Loading...
HomeMy WebLinkAboutRFQ - Sourdough Water Treatment Facility Plan and South Pressure Zone Study REQUEST FOR QUALIFICATIONS SOURDOUGH WATER TREATMENT FACILITY PLAN AND SOUTH PRESSURE ZONE STUDY CITY OF BOZEMAN PO Box 1230 Bozeman, MT 59771-1230 MARCH 2024 NOTICE IS HEREBY given that The City of Bozeman (City), through this Request for Qualifications (RFQ), is seeking to procure an engineering firm (Respondent) for two studies performed under a single contract. 1) The Sourdough Water Treatment Facility Plan focused on the City’s Sourdough Water Treatment Plant (WTP) as well as raw and treated water transmission and storage facilities delivering the City’s Sourdough and Hyalite water supply. The facility plan will identify hydraulic capital improvements, process optimization strategies, and long-range approaches to ensure compliance with the State of Montana Department of Environmental Quality (DEQ) while maintaining the award-winning potable water the community of Bozeman expects as the City continues to grow over the next 20 years. 2) The South Pressure Zone Study will evaluate a pressure zone that must be established to serve future developments to the south of the existing southern extents of the City’s potable distribution system. The purpose of the study project is to evaluate pressure zone alternatives and select a preferred alternative for detailed design and eventual construction. Copies of the Request for Qualifications (RFQ) are available on the City’s website. All responses to this RFQ must be provided as a single, searchable PDF document file and be submitted digitally as an email attachment to the submission email address below by the deadline indicated in this notice. Respondents are advised that the email attachment size limit is 25MB and that only one PDF file will be allowed per response. The subject line of the submission email shall clearly identify the RFQ title, company name, and due date/time. File sizes greater than 25MB in size may be uploaded to the City Clerks’ Office upon special arrangement with the City Clerk. If this arrangement is made, it is sole responsibility of the Respondent to ensure the file upload is completed, and that the City Clerk is separately notified via email of the completed transmittal, prior to the deadline given in this notice. The deadline for submission of responses to this RFQ is Friday, April 19th , 2024 at 2:00 pm local time. It is the responsibility of the Respondent to ensure its submission is received by the City Clerk prior to this deadline. Late submittals will not be accepted. The email address for submission is: agenda@bozeman.net NON-DISCRIMINATION AND EQUAL PAY The City of Bozeman is an Equal Opportunity Employer. Discrimination in the performance of any agreement awarded under this RFQ on the basis of race, color, religion, creed, sex, age, marital status, national origin, or actual or perceived sexual orientation, gender identity or disability is prohibited. This prohibition shall apply to the hiring and treatment of the awarded entity’s employees and to all subcontracts. As such, each entity submitting under this notice shall include a provision wherein the submitting entity, or entities, affirms in writing it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, gender identity or disability and which also recognizes the eventual contract will contain a provision prohibiting discrimination as described above and that this prohibition on discrimination shall apply to the hiring and treatment of the submitting entity’s employees and to all subcontracts. In addition, pursuant to City Commission Resolution 5169, the entity awarded a contract under this RFQ and any subcontractors must abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and affirm it will abide by the above and that it has visited the State of Montana Equal Pay for Equal Work “best practices” website, or equivalent “best practices publication and has read the material. Failure to comply with the above may be cause for the City to deem the submission non- responsive and disqualify the Respondent from award. Administrative questions regarding submittal procedures may be directed to: Mike Maas, City Clerk (406) 582-2321, agenda@bozeman.net. Technical questions regarding the Sourdough Water Treatment Facility Plan or South Pressure Zone Study may be directed to: Griffin Nielsen, PE, Water Resources Engineer, (406) 582-2279, gnielsen@bozeman.net. DATED at Bozeman, Montana, this 30th day of March, 2024. Mike Maas City Clerk City of Bozeman For publication on: Saturday, March 30th, 2024 Saturday, April 6th, 2024 Saturday, April 13th, 2024 I. Introduction The City of Bozeman (City), through this Request for Qualifications (RFQ), is seeking to procure an engineering firm (Respondent) for two studies performed under a single contract. 1) The Sourdough Water Treatment Facility Plan focused on the City’s Sourdough Water Treatment Plant (WTP) as well as raw and treated water transmission and storage facilities delivering the City’s Sourdough and Hyalite water supply. The facility plan will identify hydraulic capital improvements, process optimization strategies, and long-range approaches to ensure compliance with the State of Montana Department of Environmental Quality (DEQ) while maintaining the award-winning potable water the community of Bozeman expects as the City continues to grow over the next 20 years. 2) The South Pressure Zone Study will evaluate a pressure zone that must be established to serve future developments to the south of the existing southern extents of the City’s potable distribution system. The purpose of the study project is to evaluate pressure zone alternatives and select a preferred alternative for detailed design and eventual construction. The City intends to negotiate a professional services agreement contract (PSA) with the Respondent it determines to be most-qualified upon review of all submissions to this RFQ. Respondents are notified that the final form of the PSA contract must be substantially similar to the template PSA attached to this RFQ. Project-specific modifications to the PSA may be allowed for Article 1 through Article 8 to reflect the negotiated scope, fee, and schedule. Modifications to Article 9 will not be considered during PSA negotiations. This RFQ shall not commit the City to enter into a PSA, to pay any expenses incurred in preparation of a submission prepared in response to this RFQ, or to procure or contract for any supplies, goods or services. The City reserves the right to accept or reject all responses received for this RFQ if it is in the City’s best interest to do so. This procurement is governed by the laws of the State of Montana and venue for all legal proceedings shall be in the 18th Judicial District Court, Gallatin County. By offering to perform services under this RFQ, all submitters agree to be bound by the laws of the State of Montana and of the City, including, but not limited to, equal opportunity employment practices, safety, non-discrimination & equal pay, etc. II. Project Background The City of Bozeman has been rapidly expanding both its corporate boundary and population in recent years. Analysis of population statistics compiled by U.S. Census Bureau over the 2018 – 2022 period indicates the City experienced a continuous annual growth rate of 3.45% – a staggering factor that has placed Bozeman near the top of growing communities in the United States of similar size. To support the rapid growth the City has been actively managing the expansion of its public water utility. With the City as a headwaters community located within a closed basin, the management and planning of the City’s water utility is critical for the long-term health and vitality of the community. Two such planning efforts have risen to the top of the list: The Sourdough Water Treatment Facility Plan and the South Pressure Zone Study. The facility plan for the City’s Sourdough membrane water treatment plant and transmission and storage facilities for the Sourdough and Hyalite water supply is needed to provide the roadmap for the City to plan for hydraulic and treatment capacity upgrades needed to meet the demands of the projected growth occurring in the City of Bozeman over the next 20 years. The City Sourdough WTP was completed in 2014 and is currently rated to treat up to 22 MGD max day and is operating at approximately 50% of its capacity, however, the facility will reach capacity in the next five to ten depending on the growth rate. The facility was designed to be expanded to 36 MGD as demands increase within the City, however, no comprehensive planning effort has been completed to guide expansion. The City’s 2017 Water Facility Plan Update (WFPU) identified and evaluated future pressure zones necessary to serve anticipated growth and development under full buildout conditions. The South Pressure Zone Study will evaluate a new pressure zone that must be established to serve future development south of the existing southern extents of the City’s potable distribution system. The South Pressure Zone Study will focus on the Water Treatment Plant Pressure Zone (approximately of HGL 5221), generally described as areas south of Blackwood Road on the west side of South 19th Ave and areas south of Goldenstein Lane on the east side of south 19th, as depicted in 2017 WFPU. The City has decided to procure and conduct these studies under a single contract partially for efficiency but primarily as the scope of the studies overlap and the pending recommendations will be better derived when the study efforts are completed in tandem. III. Scope of Services The scope of services for the Project is comprised of the major elements contained within this section. The City desires for the Project to be completed in a diligent manner. Upon the City’s selection of the Respondent it deems most-qualified, the final scope of services, fee and schedule will be negotiated within a PSA. The initial scope of services presented by the selected firm must generally include the scope of services provided in this section, further refined to reflect the detailed project approach and schedule as presented within the selected firm’s RFQ submission. Sourdough Water Treatment Facility Plan: The purpose of the Sourdough Water Treatment Facility Plan is to provide the City with a detailed plan that evaluates the existing and future facility needs while clearly identifying necessary capital improvements the City will need to make over the next 20 years to ensure the plant has adequate treatment and delivery capacity to meet future demands. Evaluations include but are not limited to plant capacity upgrades, capital replacement, site master planning, raw water and treated water transmission capacity and storage with specific consideration for instrumentation and controls, physical and IT security upgrades, solids residual dewatering, chlorine contact time (CT) optimization, plant metering, emergency operations plan during or after wildfire, membrane filter replacement schedule, staffing and