96 Sand Filter Retrofit Glencoe IL 60022 678 Villa e Court g Glen Ellyn, 11, , 708-835-4]83 Glencoe, L 60D22 708-835-4183 WAST'IiWATBR 7RFA'fMEN-f PLANT City of SI. Charles St. Charles Odor Control 2 East Main Street Robert H. Anderson & Assoc. $ 210,170.00 Nov 96 St. Charles, 11. St. Charles IL 60174 220 W. River Drive , St. Charles, IL 60174 630-377-4400 708-584-3530 WASTiWAT'ER'fRl'A"CMEN'I'PLAN'f Village of West Dundee ' West llundee -Phase 2 102 S. Second Street Roy F . Weston $ 1,166,258.00 Nov-96 West Dundee, IL Wcst Dundee IL 60118 3 Hawthorn Parkway , 847-551-3800 Suite 400 Vernon HiIIs,IL 60061 847-918-4000 WASTEWATER TREATMENT PLANT' Wheaton Sanitary District Baxter & Woodman Wheaton Digester Control Bldg. P O Box 626 $ 1,580,567.00 Nov-96 Wheaton, IL . . Wheaton IL 60189 8678 Ridgefield Road , Crystal Lake, IL 60012 630-668-1515 815-459-1260 WASTEWATER TREATMENT' PLANT Village of Bartlett Pavia-Martin Co g Bartlett WWTP 233 Main Street . 910 Lake Street $ 8,612,300.00 Oct-9G Barlett, II. Banleu, IL 60103 Roselle, IL 60172 70R-837-OR00 70R-529-8000 WA'flsK "1T28AT'MEN'f PLANT City of Crystal Lake Baxter & Woodman Crystal lake Water'I'reatment k5 100 W. Municipal Complex 8678 Ridgefield Road $ 2,555,615.00 Sep-96 Iron & Barium Removal Facility Crystal Laku, IL 60014 Crystal Lake IL 60012 Crystal Lake, IL 815-459-2020 , 815-459-1260 'fREAT'MEN'f Pl-ANT' Ri Village of Riverwoods Donald Manhard $ verwoods Freshwater Pum Station P 300 S. Portwine Road 1,181,624.00 Aug-96 & Reservoir Riverwoods IL 60015 900 Woodland Parkway Riverwoods, IL , Vernon Hills, IL 60061 847-634-1300 WASTEWATER TREATMENT PLANT City of Joliet Joliet W WTP 150 W. Jefferson Street Clark Dietz, lnc. 1817 Neil Suite 100 $ 1,761,203.00 Aug-96 Joliet, IL Joliet, IL 60431-1144 , Champaign, IL 61820 815-740-2218 217-373-8900 WAS'I'IiWAT'ER TR}ATMIN'I PLANT North Shore Sanitary District North Shore Sanitar District y $ North Shore Sanitar District y P.O. Box 750; Russell Road P.O. Box 750; Russell Road 317,500.00 Sep-)6 Bar Screen Replacement Phase 2 Gurnee, IL 6003] Gurnee IL 60031 Waukegan, (L 847-G23-6060 , 847-623-6060 Joseph J, Henderson Son, Inc. peso y General Contractor Established 1928 Water & Wastewater Treatment Plant Projects Qualification Statement Item No. 1 PROJECT OWNER KESF:RVOIR City of Elgin Slade Avenue 1.5 MG Freshwater 150 Dexter Court Reservoir Facility Elgin, IL 60120 Elgin, IL 847-931-6100 WA51'EWATER TREATMENT PLANT Terrestris Development Co. Fox River Grove Iron Removal Fac. 1301 W. 22nd Street Fox River Urove,[I. Oakbrook, IL 60521 708-573-0460 WASTEWA"CF;R TREATMF-,NT YL.ANT Village of Carpemersville Belt Filter Press 1200 L.W. Beringer Carpentersville, IL Carpentersville, 11. 