Loading...
HomeMy WebLinkAboutRFP - General Contractor - Elevator Machine Room Modernization - PacketPage 1 of 13 REQUEST FOR PROPOSALS (RFP) ELEVATOR MACHINE ROOM MODERNIZATION GENERAL CONTRACTOR STIFF PROFESSIONAL BUILDING – 20 E. OLIVE, BOZEMAN, MT 59715 CITY OF BOZEMAN Bozeman, MT City of Bozeman PO Box 1230 Bozeman, MT 59771-1230 January 2024 NOTICE IS HEREBY given that the City of Bozeman (City) is seeking proposals from Genral Contracting firms to renovate an elevator machine room to meet current building code requirements and support the modernization of a 1978 elevator being replaced by Otis Elevator Company. Machine room upgrades to include carpentry, plumbing, electrical, and fire suppression systems modifications. This project is located at the Stiff Professional Building, 20 E. Olive, Bozeman, MT 59715. Copies of the Request for Proposals are available on the City’s website. All proposals must be provided as a single, searchable PDF document file and be submitted digitally as an email attachment to the RFP Recipient email address below. Respondents are advised that Recipient’s email attachment size limit is 25MB and that only one PDF file will be allowed per response. The subject line of the transmittal email shall clearly identify the RFP title, company name and due date/time. File sizes greater than 25MB in size may be uploaded to bzncloud.bozeman.net upon special arrangement of the Recipient; however, it is the respondent’s sole responsibility to ensure the file upload is completed, and that the Recipient is separately notified via email of same, prior to the given deadline. Deliver RFPs via email to the City Clerk by February 23, 2024 at 2:00 PM MST. It is the sole responsibility of the proposing party to ensure that proposals are received prior to the closing time as late submittals will not be accepted and will be returned unopened. The email address for submission is: agenda@bozeman.net NON-DISCRIMINATION AND EQUAL PAY The City of Bozeman is an Equal Opportunity Employer. Discrimination in the performance of any agreement awarded under this RFP on the basis of race, color, religion, creed, sex, age, marital status, national origin, or actual or perceived sexual orientation, gender identity or disability is prohibited. This prohibition shall apply to the hiring and treatment of the awarded entity’s employees and to all subcontracts. As such, each entity submitting under this notice shall include a provision wherein the submitting entity, or entities, affirms in writing it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, gender identity or disability and which also recognizes the eventual contract will contain a provision prohibiting discrimination as described above and that this prohibition on discrimination shall apply to the hiring and treatment of the submitting entity’s employees and to all subcontracts. In addition, pursuant to City Commission Resolution 5169, the entity awarded a contract under this RFP and any subcontractors must abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and affirm it will abide by the above and that it has visited the State of Montana Equal Pay for Equal Work “best practices” website, or equivalent “best practices publication and has read the material. Any administrative questions regarding proposal procedures should be directed to: Mike Maas, City Clerk (406) 582-2321, agenda@bozeman.net. Questions relating to the RFP should be directed to: Max Ziegler, Facilities Project Coordinator, (406) 582-2439, wziegler@bozeman.net. DATED at Bozeman, Montana, this January 13, 2024. Mike Maas City Clerk City of Bozeman For publication on: Saturday, January 13, 2024 Saturday, February 17, 2024 I. INTRODUCTION The City of Bozeman (Owner), is seeking proposals from General Contracting firms to undertake a code compliance renovation of an elevator machine room where a 1978 hydraulic lift is being replaced by Otis Elevator Company The Owner intends to enter into a contract with the selected General Contractor that will include all renovation and improvement work required to accommodate the modernization of the existing elevator and bring the existing elevator machine room up to current code requirements. This work will include carpentry, plumbing, electrical, and fire suppression system improvements to the machine room and hoistway. This project is to be completed in advance of the elevator modernization. This RFP shall not commit the Owner to enter into an agreement, to pay any expenses incurred in preparation of any response to this request, or to procure or contract for any supplies, goods or services. The Owner reserves the right to accept or reject all responses received as a result of this RFP if it is in the Owner’s best interest to do so. This procurement is governed by the laws of the State of Montana and venue for all legal proceedings shall be in the 18th Judicial District Court, Gallatin County. By offering to perform services under this RFP, all Submitters agree to be bound by the laws of the State of Montana and of the Owner, including, but not limited to, applicable wage rates, payments, gross receipts taxes, building codes, equal opportunity employment practices, safety, non-discrimination, etc. II. PROJECT BACKGROUND AND DESCRIPTION The Stiff Professional Building is a municipal office building located at 20 E Olive St., Bozeman, MT 59715. Originally constructed in 1959, a second level and hydraulic elevator was added in 1978. The Elevator has since exceeded its service life and is to be modernized by Otis Elevator