laboratory needs, main electrical feed power quality analysis and improvement recommendations, alternative power generation feasibility include solar and micro-hydro and reevaluation of the future 36 MGD max day design capacity as the base of design. Furthermore, the study must ensure all City, State, and Federal requirements are satisfied. In addition, an analysis of conveyance and storage infrastructure will be required to address existing operational challenges at the WTP with the new 5.3 MG ground storage reservoir in operation as well as base planning for the Hyalite Equalization Storage, Sourdough Bi-Pass Flow Control Expansion, Nash Road Transmission Main Projects. The results of the study will result in a recommended capital improvement plan associated with the WTP facility providing the City with a time-based list of improvements necessary to meet the City’s existing and future needs. The capital improvement plan must include construction cost estimates along with estimated operation and maintenance (O& M) costs for the year of expenditure, including inflation. South Pressure Zone Study: The purpose of the South Pressure Zone study is to provide the City with a logical roadmap on the implementation and future development of the Water Treatment Plant pressure zone recognizing that the WFPU provides a long-term buildout picture and that the development and establishment of the Water Treatment Plant zone may need to be phased. Moreover, an analysis of alternatives may be necessary as part of the study, such as a regional booster pump station in the interim. The study must consider both existing (i.e. Sourdough Transmission Main) and future transmission assets (i.e. West Transmission Main), storage needs within the future zone and greater distribution system, storage operations, pressure facility locations (future pressure reducing valves), boarding pressure zones, and other critical components needed to satisfy future zone needs. Economic assessments related to system improvements will be required for each scenario considered. A preferred alternative(s) will be recommended.. The City’s Innovyze Infowater future system model will be updated to include the preferred alternative and an addendum will be issued for the City’s 2017 water facility plan to incorporate the pressure zone study. Furthermore, the study must ensure all City, State, and Federal requirements are satisfied. Though separate these study efforts may occur in tandem with the City update to the Integrated Water Resource Plan (IWRP). The scope of these study efforts will be distinct from the IWRP update however there are direct links between the two there which may entail working collaboratively with outside counsel and/or other consultant experts separately engaged in the IWRP Update planning exercise with the City. The City has a total budget of $450,000 to complete these study efforts for the Sourdough Water Treatment Facility Plan and South Pressure Zone Study. IV. RFQ Submittal Instructions & Timelines Respondents must provide submissions for this RFQ via email to the City Clerk at agenda@bozeman.net by Friday, April 19, 2024 at 2:00pm local time. Submissions must be provided as a single, searchable PDF document file as an email attachment. Respondents are advised that the email attachment size limit is 25MB and that only one PDF file will be allowed per response. The subject line of the submission email shall clearly identify the RFQ title, company name, and due date/time. File sizes greater than 25MB in size may be uploaded to the City Clerks’ Office upon special arrangement with the City Clerk. If this arrangement is made, it is sole responsibility of the Respondent to ensure the file upload is completed, and that the City Clerk is separately notified via email of the completed transmittal, prior to the deadline given in this notice. Late submittals will not be accepted. Contact Information for Questions Questions concerning this RFQ or Project shall be directed to the Project Manager or WTP Superintendent. Project Manager WTP Superintendent Griffin Nielsen, PE Jill Miller gnielsen@bozeman.net jmiller@bozeman.net 406-582-2279 406-994-0503 Timeline EVENT DATE RFQ Notice Dates Saturday, March 30th , 2024; Saturday, April 6th , 2024; Saturday, April 13th , 2024 RFQ Submittal Deadline Friday, April 19th, 2024 at 2:00pm local time Evaluation of proposals By April 30th ,2024 Interviews (At City’s discretion) May 3rd, 2024 Selection Decision On or before May 6th, 2024 Contract Negotiation May 7th, 2024, through June 19th 2024 Contract Authorization & Notice to Proceed On or before July, 1st 2024 Except for the RFQ notice dates and submittal deadline, the above RFQ timeline may be modified without notice by the City. V. Submission Contents and Format Respondent submissions to this RFQ must contain the information requested within this section and be formatted as described within this section. A. Submission Contents 1. Firm Background Provide general information about the firm, its history, strengths/weaknesses, and special capabilities that set the firm apart from its competitors. If the Respondent consists of a team of firms, provide the specific capabilities for each respective firm and the particular value that a team approach provides for successful delivery of the Project. 2. Project Overview and Understanding Provide a high level overview of the Project and the particular understanding of the purpose and need for the major elements described in the Scope of Services section of this RFQ. 3. Detailed Project Approach Describe the detailed approach to delivering the Project within a detailed scope of services. The submission should include specific scope items and identify milestones that are proposed to support the successful delivery of the major elements described in the Scope of Services section of this RFQ. If the Respondent is comprised of a team of engineering firms, the submission contents must clearly indicate which firm will be the prime firm for the PSA, and clearly distinguish the respective aspects of the detailed project approach each firm will be working on. 4. Proposed Project Schedule Prepare a project schedule consistent with the proposed detailed project approach. 5. Project Management and Staff Qualifications Describe the Respondent’s project manager and principal-in-charge and their particular qualifications along with their respective office locations. Describe the experience and qualifications of professional personnel to be assigned to the project and their particular role in delivering the scope of services described in the proposed detailed project approach. 6. Respondent’s Workload and Related Experience on Similar Projects Describe the Respondent’s recent or current work with the City, if any. Provide the status of current and anticipated workload and the Respondent’s capability to meet the proposed project schedule. Provide a description of not less than three projects of similar size and scope that the Respondent has successfully completed within the past 5 years. The project description shall include a brief overview, overall construction costs, overall engineering fees, and detailed contact information for the project owner. 7. Signed Nondiscrimination & Equal Pay Affirmation Form Provide a signed version of the Nondiscrimination & Equal Pay Affirmation Form attached to this RFQ. If the Respondent is a team of firms, a separate form shall be signed by an authorized representative from each firm. B. Submission Format 1. Submissions shall be provided as a single, searchable, PDF document file. 2. Submissions shall contain a cover letter signed by an officer or principal of the responding prime firm. 3. Submissions shall be a total of twenty (20) 8.5”x11” pages or less, with margins not smaller than 0.50”, and font not smaller than 11-point type. a. The following pages are exempted from the 20 page limit: Cover Page, Cover Letter, Table of Contents, Divider Pages, Personnel Resumes, and signed non- discrimination and equal pay affirmation form. b. A project schedule sheet is exempted from the 8.5”x11” page size limit, but is included in the 20 page submission limit. VI. Selection Criteria and Procedure Submissions will be evaluated on the criteria listed below. These are minimum criteria listed in Sec. 18-8-204 MCA as well as an additional criterion capturing the specific project approach and understanding. These criteria are not assigned point values for relative weighting in the evaluation and ranking process. A City selection committee consisting of at least five staff members will review and evaluate the submission as a whole to assign proposal rankings from most- to least-qualified. 1. The specific project approach and understanding; 2. Qualifications of professional personnel to be assigned to the project; 3. Capability to meet project time and budget requirements; 4. Location of the firm; 5. Present and projected workloads; 6. Related experience on similar projects; and 7. Recent and current work for the City. The Respondent whose submission is determined by the selection committee to be most- qualified will be selected to enter into contract negotiations with the City. The selection committee may choose to select multiple firms for contract negotiations of discrete scope elements if it believes the City will receive superior service and results compared to the selection of a single firm. Contract negotiations in the form a professional services agreement will proceed after selection and will take into account the estimated value of services to be rendered, as well as the scope, complexity, and professional nature thereof, in order to arrive at a contract the City determines to be fair and reasonable. If the City is unable to negotiate a satisfactory contract with the initially selected Respondent at a price it determines to be fair and reasonable, negotiations with that Respondent will be formally terminated. If this occurs, the City may initiate contract negotiations with the next most-qualified Respondent and continue until an agreement is reached or the procurement process under this RFQ is terminated. VII. Form of Professional Services Agreement Respondents are notified that the final form of the PSA contract must be substantially similar to the template PSA attached to this RFQ. Project-specific modifications to the PSA may be allowed for Article 1 through Article 8 to reflect the negotiated scope, fee, and schedule. Substantial modifications to Article 9 will not be considered during PSA negotiations. VIII. City Reservation of Rights All proposals submitted in response to this RFQ become the property of the City and public records and, as such, may be subject to public review. A SUBMISSION IN RESPONSE TO THIS REQUEST FOR QUALIFICATIONS CONFERS NO RIGHTS UPON ANY RESPONDENTS AND SHALL NOT OBLIGATE THE CITY IN ANY MANNER WHATSOEVER. THE CITY RESERVES THE RIGHT TO MAKE NO AWARD AND TO SOLICIT ADDITIONAL REQUEST FOR QUALIFICATIONS AT A LATER DATE. A. This RFQ may be canceled or any or all responses may be