60010 847-426-3439 PUBLIC WORKS FACILITY Village of West Dundee West Dundee W'I'P 102 S. Second Street Barium Removal Facility Wesl Dundee, II. 60118 West Dundee, IL 847-551-3800 WATER "CREATMF.N"f PLANT City of Naperville Springbrook Water Rec. 400 S. Eagle Naperville, IL Naperville, IL 60566 708-420-6064 WATER TREATMENT PLANT Hinsdale Sanitary District Hinsdale Treatment Plant 6975 Commonwealth Hinsdale, IL Hinsdale; IL. 60522 708-323-3299 WATER TREATMENT PLANT Village of BartleU Bartlett Well 7 & 2 Iron Removal Facility 233 Main Street Bartlett, 11. Bartlett, IL 60103 70R-837-0800 WA"rER'PREATMIiNT PLANT Village of Northbrook Northbrook Freshwater Treatment Plant 1225 Cedar lane Northbrook, 11, Northbrook, IL 60062 847-272-4711 WASTEWATER TREATMENT PLANT N. Shore Sanitary District N. Shore Sanitary Bar Screen P.O. Box 750; Russell Road Aurora, IL Gurnee, IL 60031 847-623-6060 WASTEWATER TRFA'I MFNT PLANT Aurora Sanitary District Rehabilitation of TDF's k2-8 682 Route 31 Aurora, IL Aurora, 1L 60543 RESERVOIR Village of Rosemont William Street 5 MG Freshwater Pump 9501 West Devon Station & Reservoir Rosemont, IL 60018 Rosemont, Il. WAS'PEWATER'1RL'ATMENTPLAN"1' Wheaton Sanitary District Wheaton WWTP 1 5.649 Shaffner Wheaton,IL Wheaton, IL 60189 708-668-1515 TREATMENT PLANT DuPage County Knollwood Treatment Plant 421 County Farm Road Wheaton, IL Wheaton, IL 60187 708-682-7000 WASTF,WATF.R TREA'FMEN'L PLANT' Village of Lake in the Hills Lake in the Bills Public Works 1115 Crystal Lake Road Lake in the hills, IL Lake in the Hills, IL 60102 708-658-4213 WASTI:WA'1'ER 7Bk:ATMEN"f PLANT North Shore Sanitary Dist. Waukegan WWTP P.O. Box 750; Russell Road Waukegan,IL Gurnee, IL 60031 847-623-6060 ARCHITECT Clark Dietz, Inc. 1817 S. Neil, Ste. 100 Champaign, IL 61820 217-373-8900 Baxter & Woodman 8678 Ridgefield Road Crystal Lake, IL 60012 815-459-1260 Baxter & Woodman 8678 Ridgefield Road Crystal Lake, IL 60012 815-459-1260 Rust Environmental 1501 Woodfield Road Suite 200E Schaumburg,lL 60173 708-605-8800 Clark Dietz, Inc. 1817 S. Neil Suite 100 Champaign, IL 61820 217-373-8900 Greeley & Hansen 100 S. Wacker Dr, Ste 1400 Chicago, IL 60606 312-558-9000 Pavia-Marring Co. 910Iake Street Roselle, IL 60172 708-529-8000 Harza Environmental Serv. Seats "Cower 233 S. Wacker llr., Ste 800 Chicago, IL 60606 312-831-3000 N. Shore Sanitary District P.O. Box 750; Russell Road Gurnee, IL 60031 847-623-6060 Aurora Sanitary District 682 Route 31 Aurora, II, 60543 Christopher B. Burke 10275 W. Higgins Road Suite 460 Rosemont, IL 60018 847-823-0500 Baxter& Woodman 8678 Ridgefield Road Crystal lake, IL 60012 815-459-1260 DuPage County 421 County Farm Road Wheaton, IL 60187 708-682-7000 1. Michael Delapp 266 W. Lake Shore Drive Barrington,iL 60010 708-526-5429 Rust Environmental 4728 N. 40th Street Sheboygan, W153083 414-458-8711 CONTRACT coMPLE'HON AMOUNT DnTF $ 1,504,748.00 Jul-96 $ 1,451,650.00 Jun-96 $ 419,189.00 Jun-96 $ 3,878,001.00 May-96 $ 2,215,456.00 Mar-96 $ 402,882.00 Feb-96 $ 553,378.00 Jun-95 $ 9,196,778.00 Aug-95 $ 313,700.00 Aug-95 $ 198,600.00 Sep-95 $ 4,907,693.00 Aug-95 $ 745,579.00 Aug-95 $ 9,247,044.00 Aug-95 $ 1,121,146.00 Jun-95 $ 253,700.00 Mar-95 Joseph J. Henderson Son, Inc. General Contractor Page 10 Established 1928 Water & Wastewater Treatment Plant Projects Qualification Statement ltem No. 1 PROJECT OWNER ARCHITECT WASTEWATER TREATMFNT PLANT Village of LakeZ,urich Lake Zurich Transfer