Company in 2024. The contract with Otis Elevator does not include improvements to the elevator machine room required by code which must be completed before the elevator may be installed. As elevator code has undergone significant revision since the 1978 installation of the existing elevator, a number of upgrades are required to meet fire and electrical code requirements. This project will include installing sheetrock and fire rated assemblies, patching penetrations, installing a sump pump, ventilating the machine room, installing shunt trip electrical disconnects, improve lighting and electrical distribution, and modification of sprinkler and smoke detection systems. The City is seeking a General Contractor to complete the full Scope of Services below in Spring/Summer of 2024. Submitting firms will be required to attend a walkthrough of the project site. Walkthroughs may be scheduled Monday – Friday 8:00AM - 4:00 PM during this RFP’s open window, pending availability. To schedule a pre-submission walkthrough please contact: Max Ziegler Facilites Project Coordinator wziegler@bozeman.net 406-582-2439 III. SCOPE OF SERVICES The Scope of Services for this project is to execute all required elevator machine room improvements not being provided by Otis Elevator Company in order to bring the machine room into compliance with all current applicable codes and regulations. The selected General Contractor will be responsible for all aspects of construction, including permitting, bidding, and inspections. Please see Appendix C for scope of services provided by Otis Elevator Company. The following tasks have been identified as requirements for this project. The selected Contractor will be responsible for ensuring that proposed scope of services meets and satisfies all code requirements related to the elevator modernization project. Carpenty: - Install 7’6” hard lid ceiling in machine room below exposed plumbing to meet fire rating requirement. Install fire rated access hatches below any plumbing controls. - Remove all flammable sound dampening from Machine Room - Install new fire rated Machine Room door and jamb with auto close and spring lock - Install second layer of sheetrock in Machine Room, patch and seal all penetrations - Inside hoistway, install 75 degree angled surface on top of ledge at second floor - Inside hoistway, patch holes in concrete block for fire rating - Inside hoistway, patch sheetrock gaps between elevator door jambs and walls Plumbing: - Install sump pump designed for elevator pits with oil separator. To be pinned to floor of hoistway and discharged to sanitary sewer Electrical: - Ventilate Machine Room – install thermostatic fire rated 150 cfm exhaust fan for temperature control requirement. Vent to hoistway and install fire rated passive air intake. - Replace Elevator main power disconnect with shunt trip breaker - Relocate Machine Room lighting to accommodate hard lid installation - Re-route electrical conduit to elevator machinery - Replace electrical conduit in hoistway pit to be either 4’ above floor or watertight - Replace existing light in hoistway with new LED fixture - Install overload protection device inside Machine Room for 120V service - Replace 120V outlet in elevator hoistway pit with GFCI - Install electrical connection for sump pump Fire Suppression Systems: - Relocate smoke/heat detectors at top of hoistway to next to sprinkler head - Relocate smoke/heat detectors in Machine Room to new hard lid - Connect shunt trip breaker to fire detection / alarm system - Remove smoke/heat detector at bottom of hoistway Third Party Inspection: - The City may, at the City’s discresion, employ a third party elevator inspection firm to inspect all work related to the mechical room and hositway upgrades. Submitting firms will be required to attend a walkthrough of the project site. Walkthroughs may be scheduled Monday – Friday 8:00AM - 4:00 PM during this RFP’s open window, pending availability. To schedule a pre-submission walkthrough please contact: Max Ziegler Facilites Project Coordinator wziegler@bozeman.net 406-582-2439 IV. PROPOSAL REQUIREMENTS Firms interested in providing the services described above are requested to submit the following information. Responses to each item should appear in the same order as in this RFP and should identify the item to which the responses applies. a) Executive Summary Provide a brief overview of your proposal. b) Firm Profile A summary of the proposing firm, including but not limited to capabilities and capacities, staffing, financial status, and insurance and bonding. c) Experience with Similar Projects Describe your firm’s experience with projects of a similar size or scope. d) Description of Proposed Solution Outline your proposed method of project execution, including any alternate solutions to items included in the Scope of Services e) Proposed Schedule Provide a schedule for delivery of this project, including possible start dates and duration of construction. f) Present and Projected Workloads Provide a summary of your current and projected workloads for 2024. g) Recent and Current Work for the City of Bozeman List any projects in process or previously completed for the City of Bozeman h) References List three (3) references from clients who the firm has completed projects for within the last five (5) years. i) Price Proposal Provide a fully inclusive and detailed price proposal for completion of this project. Provide alternates as applicable. j) Affirmation of Nondiscrimination (see Appendix A) Non-completion of the Affirmation