rejected in whole or in part, as specified herein, when it is in the best interests of the City. If the City cancels or revises this RFQ, all Respondents who submitted will be notified using email. B. The City reserves the right to accept or reject any and all submissions; to add or delete items and/or quantities; to amend the RFQ; to waive any minor irregularities, informalities, or failure to conform to the RFQ; to extend the deadline for submitting proposals; to postpone award for up to 60 days; to award one or more contracts, by item or task, or groups of items or tasks, if so provided in the RFQ and if multiple awards are determined by the City to be in the public interest. C. The City reserves the right to reject the submission of any person/firm who previously failed to perform properly to the satisfaction of the City, or complete on time agreements of similar nature, or to reject the submission of any person/firm who is not in a position to perform such an agreement satisfactorily as determined by the City. D. The City reserves the right to determine the best qualified Respondents and negotiate a final scope of service and cost, negotiate a contract with another Respondents if an agreement cannot be reached with the first selected Respondents, or reject all proposals. E. The successful Respondents will be required to enter into a contract with the City, which will incorporate the Respondents' scope of service and work schedule as part of the agreement. F. This RFQ does not commit the City to award a contract. The City assumes no liability or responsibility for costs incurred by Respondents in responding to this request for qualifications or request for interviews, additional data, or other information with respect to the selection process, prior to the issuance of an agreement, contract or purchase order. The Respondents, by submitting a response to this RFQ, waives all right to protest or seek any legal remedies whatsoever regarding any aspect of this RFQ. G. This project is subject to the availability of funds. IX. Miscellaneous A. No Oral Agreements. No conversations or oral agreements with any officer, employee, or agent of the City shall affect or modify any term of this solicitation. Oral communications or any written/email communication between any person and City officer, employee or agent shall not be considered binding. B. No Partnership/Business Organization. Nothing in this solicitation or in any subsequent agreement, or any other contract entered into as a result of this solicitation, shall constitute, create, give rise to or otherwise be recognized as a partnership or formal business organization of any kind between or among the respondent and the City. C. Employment Restriction and Indemnity. No person who is a City, officer, employee, contractor, or consultant of a respondent shall be an officer or employee of the City. No rights of the City’s retirement or personnel rules accrue to a respondent, its officers, employees, contractors, or consultants. Respondents shall have the responsibility of all salaries, wages, bonuses, retirement, withholdings, worker’s compensation and occupational disease compensation, insurance, unemployment compensation other benefits and taxes and premiums appurtenant thereto concerning its officers, employees, contractors, and consultants. Each Respondent shall save and hold the City harmless with respect to any and all claims for payment, compensation, salary, wages, bonuses, retirement, withholdings, worker’s compensation and occupational disease compensation, insurance, unemployment compensation other benefits and taxes and premiums in any way related to each respondent’s officers, employees, contractors and consultants. D. Accessibility. Upon reasonable notice, the City will provide assistance for those persons with sensory impairments. For further information please contact the ADA Coordinator Mike Gray at 406-582-3232 or the City’s TTY line at 406-582-2301. E. Procurement. When discrepancies occur between words and figures in this solicitation, the words shall govern. No responsibility shall attach to a City employee for the premature opening of an SOQ not properly addressed and identified in accordance with these documents. F. Governing Law. This solicitation and any disputes arising hereunder or under any future agreement shall be governed and construed and enforced in accordance with the laws of the State of Montana, without reference to principles of choice or conflicts of laws. X. Attachments 1. Nondiscrimination and Equal Pay Affirmation Form 2. Professional Services Agreement XI. Other Resources The following documents link are available for additional background. If there is trouble accessing the documents please email gnielsen@bozeman.net. 1. 2017 Water Facility Plan Update 2. Hyalite/Sourdough WTP Preliminary Design Report **END OF RFQ EXCEPT FOR ATTACHMENTS** ATTACHMENT 1 NONDISCRIMINATION AND EQUAL PAY AFFIRMATION FORM Attachment 1 NONDISCRIMINATION AND EQUAL PAY AFFIRMATION ____________________________________(name of entity submitting) hereby affirms it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, gender identity or disability and acknowledges and understands the eventual contract will contain a provision prohibiting discrimination as described above and this prohibition on discrimination shall apply to the hiring and treatments or proposer’s employees and to all subcontracts. In addition, ____________________________________(name of entity submitting) hereby affirms it will abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and has visited the State of Montana Equal Pay for Equal Work “best practices” website, or equivalent “best practices publication and has read the material. ______________________________________ Name and title of person authorized to sign on behalf of submitter ATTACHMENT 2 PROFESSIONAL SERVICES AGREEMENT 1 PROFESSIONAL SERVICES AGREEMENT THIS IS AN AGREEMENT made as of , between THE CITY OF BOZEMAN, a self-governing municipal corporation organized and existing under its Charter and the laws of the State of Montana, 121 N. Rouse Ave., Bozeman, Montana, 59771 (OWNER) and , Montana, (ENGINEER). Whereas the accomplishment of the work and services described in this Agreement is essential to the OWNER'S public works improvement program. Whereas the OWNER intends to and has selected the ENGINEER to provide necessary and professional engineering services for the project. Whereas the ENGINEER represents that it is willing and qualified to perform the professional engineering services for this project described in this Agreement. Therefore, in consideration of the foregoing recitals and the mutual covenants and conditions contained herein, the parties agree as follows: ARTICLE 1 - ENGINEERING SERVICES 1.1. The detailed description of the specific project components is described as follows: (Insert detailed project description) 1.2. The scope of services under this contract is set forth in this Agreement and the attached EXHIBITS. ARTICLE 2 - ENGINEER'S RESPONSIBILITIES 2.1. ENGINEER shall perform for OWNER professional engineering services in all phases of the Project to which this Agreement applies as hereinafter provided. These services will include, but not be limited to, serving as OWNER's professional engineering representative for the Project, providing professional engineering consultation and advice and furnishing customary civil and structural engineering services incidental thereto. 2.2. The ENGINEER shall furnish all labor, materials, equipment, supplies, and incidentals necessary to conduct and complete the ENGINEER'S portions of the Project and to prepare and deliver to the OWNER all data, reports, plans, specifications, and recommendations as designated herein. 2.3. The ENGINEER shall ascertain such information as may have a bearing on the work from local units of government, public, and private organizations and shall be authorized to procure information from other authorities as to the extent of these contacts and the results thereof. 2.4. The ENGINEER'S work shall be in accordance with the standards of sound engineering practices. 2.5. The ENGINEER shall name a Principal-In-Charge for the duration of the project. The Principal-In-Charge shall be . 2.6. The ENGINEER shall name a Project Manager who shall be the liaison between the ENGINEER and the OWNER. The Project Manager shall be . The OWNER may name a Task Director who would be the liaison between the ENGINEER and the OWNER during the design segment of the Project. 2.7. The ENGINEER shall submit an estimated progress schedule at the beginning of the work, and monthly progress reports thereafter until the project is completed. 2 ARTICLE 3 - OWNER'S RESPONSIBILITIES 3.1 The OWNER shall name a Task Director who shall be the liaison between the ENGINEER and the OWNER during DESIGN segment of the Project. The Task Director designated shall be . 3.2 The OWNER shall have the right of review and examination of the ENGINEER'S work at all times. 3.3 The OWNER shall make available all records (record drawings, construction records, etc.) indicating the existing configuration of the city utilities. 3.4 The OWNER will be responsible for advertising bid openings. 3.5 The OWNER shall attend the pre-bid conferences, bid openings, pre-construction conferences, construction progress and other job related meetings, substantial completion inspections and final payment inspections. ARTICLE 4 - BASIC ENGINEERING SERVICES The ENGINEER shall render professional Engineering Services as follows: 4.1 PRE-DESIGN INVESTIGATION PHASE After written authorization to proceed, ENGINEER shall: 4.1.1 Consult with OWNER to clarify and define OWNER's requirements for the Project and review available data. 4.1.2 Advise OWNER as to the necessity of OWNER's providing or obtaining from others, data or services and assist OWNER in obtaining such data or services. 4.1.3 Identify and analyze requirements of governmental authorities having jurisdiction to approve the design of the Project and participate in consultations with such authorities. 4.1.4. Provide analyses of OWNER's needs, planning surveys, site evaluations and comparative studies of prospective sites and solutions. 4.1.5. Provide a general economic analysis of OWNER's requirements applicable to various alternatives. 4.1.6 Assist in formation of Special Improvement Districts (SID) by preparing district boundary descriptions and maps, preparing a property owner's and assessments role lists including project assessment costs based on the preliminary project cost estimates, and providing technical information at SID public hearings, if applicable. 