Facility 70 Fast Plain S[reet Rezek, Henry, Meisenheimer, Lake`Lurich,IL [akeLurich,IL 60047 & Gende 162 E. Cook Avenue Libertyville. IL 60048 708-362-5959 WAS'I'EWA'I'ISR "IRF.ATMI?N"I' I'I,AN'l~ Village of Carol Stream Carol Stream W WRC 500 N Cedar Baxter & Woodman Carol Stream, IL . Carol Stream IL 60788 8678 Ridgefield Road , Crystal take, IL 60012 708-665-7050 815-459-1260 PUMP STATION City of Elmhurst ('lark Dietz Utley & Jackson Pump Station 209 N York Street Elmhurst, II, . Elmhurst IL 60126 1817 S. Neil , 847-530-3023 Suite ]00 Champaign, IL 61520 217-373-8900 WAS'1'EWATIR TREA"IMENT PLANT' Village of Bloomingdale Bloomingdale W WTP 201 S. Bloomingdale Road Baxter & Woodman Bloomingdale, IL Bloomingdale IL 60108 8678 Ridgefield Road , Crystal Lake, 1L 60012 708-893-7000 815-459-1260 WASTEWATER TREATMENT PLANT Village of Addison Excess Flow Clarifier 131 W. Lake Street Clark Dietz Addison, II. Addison IL 60101 1817 S. Neil , 708-543-4100 Suite 100 Champaign, IL 61820 217-373-8900 WASTI?WATER TRLiA1'MI:N"I' PLANT Abbott Laboratories Abbott X-9 W WTP 1401 Sheridan Road Abbott Laboratories North Chicago, IL. North Chicago ]l. 60064 1401 Sheridan Road , North Chicago. IL 60064 847-937-1502 847-937-1502 WAS1'IWAT1iR TREA"fMEN1' PLANT Yorkville-Bristol Sanitary Walter E Deuchler Yorkville W WTP Yorkville IL 304 S. River Street . 230 Woodlawn Avenue , Yorkville, IL 60560 Aurora, IL 60506 708-897-4651 ADDITION Sand Filter Building Downers Grove Sanitary Dist. Bax[er & Woodman Downers Grove W WTP 2710 Curtiss Downers Grove IL 60515 8678 Ridgefield Road Downers Grove, IL , 708-969-0664 Crystal Lake, [L 60012 815-459-1260 WASTIiWA1l?R'FREA'I'MEN"f PLANT City of Elgin Elgin W WTP Addition P.O Box 92 Donohue & Assoc. Elgin, 11, . Elgin IL. 60121 4738 N. 40th Street , Sheboygan, Wl 53083 847-931-5615 414-271-4700 PUMPING STATION Village of Grayslake Midwest Consulting Eng Grayslake Pumping Station & Reservoir (new) 164 Hawley Street . 5151 N Harlem Avenue Grayslake, Il. Grayslake, IL 60030 . Chicago, IL 60656 847-223-8515 312-792-]100 PUMPING STATION Village of Gurnee Baxter & Woodman Gurnee Pump Station & Reservoir 4573 Grand Avenue 8678 Ridgefield Road Gurnee, IL Gurnee, IL 60031 Crystal Lake, IL 60012 847-623-7658 815-4'59-1260 WASTEWATER TREATMENT PLANT Village of Fox Lake Donohue & Associates Fox Lake W WTP 301 Route 59 4738 N 40th Stree[ Fox Lake, IL Fox Lake, IL 60020 . Sheboygan, WI 53083 414-271-4700 WASTEWA'FER'LRF:A1'MEN"F PLANT Gillette Chemical Baxter & Woodman Gillette Chemical W W1'P 3500 W. 16th S[reet 8678 Ridgefield Road North Chicago, IL North Chicago, IL 60064 Crystal Lake, IL 60014 815-459-1260 NF.W CONSTRUCTION U.S. Army Eng. Dist Corps of Eng. U.S. Army Eng. Dist. Corps of Eng Reservoir 29A Chicago, Il. . Chicago, IL Lake Cook Road WAST1iWA'I'1;R 7R}iATMINT PLANT City of Elmhurst R7N Environmental Assoc Wastewater Tr. Plant Improvements 119 Schiller Street . 