4.1.7. Prepare a Report containing schematic layouts, sketches and conceptual design criteria with appropriate exhibits to indicate clearly the considerations involved (including applicable requirements of governmental authorities having jurisdiction as aforesaid) and the alternative solutions available to OWNER and setting forth ENGINEER's findings and recommendations. This Report will be accompanied by ENGINEER's opinion of probable costs for the Project, including the following which will be separately itemized: Construction Cost, allowance for engineering costs and contingencies, and (on the basis of information furnished by OWNER) allowances for such other items as charges of all other professionals and consultants, for the cost of land and rights-of-way, for compensation for or damages to properties, for interest and financing charges and for other services to be provided by others for Owner. The total of all such costs, allowance, etc. are hereinafter called "Total Project Costs". 4.1.8. Furnish copies and an electronic copy of the Study and Report documents and review them in person with OWNER. 3 The Pre-design Investigation Phase will be completed and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.2 PRELIMINARY DESIGN PHASE After acceptance of the pre-design report and receipt of written authorization to proceed with the Preliminary Design Phase, ENGINEER shall: 4.2.1. In consultation with OWNER determine general scope, extent and character of the Project. 4.2.2. ENGINEER shall then prepare a Preliminary Design Report, preliminary plans and specifications and a written description for the Project. 4.2.3. Preliminary Design Report: Specific items to be addressed in the design report will include, but not be limited to: 4.2.3.1. Summary of construction requirements with appropriate drawings for each task included in the project. 4.2.3.2. Plans for providing water and sewer services for affected properties during construction. 4.2.3.3. Summary geotechnical report for specific tasks, if needed. 4.2.3.4. Special design considerations for Project tasks with conditions not covered in standard construction methods or specifications. 4.2.3.5. A traffic control plan for each project task, if necessary. 4.2.4. Design and Construction Survey: The ENGINEER shall conduct a design field survey of the project areas, as necessary, for locating existing utilities (such as gas, power, telephone, TV cables, water and sewer lines, irrigation facilities, fences, and approach driveways), existing right-of-way and easements, and making measured drawings of or investigating conditions of existing facilities. The ENGINEER shall provide suitable horizontal and vertical reference control points for the construction phase. 4.2.5. Permits and Rights-of-Way: The ENGINEER shall obtain approved permits, licenses, and/or easement agreements from private landowners and any other agencies or entities requiring similar approvals prior to bidding. These approvals will be coordinated with the OWNER and will be made on easement and permit documents approved by the OWNER. Information and easement descriptions provided in the Basic Engineering Services will be based on data available from design surveys and courthouse records. 4.2.6. Geotechnical Explorations and Analysis: The ENGINEER shall conduct such geotechnical explorations and analysis as necessary for project design and bidding. A geotechnical report will be prepared with recommendations relating to conditions pertinent to the design and construction of the Project. Subsurface information will be obtained by reviewing any existing geotechnical data available and using additional backhoe test pits and soil borings as necessary. The ENGINEER shall furnish copies of a geotechnical report as requested to OWNER for use by OWNER and Contractors, and review the results of the report with Contractors in a pre-bid meeting. The report is to be prepared for design purposes; ENGINEER will not be responsible if it is used by others for other purposes. 4.2.7. Preliminary Plans and Specifications. Prepare preliminary construction plans and specifications with information which addresses the special features of each project task. 4 4.2.8. Based on the information contained in the preliminary design documents, ENGINEER will submit a revised opinion of probable Total Project Costs to the OWNER. 4.2.9. ENGINEER shall prepare and furnish complete paper and electronic copies of preliminary bidding documents and design report as requested to OWNER and at the same time furnish copies as directed by OWNER to agencies and/or parties having regulatory responsibilities or direct financial participation in any part of the Project; provide any technical criteria, written descriptions and design data necessary for securing permits or approval from authorities having jurisdiction to review and approve the design, and assist owner in securing such approvals; and review documents in person with OWNER and review authorities, and, if necessary, conduct a plan-in-hand site review. All changes agreed to between ENGINEER and OWNER will be noted in a memorandum from the ENGINEER to the OWNER and incorporated into the final plans and specifications. The Preliminary Design Phase will be completed and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.3 FINAL DESIGN PHASE After written authorization to proceed with the Final Design Phase, ENGINEER shall: 4.3.1. On the basis of the accepted Preliminary Design documents and the revised opinion of probable Total Project Costs, prepare for incorporation in the Contract Documents final drawings and Technical Specifications of sufficient detail to show the general scope, extent and detailed character of the work to be furnished and performed by the Contractor(s) suitable for use in the project bidding and construction. 4.3.2. Advise OWNER of any adjustments to the latest opinion of probable Total Project Costs caused by changes in general scope, extent or character or design requirements of the Project or Construction Costs. Furnish to OWNER a revised opinion of probable Total Project Costs based on the Drawings and Specifications. 4.3.3. Prepare for review and approval by OWNER, its legal counsel and other advisors, contract agreement forms, general conditions and supplementary conditions, and (where appropriate) bid forms, invitations to bid and instructions to bidders, special provisions, technical specifications, and standard drawings, and other related contract documents in conformance with the latest edition of the Montana Public Works Standard Specifications (MPWSS) and City of Bozeman Modifications to MPWSS adopted by the City of Bozeman. 4.3.4. Furnish OWNER six copies and an electronic copy of the Contract Documents (including design drawings, specifications and contracts). The Final Phase will be complete and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.4 BIDDING OR NEGOTIATING PHASE After written authorization to proceed with the Bidding or Negotiating Phase, ENGINEER shall: 4.4.1. Assist OWNER in advertising for and obtaining bids or negotiating proposals for construction contract(s) and record prospective bidders to whom Bidding Documents have been issued, receive and process deposits for Bidding Documents and conduct pre-bid conferences. 4.4.2. Provide interpretation or clarification to prospective bidders regarding the Bidding Documents, and issue addenda as appropriate. 4.4.3. Consult with and advise OWNER as to the acceptability of the prime contractor, subcontractors, suppliers and other persons and organizations proposed by the prime contractor(s) (herein call "Contractor(s)") for those portions of the work as to which such acceptability is required by the Bidding Documents. 5 4.4.4. Consult with OWNER concerning and determine the acceptability of substitute materials and equipment proposed by Contractor(s) when substitution prior to the award of contracts is allowed by the Bidding Documents. 4.4.5. Attend the bid opening, prepare bid tabulation, evaluate bids, assess bidders' responsiveness and responsibility and make award recommendation to OWNER. 4.4.6 Facilitate contract award, and the execution and distribution of the contract documents for construction, materials, equipment and services. Furnish Owner two original signature sets of executed contract documents (including design drawings, specifications and contracts). Furnish contractor with one set of original signature executed contract documents and up to three sets of construction documents. 4.5 CONSTRUCTION PHASE The responsibilities of the ENGINEER during the Construction Phase are summarized as follows: 4.5.1. General Administration of Construction Contract. ENGINEER shall consult with and advise OWNER and act as OWNER'S representative as provided in EXHIBIT A - ENGINEER'S STATUS DURING CONSTRUCTION, attached to and made part of this Agreement and may be further provided under the General Conditions of the contract documents. The extent and limitations of the authority, duties, and responsibilities of the ENGINEER on the construction job site as described here-in shall not be modified except as the ENGINEER and OWNER may otherwise agree in writing. All of OWNER's instruction to Contractor(s) will be issued through ENGINEER who will have authority to act on behalf of OWNER to the extent provided in the General Conditions except as otherwise provided in writing. In addition to the services provided under Article 10 (Exhibit A) the ENGINEER shall provide the following services during construction: 4.5.1.1 Schedule and conduct a pre-construction conference. 4.5.1.2 Provide personnel, equipment and supplies for construction layout and control, including establishment of line, grade, and blue top control staking. 4.5.1.3 Review Contractors' construction schedules and operations, and the Contractors' traffic control plans and its implementation prior to the start of construction. 4.5.1.4 Ascertain that the Contractor has secured required permits needed to accomplish his work. 4.5.1.5 Prepare and provide weekly activity and progress reports to the City's Task Director. 4.5.1.6 ENGINEER shall provide OWNER copies of all correspondence between the ENGINEER and Contractor. 4.5.1.7 Issue stop and resume work orders, in whole or in part, when work is not or cannot be performed in accordance with the Contract Documents. 4.5.1.8 Review and approve, for conformance with the project technical specifications all shop drawings, and other Contractor submittals required by the Contract Documents. 4.5.1.9 During construction review Contractors' construction schedules and evaluate conformance and progress under the Contract time provisions. 4.5.1.10 Prepare for OWNER'S approval any plan and specification changes which due to any initial design or engineering deficiencies are required to complete the project original design concept. 6 4.5.1.11 Inspect the project and when appropriate, and after conferring with OWNER, issue a Certificate of Substantial Completion to the Contractor. 4.5.1.12 Prior to recommending final payment, schedule and conduct with the OWNER a final project inspection and submit a report to the OWNER documenting any outstanding items or deficiencies requiring correction prior to final payment. Upon satisfactory project completion ENGINEER shall certify in writing to the OWNER, and any required regulatory agencies, that the construction was completed in accordance with the approved plans and specifications and is performing in accordance with the design concept. 4.5.1.13 Twenty-three months after project substantial completion schedule and conduct with the Owner a Two Year Warranty Inspection of the project and advise the owner in writing whether project deficiencies exist and if the project is performing in accordance with the design concept. 4.5.2. Resident Project Representative. ENGINEER shall provide a qualified Resident Project Representative at the job site to provide observation of the work as provided in EXHIBIT B - A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE, attached to and made part of this Agreement. The ENGINEER shall submit to the OWNER, for review and acceptance, the resume of each Resident Project Representative who may be assigned to the job site during the course of the Project not less than 10 calendar days prior to the pre-construction meeting. Any subsequent change in the resident representative shall also be subject to the OWNER'S approval. 4.5.3 Limitations of Responsibilities. ENGINEER will not be responsible for CONTRACTOR's means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, and ENGINEER will not be responsible for CONTRACTOR's failure to perform or furnish the Work in accordance with the Contract Documents; however, nothing contained in this Agreement shall be construed to release ENGINEER from liability for failure to properly perform duties and responsibilities assumed by ENGINEER in the Contract Documents. 4.6. PROJECT DOCUMENTATION ENGINEER shall furnish OWNER with (a) one mylar copy, two paper copies, and an electronic copy of the Project Record Drawings ("As-Builts"), (b) written monthly progress reports, and (c) a project notebook containing such correspondence and documentation as requested by OWNER. 4.7. CONSTRUCTION TESTING The inspection services shall include material testing and verification of contract compliance with job site requirements, plans and specifications. The ENGINEER shall provide and maintain detailed documentation of the following material testing: 1) Concrete strength, air content and slump 2) Embankment, trench backfill, and gravel and pavement densities 3) Aggregate gradations 4) Plant mix strength, flow and asphalt content 7 ARTICLE 5 - ADDITIONAL SERVICES 5.1. If OWNER wishes ENGINEER to perform any of the following Additional Services, OWNER shall so instruct ENGINEER in writing, and ENGINEER shall perform or obtain from others such services and will be paid therefor as provided in this Agreement: 5.1.1. Legal land surveys performed to obtain data for preparing easements and rights-of-way descriptions. 5.1.2. Preparation of applications and supporting documents for governmental agencies in addition to those required under Basic Services; preparation or review of environmental studies and related services; and assistance in obtaining environmental approvals. 5.1.3. Services resulting from significant changes in the general scope, extent or character of the Project or major changes in documentation previously accepted by OWNER where changes are due to causes beyond ENGINEER's control. 5.1.4. Providing renderings or models. 5.1.5. Preparing documents for alternate bids requested by OWNER for work not executed or for out-of-sequence work. 5.1.6. Providing other services not otherwise provided for in this Agreement, including services normally furnished by the OWNER as elsewhere herein described. 5.1.7. Furnishing the services of independent professional associates or consultants for other than Basic Services. 5.2. When required by the Contract Documents in circumstances beyond ENGINEER's control, ENGINEER shall perform or obtain from others any of the following Additional Services as circumstances require during construction and without waiting for specific instructions from OWNER, and ENGINEER will be paid therefor as provided in this Agreement: 5.2.1. Services in connection with work directive changes and change orders to reflect the changes requested by OWNER if the resulting change in compensation for Basic Services is not commensurate with the additional services rendered. 5.2.2. Services in making revisions to Drawings and Specifications occasioned by the OWNER'S acceptance of substitutions proposed by Contractor(s); services after the award of each contract in evaluating and determining the acceptability of an unreasonable or excessive number of substitutions proposed by Contractor; and evaluating an unreasonable or extensive number of claims submitted by Contractor(s) or others in connection with the work. 5.2.3. Services resulting from significant delays, changes or price increases occurring as a direct result of materials, equipment or energy shortages. 5.2.4. Additional or extended services during construction made necessary by (1) work damage by fire or other causes during construction, (2) a significant amount of defective or neglected work of any Contractor, (3) acceleration of the progress schedule involving services beyond normal working hours, (4) default by any Contractor. ARTICLE 6 - COMPENSATION FOR ENGINEERING SERVICE 6.1 LUMP SUM AGREEMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER 8 6.1.1 Payment. The OWNER shall for design phase services performed as Basic Engineering Services under sections 4.1 through 4.3 of this Agreement pay a total sum in the amount of $ for such services. 6.1.2 Payment Schedule. Total cumulative payments for the design phase engineering services (sections 4.1 through 4.4) shall not exceed the following ceilings: $ (10 % of design fee) until the Pre-design Investigation and Preliminary Design Report have been submitted to the OWNER. $ (50% of design fee) until the Preliminary Plans and Specifications have been submitted to the OWNER and review authorities. $ (90% of design fee) until the Final Plans and Specifications have been submitted to the OWNER and review authorities. 6.1.3 General. Engineer shall submit monthly statements for services rendered. The statements shall be based upon Engineer's estimate of the proportion of the total services actually completed at the time of billing, subject to any limitations on Payments based on completion of tasks or specific retainage requirements pursuant to the payment provisions of this Agreement. 6.1.4 Reimbursable Expenses. Only those expenses specifically identified for payment under section 6.2 of this Agreement are reimbursable. All other design related expenses are included in the Lump Sum Payment for the Basic services (4.1 through 4.4) and are not separately reimbursable. Additional Services specifically identified under the scope of design services for payment under 6.1 are not separately reimbursable. 6.2 DIRECT LABOR COST PAYMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER. Construction and project documentation services performed as Basic Engineering Services under sections 4.4 through 4.7 including General Administration of Construction Contract, Resident Project Representation, Project Documentation, and Construction Testing, shall be compensated in accordance with the following: 6.2.1 The OWNER shall pay for Construction Phase and Project Documentation Services an amount not to exceed except as provided under 6.2.1.2 and 6.2.4. 6.2.1.1 Costs Compensation. Compensation for these services shall be based on the ENGINEER's Direct Labor Cost times a factor of for services rendered which shall cover Direct Labor, Direct Labor Overhead, General & Administrative Overhead and Profit. 6.2.1.2 Notification. At any time during the construction that it becomes apparent that the Construction Phase and Project Documentation Services rendered under this Agreement will exceed the negotiated compensation for these services, and prior to performing services in excess of the contract ceiling, the ENGINEER shall give OWNER written notice thereof. Promptly thereafter OWNER and ENGINEER shall review the scope and progress of the project work. ENGINEER shall obtain written authorization from OWNER, prior to any additional costs being incurred under paragraph 6.2.1.3. If it is determined that due to a change in project scope under paragraph 5.2.1, the ENGINEER is entitled to additional compensation, OWNER and ENGINEER may negotiate terms as provided under 6.2.1.1. The amount and terms of any additional compensation under 6.2.1.1 or 6.2.1.3 shall be negotiated and agreed in writing pursuant to 9.16. 6.2.1.3 Costs Exceeding Estimated Compensation. Except as allowed under 5.2.1, when the total cost of the original scope Construction Phase and Project Documentation Services exceeds the negotiated compensation for these services, the OWNER shall pay only for the direct costs incurred in excess of the estimated compensation. These costs consist of an amount equal to the ENGINEER'S Direct Labor 9 Cost times a factor of for services rendered which shall include Direct Labor, the federally audited payroll Direct Labor Overhead, and General & Administrative Overhead costs, but shall not include any allowance for profit. 6.2.2. Reimbursable Expenses, as defined in section 7.4 of this Agreement, for Basic Services and Approved Additional Services shall be paid to the ENGINEER by the OWNER in the actual amount of the costs incurred up to an amount not to exceed $ which includes $ for consultants employed by the Engineer and $ for all other reimbursable expenses. The estimated reimbursable expenses are identified in Exhibit " ". 6.2.3. Failed Test Expenses. The ENGINEER shall maintain and provide to the OWNER, a record of the costs associated with failing quality control tests performed for the OWNER during the course of the construction of the project and recommend an amount the OWNER deduct from the contractor(s) payments. 6.2.4 The OWNER shall pay an amount for Additional Services rendered by the ENGINEER and approved in writing by the OWNER on the basis of the ENGINEER'S Direct Labor Costs times a factor of , or an amount otherwise negotiated at the time such services are requested and approved by the OWNER. ARTICLE 7 - MEANING OF TERMS 7.1 AGREEMENT As used herein the term "this Agreement" refers to the contents of this document and its Exhibits attached hereto and referred to as if they were part of one and the same document. 7.2 CONSTRUCTION COSTS The construction cost of the entire Project (herein referred to as "Construction Cost") means the total cost to OWNER of those portions of the entire Project designed and specified by ENGINEER, but it will not include ENGINEER's compensation and expenses, the cost of land, rights-of-way, or compensation for or damages to, properties unless this Agreement so specifies, nor will it include OWNER's legal, accounting, insurance counseling or auditing services, or interest and financing charges incurred in connection with the Project or the cost of other services to be provided by others to OWNER. 