202 W. Front Street Elmhurst, 11. Elmhurst, IL 60126 Wheaton, IL 60187 708-530-3020 708-682-4777 Page 11 CONTRACT COMPLETION AMOUNT DA E $ 2,616,039.00 Jan-95 $ 10,146,121.00 Jan-95 $ 807,042.00 Jan-9S $ 1,843,262.00 Nov-94 $ 196,581.00 Oct-94 $ 785,046.00 Aug-94 F 3,224,006.00 llec-93 $ 1,287,420.00 Jul-93 $ 6,738,3]7.00 Mac-93 $ 3,372,667.00 Dec-92 $ 1,900,843.00 Dec-92 $ 22,516,914.00 Aug-92 $ 1,646,]52.00 Jun-92 $ 845,225A0 Jun-92 $ 15,294,254.00 Feb-92 Joseph J. Henderson Son, Inc. General Contractor Established 1928 Water & Wastewater Treatment Plant Projects Qualification Statement Item No. 1 PROJECT OWNER 'I'KEATMEN'1' PLANT Village of Addison Water Transmission System 131 W. lake Street Pressure Reducing Station Addison, IL. 6010] Addison, IL WAS"I'1iWATER TREA"CMENT PLANT Downers Grove Sanitary 1988 -Improvements 2710 Curtiss Street Downers Grove, IL Downers Grove, IL 60515 WAS"CP.WATER'I'RIATMEN'I' PLANT' Village of Plainfield Plainfield W WTP 1400 N. Division Street Plainfield, ll. Plaintield,IL 815-436-3577 WASTEWATER TREATMENT PLANT North Shore Sanitary District N.S.S.D. P.O. Box 750; Russell Road Gurnee, IL Gurnee, IL 60031 708-623-6060 WAS'CEWATER 'fR1;A'PMIiNT PLANT Noah Shore Sanitary District Dahringer Road N.O. Box 750; Russell Road Waukegan,ll. Gurnee, IL 60031 708-623-6060 PUMP STATION City of I:Imhurst P,Imhurst Pump Station 119 Schiller Street Elmhurst, 11. C_Imhurst, IL 60126 WASTEWATER'CRF.A'1'MEN'I~ PLANT Downers Grove Sanitary 1984 -Phase II Improvements 2770 Curtiss Street llowners Grove, IL ~ Downers Grove, IL 60515 708-969-0664 RESERVOIR Village of Skokie Storm Sewer 5127 Oakton Skokie, II, Skokie, Il. METERING STATIONS Du Page County Water Comm. DuPage Water Commission 721 E. Madison Street Dupage County Villa Park, IL 60181 708-834-0100 'I'REATMF.N'I' CENTER IMPRV. North Shore Sanitary llistrict Belt Press Facility N.O. Box 750; Russell Road Waukegan,IL Gurnee, IL 60031 708-623-6060 WASTEWATER'I'RIiATM]iNT PLANT Village of Libertyville Libertyville W WTP 200 E. Cook Avenue Libertyville, IL Libertyville, IL 60048 708-362-2430 Page 12 ARCHITECT HNTB Engineers 11 I N. Canal Street, Ste. 880 Chicago,]L 60606 Baxter& Woodman 8678 Ridgefield Road (:rystal Lake, IL 60014 815-459-1260 Robert E. Hamilton 455 Ruby Street ]oliet, IL 60435 815-722-3444 Donohue & Associates 4738 N. 40th Street Sheboygan, WI 53083 414-271-4700 Donohue & Associates 4738 N. 40th Street Sheboygan, W153083 414-271-4700 RJN Environmental 202 W. front Street Wheaton, IL 60187 Baxter& Woodman 8678 Ridgefield Road Crystal Lake, IL 60012 815-459-1260 Donohue & Associates 4738 N. 40th Street Sheboygan, W153081 414-458-0537 Alvord, Burdick & Howson 20 N. Wacker, Ste ]401 Chicago, IL 60606 312-236-9147 Clark-Dietz,lnc. 18]7 S. Neil Street, Ste. 100 Champaign, IL 61820 217-373-8900 Rezek, Henry, Meisenheimer & Gende 162 E. Cook Avenue Libertyville, [L 60048 708-362-5959 CONTRACT COMPLETION AMOUNT DA7 E $ 978,000.00 Jan-92 $ 4,300,858.00 Aug-9] $ 1,521,278.00 Jun-9] $ 10,416,724.00 May-91 $ 1,515,500.00 May-9] $ 2,106,666.00 Apr-91 $ 1Q711,453.00 Oct-90 $ 525,000.00 Aug-90 $ 8,027,160.00 Mar-90 $ ],534,288.00 Aug-90 $ 2,379,530.00 Mar-90 Joseph J. Henderson Son, Inc. General Contractor Established 7928