7.3 DIRECT LABOR COSTS Direct Labor Costs used as a basis for payment mean the actual salaries and wages paid to all ENGINEER's personnel engaged directly on the Project, including, but not limited to, engineers, architects, surveyors, designers, drafters, specification writers, estimators, other technical and business personnel; but does not include indirect payroll related costs or fringe benefits. For the purposes of this Agreement the principals and employees of the ENGINEER maximum billable Direct Labor Costs are: Principals $ /hour Project Manager $ /hour Senior Engineer $ /hour Staff Engineer $ /hour Senior Technicians $ /hour CADD Drafter $ /hour Technicians $ /hour Construction Inspector $ /hour 10 Two Person Survey Crew $ /hour Clerical $ /hour 7.4 REIMBURSABLE EXPENSES Reimbursable Expenses mean the actual expenses incurred by ENGINEER or ENGINEER's independent professional associates or consultants directly in connection with the Project, such as expenses for: transportation and subsistence incidental thereto; obtaining bids or proposals from Contractor(s); subsistence and transportation of Resident Project Representatives and their assistants; toll telephone calls and telegrams; reproduction of reports, Drawings, Specifications, Bidding Documents and similar Project-related items; and if authorized in advance by OWNER, overtime work requiring higher than regular rates. In addition, when compensation for Basic Services is on the basis of Direct Labor Costs method of payment, Reimbursable Expenses will also include the amount billed to ENGINEER by special consultants employed by ENGINEER and authorized by OWNER (other than as an authorized Additional Services) and will also include expenses incurred for computer time and other specialized equipment, including an appropriate charge for previously established programs and expenses of photographic production techniques. ARTICLE 8 - PAYMENT PROVISIONS 8.1 TIMES OF PAYMENTS. ENGINEER may submit monthly statements for Basic Services and approved Additional Services rendered and for Reimbursable Expenses incurred; however, payments shall not exceed the ceilings provided in 6.1 and 6.2. Final payment shall be made only after acceptance of the project by the OWNER. If OWNER disputes the amount of the billing, OWNER will notify the ENGINEER in writing within ten (10) calendar days of the receipt of bill of the dispute. 8.2 REQUESTS FOR PAYMENT. Each request for payment shall include a documentation summary of the period incremental man hours incurred, direct labor rates and billed rates, detail of reimbursable costs, total period billing, and total cumulative billing. When requested by OWNER services for distinct project segments shall be accounted and billed separately. 8.3 PAYMENT UNDER TERMINATION. In the event of termination by the OWNER upon the completion of any phase of the Basic Services, progress payments due ENGINEER for services rendered through such phase shall constitute total payment for such services. In the event of such termination by OWNER during any phase of the Basic Services, ENGINEER also will be reimbursed for the charges of pre-approved independent professional associates and consultants employed by ENGINEER to render Basic Services, and paid for services rendered during that phase on the basis of the payment provisions of the Agreement. In the event of any such termination, ENGINEER will be paid for unpaid pre-approved Additional Services and unpaid Reimbursable Expenses which are authorized under this agreement. ARTICLE 9 - GENERAL CONSIDERATIONS 9.1 TERMINATION OF AGREEMENT 9.1.1 The sole right is hereby reserved to the OWNER to terminate this Engineering Agreement for any and all causes or for its convenience at any time upon fifteen (15) days written notice to the ENGINEER. 9.1.2 If termination for default is effected by the OWNER, an equitable adjustment in the price provided for in this Agreement shall be made, but (1) no amount shall be allowed for anticipated profit on unperformed services or other work, and (2) any payment due to the ENGINEER at the time of termination may be adjusted to 11 cover any additional costs to the OWNER because of the ENGINEER's default. If termination for convenience is effected by the OWNER, the equitable adjustment shall include a reasonable profit, as determined by owner, for services or other work performed. The equitable adjustment for any termination shall provide for payment to the ENGINEER for services rendered and expenses incurred prior to the termination, in addition to termination settlement costs reasonably incurred by the ENGINEER relating to commitments which had become firm prior to the termination. 9.1.3 Upon receipt of a termination action under paragraph 9.1.2, the ENGINEER shall (1) promptly discontinue all affected work (unless the notice directs otherwise), and (2) deliver or otherwise make available to the OWNER within ten (10) days copies of all data, design drawings, specifications, reports, estimates, summaries and such other information and materials as may have been accumulated by the ENGINEER in performing this Agreement, whether completed or in process. 9.1.4 In the event this Contract is terminated prior to completion, the original copies of the ENGINEER'S data, recommendations, plans, specifications, analysis and other related documents prepared by the ENGINEER prior to said termination shall be delivered to and become the property of the OWNER. 9.1.5 Upon termination, the OWNER may take over the work and may award another party an Agreement to complete the work under this Agreement. 9.1.6 OWNER'S right to terminate is in addition to any other remedies OWNER may have under the law. 9.2 INSPECTION AND AUDIT All books, papers, records, payrolls, vouchers and invoices relating to costs and expenditures incurred as to the performance of the services by the ENGINEER hereunder shall be made available to the OWNER, or their authorized representatives for audit and review, at the ENGINEER'S respective offices at all reasonable times during the contract period and for three years from the date of final payment. 9.3 EMPLOYMENT The ENGINEER warrants that he has not employed or retained any company or persons, other than a bona fide employee, working solely for the ENGINEER, to solicit to secure this contract, and that he has not paid or agreed to pay any company or person, other than bona fide employees working solely for the ENGINEER, any fee, commission, percentage, brokerage fee, gifts or any other considerations contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, the OWNER shall have the right to annul the Contract without liability or in its discretion to deduct from the price or consideration or otherwise recover the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. All employees of the ENGINEER or other persons while engaged in the performance of work or services required by the ENGINEER shall be considered employees of the ENGINEER only and not of the OWNER. 9.4 NONDISCRIMINATION The ENGINEER agrees that all hiring by ENGINEER of persons performing this Agreement shall be on the basis of merit and qualifications. The ENGINEER will have a policy to provide equal employment opportunity in accordance with all applicable state and federal anti-discrimination laws, regulations, and contracts. 12 The ENGINEER will not refuse employment to a person, bar a person from employment, or discriminate against a person in compensation or in a term, condition, or privilege of employment because of race, color, religion, creed, political ideas, sex, age, marital status, national origin, actual or perceived sexual orientation, gender identity, physical or mental disability, except when the reasonable demands of the position require an age, physical or mental disability, marital status or sex distinction. The ENGINEER shall be subject to and comply with Title VI of the Civil Rights Act of 1964; Section 140, Title 2, United States Code, and all regulations promulgated thereunder. ENGINEER represents it is, and for the term of this Agreement will be, in compliance with the requirements of the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act). ENGINEER must report to the City any violations of the Montana Equal Pay Act that Contractor has been found guilty of within 60 days of such finding for violations occurring during the term of this Agreement. ENGINEER shall require these nondiscrimination terms of its subcontractors providing services under this Agreement. The ENGINEER shall require these nondiscrimination terms of its sub-consultants providing services under this agreement. 9.5 SUBLETTING OR ASSIGNING OF WORK The ENGINEER shall not sublet or assign any of the work covered herein without prior written approval of the OWNER. 9.6 STANDARD OF CARE In providing services under this agreement, the ENGINEER will perform in a manner consistent with the degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances. If any service should be found to be not in conformance with this standard, the ENGINEER shall, at the OWNER’s request, re-perform the service at its own expense. Engineer shall also, at its own expense, make such changes, modifications or additions to the project which are made necessary as a result of the initial non-performance or the re-performance of services. The OWNER’s rights herein are in addition to any other remedies the OWNER may have under the law. 9.7 LEGAL RELATIONS: 9.7.1 The ENGINEER shall, consistent with the standard care, comply with those Federal, State, and Local laws and ordinances applicable to the work to be done. 9.7.2 For claims, causes of action, losses, or damages (collectively, “Claims”) asserted by third-parties and arising out of the performance of professional services by the ENGINEER, the ENGINEER shall indemnify and hold the Owner and the Owner’s officers, directors, and employees harmless from such Claims, including reasonable attorneys’ fees and expenses recoverable under applicable law, but only to the extent such Claims are caused by the negligence or intentional misconduct of the ENGINEER, its employees and its consultants in the performance of professional services under this Agreement. The ENGINEER’S obligation to indemnify and hold the Owner and the Owner’s officers and employees harmless under this section 9.7.2 does not include a duty to defend. 9.7.3 For Claims asserted by third-parties that do not arise out of the performance of professional services by the ENGINEER, the ENGINEER shall, to the extent covered by the ENGINEER’S insurance, defend, indemnify, and hold the Owner and the Owner’s officers, directors, and employees harmless from such Claims, including 13 reasonable attorneys’ fees and expenses recoverable under applicable law, but only to the extent such Claims are caused by the negligence or intentional misconduct of the ENGINEER, its employees and its consultants. 9.7.4 In the event the OWNER is found proportionately responsible for any damages ultimately awarded to a plaintiff or plaintiffs in any lawsuit, the ENGINEER will be responsible for only those damages, costs, or liabilities as are attributable to the ENGINEER’S percent of fault as compared with 100% of the fault giving rise to the damages. Should the OWNER be found responsible for negligence by its own officers, directors, agents or employees, then in that event the OWNER agrees to reimburse the ENGINEER for the reasonable attorney’s fees and costs incurred in any defense of the OWNER in an amount proportional to the fault attributed to the OWNER. The indemnity required herein shall not be limited by reason of the specification of any particular insurance coverage in this Agreement. 9.7.5 Should either OWNER or ENGINEER be held responsible, for any damages, costs or liabilities resulting from intentional misconduct by any officer, director, agent or employee in connection with the work specified in this Agreement, then in that event, that party shall indemnify and hold harmless the other as to any damages, costs or liabilities that result from or arise out of that intentional misconduct, including reasonable attorney’s fees and costs which shall include costs and salary of the city attorney or other in-house counsel. Further, notwithstanding the obligations set forth in paragraphs 9.7.2 and 9.7.3 above, the ENGINEER agrees to defend OWNER where the OWNER’S alleged liability arises from intentional misconduct by the ENGINEER. Should the OWNER be found responsible for intentional misconduct by its own officer, director, agent or employee, then OWNER agrees to reimburse ENGINEER for the reasonable attorney’s fees and costs incurred in any defense of the OWNER. 9.7.6 The ENGINEER shall perform this agreement as an independent contractor, and as such, is responsible to the OWNER only as to the results to be obtained in the work herein specified, and to the extent that the work shall be done in accordance with the terms, plans and specifications. The ENGINEER shall have and maintain complete control over all of its employees, subcontractors, agents and operations, being responsible for any required payroll deductions and providing required benefits, such as, but not limited to worker’s compensation with statutory limits, and unemployment insurance. 9.8 INSURANCE The ENGINEER shall secure and furnish to the OWNER certificate of insurance, therein, naming the OWNER as an additional insured, to include thirty (30) days notice of cancellation or non-renewal. Without limiting any of ENGINEER's obligations hereunder, ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, insurance coverage naming the OWNER as additional insured with minimum insurance coverage as follows: 14 Type of Coverage Limits Employers' Liability: $ 1,000,000. per accident General Liability: Bodily Injury & Property Damage Single and combined $ 1,000,000. per accident General Aggregate: $ 2,000,000. Excess Liability Coverage (umbrella) $1,000,000. each occurrence Automobile: Bodily Injury covering all $ 1,000,000 each person automobiles, trucks, tractors, trailers, or $ 1,000,000 each occurrence other automotive equip- ment whether owned or rented by Engineer or owned by employees of Engineer. Property Damage covering $ 1,000,000 each occurrence all automobiles, trucks, tractors, trailers or other automotive equipment whether owned or rented by Engineer or owned by employees of Engineer OR Bodily Injury & Property $1,000,000 each occurrence Damage Single and combined In addition to the above insurance coverage, the ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, and without naming OWNER as an additional insured, professional errors and omissions coverage as follows: Professional Errors & Omissions: $ 1,000,000 per claim and aggregate each occurrence 9.9 ENDORSEMENT The ENGINEER shall place his endorsement on all drawings and other data furnished by him. 15 9.10 OWNERSHIP OF DOCUMENTS The parties admit and agree the documents produced under this agreement are not intended or represented to be suitable for reuse by OWNER or any other individual on any other project. Any reuse without written verification or adaptation by ENGINEER will be at OWNER’s sole risk and without liability or legal exposure to ENGINEER, or to ENGINEER’s independent professional associates or consultants. Files in electronic media format of text, data, graphics, or of other types that are furnished by ENGINEER to OWNER are only for convenience of owner. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. 9.11 PUBLIC INFORMATION The ENGINEER shall not issue any statements, releases or information for public dissemination without prior approval of the OWNER. 9.12 PROPRIETARY RIGHTS If patentable discoveries or inventions should result from work required herein, all rights accruing from such discoveries or inventions shall be joint property of the ENGINEER and the OWNER. Provided that the OWNER, state agencies or political subdivisions and the United States Government shall have the irrevocable, nonexclusive, nontransferable and royalty-free license to use each invention in the manufacture, use and disposition, according to law, of any article or material, and in the use of any method that may be developed as part of the work described and contemplated herein. 9.13 RECORDS The ENGINEER shall maintain accounting records and other evidence pertaining to the cost incurred and to make the records available at all reasonable times during the Contract term and for one (1) year from the date of final payment. Such accounting records and other evidence pertaining to the cost incurred will be made available for inspections by OWNER. 9.14 SUCCESSORS IN INTEREST The covenants, agreements and all statements in this Contract apply to and shall be binding on the heirs, personal representatives, successors and assigns of the respective parties. 16 9.15 ATTORNEY'S FEES AND COSTS That in the event it becomes necessary for either Party of this Contract to retain an attorney to enforce any of the terms or conditions of this Contract or to give any notice required herein, then the prevailing Party or the Party giving notice shall be entitled to reasonable attorney's fees and costs, including fees, salary, and costs of in-house counsel to include City Attorney. 9.16 MODIFICATIONS AND AMENDMENTS That any amendment or modification of this Contract or any provisions herein shall be made in writing or executed in the same manner as this original document and shall after execution become a part of this Contract. 9.17 CONSENT TO ELECTRONIC SIGNATURES The Parties have consented to execute this Agreement electronically in conformance with the Montana Uniform Electronic Transactions Act, Title 30, Chapter 18, Part 1, MCA. In witness Whereof, the Parties hereto do make and execute this Agreement. CITY OF BOZEMAN, MONTANA ENGINEER BY: BY: (City Manager) (President) DATE: DATE: ATTEST: BY: (City Clerk) 1 EXHIBIT A TO AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES ENGINEER'S STATUS DURING CONSTRUCTION This Exhibit is attached to, made a part of and incorporated by reference with the Agreement made on , between CITY OF BOZEMAN (OWNER) and (ENGINEER) providing for professional engineering services. ARTICLE 10 - ENGINEER'S STATUS DURING CONSTRUCTION 10.1. OWNER’S REPRESENTATIVE ENGINEER will be OWNER's representative during the construction period. The duties and responsibilities and the limitations of authority of ENGINEER as OWNER's representative during construction are set forth in the Contract Documents and shall not be extended without written consent of OWNER and ENGINEER. 10.2. VISITS TO THE SITE ENGINEER will make visits to the site at intervals appropriate to the various stages of construction to observe the progress and quality of the executed Work and to determine, in general, if the Work is proceeding in accordance with the Contract Documents. ENGINEER will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. ENGINEER's efforts will be directed toward providing for OWNER's greater degree of confidence that the completed Work will conform to the Contract Documents. On the basis of such visits and on-site observations as an experienced and qualified design professional, ENGINEER will keep OWNER informed of the progress of the Work and will endeavor to guard OWNER against defects and deficiencies in the Work. 10.3. PROJECT REPRESENTATION If OWNER and ENGINEER agree, ENGINEER will furnish a Resident Project Representative to assist ENGINEER in observing the performance of the Work. The duties, responsibilities and limitations of authority of any such Resident Project Representative and assistants will be as provided in EXHIBIT B, A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE. 10.4. CLARIFICATIONS AND INTERPRETATIONS ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the requirements of the Contract Documents (in the form of Drawings or otherwise) as ENGINEER may determine necessary, which shall be consistent with or reasonably inferable from the overall intent of the Contract Documents. If CONTRACTOR believes that a written clarification or interpretation justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree to the amount or extent thereof, CONTRACTOR may make a claim therefor as provided in the General Provisions of the construction Contract Document. 10.5. AUTHORIZED VARIATIONS IN WORK ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Time and are consistent with the overall intent of the Contract Documents. These may be accomplished by a Field Order and will be binding on OWNER, and also on CONTRACTOR who shall perform the Work involved promptly. If CONTRACTOR believes that a Field Order justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree as 2 to the amount or extent thereof, CONTRACTOR may make a claim therefor as provided in the General Conditions of the Construction Contract. 10.6. REJECTING DEFECTIVE WORK ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, and will also have authority to require special inspection or testing of the Work as provided in the General Provisions of the construction Contract Document whether or not the work is fabricated, installed, or completed. 10.7. SHOP DRAWINGS, CHANGE ORDERS AND PAYMENT 10.7.1. The ENGINEER's responsibility for Shop Drawings and samples shall comply with the shop drawing provisions of the General Provisions of the construction Contract Document 10.7.2. The ENGINEER's responsibilities for Change Orders shall comply with the change order provisions of the General Provisions of the construction Contract Document. 10.7.3. The ENGINEER's responsibilities for contractor's Application for Payment shall comply with the payment provisions of the General Provisions of the construction Contract Document. 10.8. DETERMINATIONS FOR UNIT PRICES ENGINEER will determine the actual quantities and classifications of Unit Price Work performed by CONTRACTOR. ENGINEER will review with CONTRACTOR the ENGINEER's preliminary determinations on such matters before rendering a written recommendation thereon (by recommendation of an Application for Payment or otherwise) to OWNER. 10.9. DECISION ON DISPUTES 10.9.1. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. Claims, disputes and other matters relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the performance and furnishing of the Work and claims under The General Conditions of the Construction Contract in respect of changes in the Contract Price or Contract Time will be referred initially to ENGINEER in writing with a request for a formal decision in accordance with this paragraph, which ENGINEER will render in writing within a reasonable time. Written notice of each such claim, dispute and other matter shall be promptly reported and copied to the OWNER. 10.9.2. When functioning as interpreter under paragraphs 10.8 and 10.9.1, ENGINEER will not show partiality to OWNER or CONTRACTOR and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to paragraphs 10.8 and 10.9.1 with respect to any such claim, dispute or other matter will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any such claim, dispute or other matter. 3 10.10. LIMITATIONS ON ENGINEER'S RESPONSIBILITIES 10.10.1. Neither ENGINEER's authority to act under this Article or elsewhere in the Contract Documents nor any decision made by ENGINEER in good faith either to exercise or not exercise such authority shall give rise to any duty or responsibility of ENGINEER to CONTRACTOR, any Sub-contractor, any Supplier, or any other person or organization performing any of the Work, or to any surety for any of them. 10.10.2. Whenever in the Contract Documents the terms "as ordered", "as directed", "as required", "as allowed", "as approved" or terms of like effect or import are used, or the adjectives "reasonable", "suitable", "acceptable", "proper" or "satisfactory" or adjectives of like effect or import are used to describe a requirement, direction, review or judgment of ENGINEER as to the Work, it is intended that such requirement, direction, review or judgment will be solely to evaluate the Work for compliance with the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective shall not be effective to assign to ENGINEER any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of paragraph 4.5.3. 1 EXHIBIT B TO AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE. This Exhibit is attached to, made a part of and incorporated by reference with the Agreement made on , between CITY OF BOZEMAN (OWNER) and (ENGINEER) providing for professional engineering services. ARTICLE 11 - DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE ENGINEER shall furnish a Resident Project Representative (RPR), assistants and other field staff to assist ENGINEER in observing performance of the work of Contractor. Through more extensive on-site observations of the work in progress and field checks of materials and equipment by the RPR and assistants, ENGINEER shall endeavor to provide further protection for OWNER against defects and deficiencies in the work of CONTRACTOR; but, the furnishing of such services will not make ENGINEER responsible for or give ENGINEER control over construction means, methods, techniques, sequences or procedures or for safety precautions or programs, or responsibility for CONTRACTOR's failure to perform the Work in accordance with the Contract Documents and in particular the specific limitations set forth in section 4.5 of the Agreement are applicable. The duties and responsibilities of the RPR are limited to those of ENGINEER in this agreement and in the construction Contract Documents, and are further limited and described as follows: 11.1. GENERAL RPR is ENGINEER's agent at the site, will act as directed by and under the supervision of ENGINEER, and will confer with ENGINEER regarding RPR's actions. RPR's dealings in matters pertaining to the on-site work shall in general be with ENGINEER and CONTRACTOR keeping OWNER advised as necessary. RPR's dealings with subcontractors shall only be through or with the full knowledge and approval of CONTRACTOR. RPR shall generally communicate with OWNER with the knowledge of and under the direction of ENGINEER. 11.2. DUTIES AND RESPONSIBILITIES OF RPR 11.2.1. Schedules: Review the progress schedule, schedule of Shop Drawing submittals and schedule of values prepared by CONTRACTOR and consult with ENGINEER concerning acceptability. 11.2.2. Conferences and Meetings: Attend meetings with CONTRACTOR, such as preconstruction conferences, progress meetings, job conferences and the project-related meetings, and prepare and circulate copies of minutes thereof. 11.2.3. Liaison: 11.2.3.1. Serve as ENGINEER's liaison with CONTRACTOR, working principally through CONTRACTOR's superintendent and assist in understanding the intent of the Contract Documents; and assist ENGINEER in serving as OWNER's liaison with CONTRACTOR. 2 11.2.3.2. Assist in obtaining from OWNER additional details or information, when required for proper execution of the Work. 11.2.4. Shop Drawings and Samples: 11.2.4.1. Record date of receipt of Shop Drawings and samples. 11.2.4.2. Receive samples which are furnished at the site by CONTRACTOR, and notify ENGINEER of availability of samples for examination. 11.2.4.3. Advise ENGINEER and CONTRACTOR of the commencement of any Work requiring Shop Drawing or sample if the submittal has not been approved by ENGINEER. 11.2.5. Review of Work, Rejection of Defective Work, Inspections and Tests: 11.2.5.1. Conduct on-site observations of the Work in progress to assist ENGINEER in determining if the Work is in general proceeding in accordance with the Contract Documents. 11.2.5.2. Report to ENGINEER whenever RPR believes that any Work is unsatisfactory, faulty or defective or does not conform to the Contract Documents, or has been damaged, or does not meet the requirements of any inspection, test or approval required to be made; and advise ENGINEER of Work that RPR believes should be corrected or rejected or should be uncovered for observation, or requires special testing, inspection or approval. 11.2.5.3. Verify that tests, equipment and systems startup and operating and maintenance training are conducted in the presence of appropriate personnel, and the CONTRACTOR maintains adequate records thereof; and observe, record and report to ENGINEER appropriate details relative to the test procedures and startup. 11.2.5.4. Accompany visiting inspectors representing public or other agencies having jurisdiction over the Project, record the results of these inspections and report to ENGINEER. 11.2.6. Interpretation of Contract Documents: Report to ENGINEER when clarifications and interpretations of the Contract Documents are needed and transmit to CONTRACTOR clarifications and interpretations as issued by ENGINEER. 11.2.7. Modifications: Consider and evaluate CONTRACTOR's suggestions for modifications in Drawings or Specifications and report with RPR's recommendations to ENGINEER. Transmit to CONTRACTOR decisions as issued by ENGINEER. 11.2.8. Records: 11.2.8.1. Maintain at the job site orderly files for correspondence, reports of job conferences, Shop Drawings and samples, reproductions of original Contract Documents including all Work Directive Changes, Addenda, Change Orders, Field Orders, additional Drawings issued subsequent to the execution of the Contract, ENGINEER's clarifications and interpretations of the Contract Documents, progress reports, and other Project related documents. 11.2.8.2. Keep a detailed and accurate diary or log book, recording CONTRACTOR hours on the job site, weather conditions, prime and subcontractor daily work force, daily log of equipment onsite or on standby, data relative to questions of Work Directive Changes, Change Orders or changed conditions, list of job site visitors, daily activities, decisions, observations in general, and 3 specific observations in more detail as in the case of observing test procedures; and send copies to ENGINEER. 11.2.8.3. Record names, addresses and telephone numbers of all CONTRACTORS, subcontractors and major suppliers of materials and equipment. 11.2.9. Reports: 11.2.9.1. Furnish ENGINEER periodic reports as required of progress of the Work and of CONTRACTOR's compliance with the progress schedule and schedule of Shop Drawing and sample submittals. 11.2.9.2. Consult with ENGINEER in advance of scheduled major tests, inspections or start of important phases of the Work. 11.2.9.3. Draft proposed Change Orders and Work Directive Changes, obtaining backup material from CONTRACTOR and recommend to ENGINEER Change Orders, Work Directive Changes, and Field Orders. 11.2.9.4. Report immediately to ENGINEER and OWNER upon the occurrence of any accident. 11.2.10. Payment Requests: Review applications for payment with CONTRACTOR for compliance with the established procedure for their submission and forward with recommendations to ENGINEER, noting particularly the relationship of the payment requested to the schedule of values, Work completed and materials and equipment delivered at the site but not incorporated in the Work. 11.2.11. Certificates, Maintenance and Operation Manuals: During the course of the Work, verify that certificates, maintenance and operation manuals and other data required to be assembled and furnished by CONTRACTOR are applicable to the items actually installed and in accordance with the Contract Documents, and have this material delivered to ENGINEER for review and forwarding to OWNER prior to final payment for the Work. 11.2.12. Completion: 11.2.12.1. Submit to CONTRACTOR, and ENGINEER a list of observed items requiring completion or correction before ENGINEER may issue a Certificate of Substantial Completion. 11.2.12.2 Assess completion or correction of items noted under 11.2.12.1, advise ENGINEER on their status, and make recommendation to Engineer regarding issuance of a Certificate of Substantial completion. 11.2.12.3. Conduct final inspection in the company of ENGINEER, OWNER, and CONTRACTOR and prepare a final list of items to be completed or corrected. 11.2.12.4. Observe that all items on final list have been completed or corrected and make recommendations to ENGINEER concerning final acceptance. 11.3. LIMITATIONS OF AUTHORITY Resident Project Representative: 11.3.1. Shall not authorize any deviation from the Contract Documents or substitution of materials or equipments, unless authorized by ENGINEER. 4 11.3.2. Shall not exceed limitations of ENGINEER's authority as set forth in the Agreement or the Contract Documents. 11.3.3. Shall not undertake any of the responsibilities of CONTRACTOR, subcontractors or CONTRACTOR's superintendent. 11.3.4. Shall not advise on, issue directions relative to or assume control over any aspect of the means, methods, techniques, sequences or procedures of construction unless such advice or directions are specifically required by the Contract Documents. 11.3.5. Shall not advise on, issue directions regarding or assume control over safety precautions and programs in connection with the Work. 11.3.6. Shall not accept Shop Drawing or sample submittals from anyone other than CONTRACTOR. 11.3.7. Shall not authorize OWNER to occupy the Project in whole or in part. 11.3.8. Shall not participate in specialized field or laboratory tests or inspections conducted by others except as specifically authorized by ENGINEER.