of Nondiscrimination is cause for disqualification of firms. Submitting firms will be required to attend a walkthrough of the project site. Walkthroughs may be scheduled Monday – Friday 8:00AM - 4:00 PM during this RFP’s open window, pending availability. To schedule a pre-submission walkthrough please contact: Max Ziegler Facilites Project Coordinator wziegler@bozeman.net 406-582-2439 V. TIMELINES, DELIVERY DEADLINE, AND INSTRUCTIONS EVENT DATE/TIME Publication dates of RFP Saturday, January 13 Saturday, February Deadline for receipt of proposals February 23, 2024 Evaluation of proposals March 6, 2024 Interviews (if necessary) and Selection of consultants TBD With the exception of the advertising dates and advertised due date, the City reserves the right to modify the above timeline. Deliver RFPs via email to the City Clerk (agenda@bozeman.net) by February 23, 2024 at 2:00 PM MST. It is the sole responsibility of the proposing party to ensure that proposals are received prior to the closing time as late submittals will not be accepted and will be returned unopened. All proposals must be provided as a single, searchable PDF document file and be submitted digitally as an email attachment to the RFP Recipient email address agenda@bozeman.net. Respondents are advised that Recipient’s email attachment size limit is 25MB and that only one PDF file will be allowed per response. The subject line of the transmittal email shall clearly identify the RFP title, company name and due date/time. File sizes greater than 25MB in size may be uploaded to bzncloud.bozeman.net upon special arrangement of the Recipient; however, it is the respondent’s sole responsibility to ensure the file upload is completed, and that the Recipient is separately notified via email of same, prior to the given deadline. VI. AMENDMENTS TO SOLICITATION Any interpretation or correction of this request will be published on the City’s webpage. The deadline for questions related to this document is 12:00 PM MST on February 20, 2024. VII. CONTACT INFORMATION Any administrative questions regarding proposal procedures should be directed to: Mike Maas, City Clerk, (406) 582-2321, agenda@bozeman.net Questions relating to scope of services should be directed to: Max Ziegler, Facilities Project Coordinator, wziegler@bozeman.net, 406-582-2439. VIII. SELECTION PROCEDURE A review committee will evaluate all responses to the RFP that meet the submittal requirements and deadline. Submittals that do not meet the requirement or deadline will not be considered. The review committee will rank the proposals and may arrange interviews with the finalist(s) prior to selection. Selection may be made directly based on the written RFP submission. If interviews occur, the selection of finalists to be interviewed will be made by a selection committee representing the City of Bozeman. The selection of interview candidates will be based on an evaluation of the written responses to the RFPs. All submitted proposals must be complete and contain the information required as stated in the "Request for Proposals.” IX. SELECTION CRITERIA Proposals will be evaluated based on the following criteria:  [10 points] Executive Summary  [10 points] Firm Profile  [20 points] Experience with Similar Projects  [10 points] Description of Proposed Solution  [5 points] Proposed Schedule  [5 points] Present and Projected Workloads  [5 points] Recent Work for the City of Bozeman  [5 points] References  [30 points] Price Proposal X. FORM OF AGREEMENT The Contractor will be required to enter into a contract with the City in substantially the same form as the Construction Agreement attached as Attachment B. XI. CITY RESERVATION OF RIGHTS / LIABILITY WAIVER All proposals submitted in response to this RFP become the property of the City and public records and, as such, may be subject to public review. A SUBMISSION IN RESPONSE TO THIS REQUEST FOR QUALIFICATIONS CONFERS NO RIGHTS UPON ANY RESPONDENTS AND SHALL NOT OBLIGATE THE CITY IN ANY MANNER WHATSOEVER. THE CITY RESERVES THE RIGHT TO MAKE NO AWARD AND TO SOLICIT ADDITIONAL REQUEST FOR QUALIFICATIONS AT A LATER DATE. A. This RFP may be canceled or any or all responses may be rejected in whole or in part, as specified herein, when it is in the best interests of the City. If the City cancels or revises this RFP, all Respondents who submitted will be notified using email. B. The City reserves the right to accept or reject any and all proposals; to add or delete items and/or quantities; to amend the RFP; to waive any minor irregularities, informalities, or failure to conform to the RFP; to extend the deadline for submitting proposals; to postpone award for up to 60 days; to award one or more contracts, by item or task, or groups of items or tasks, if so provided in the RFP and if multiple awards or phases are determined by the City to be in the public interest. C. The City of Bozeman reserves the right to reject the proposal of any person/firm who previously failed to perform properly to the satisfaction of the City of Bozeman, or complete on time agreements of similar nature, or to reject the proposal of any person/firm who is not in a position to perform such an agreement satisfactorily as determined by the City of Bozeman. D. The City of Bozeman reserves the right to determine the best qualified Contractor and negotiate a final scope of service and cost, negotiate a contract with another Contractor if an agreement cannot be reached with the first selected Contractor, or reject all proposals. E. The professional services contract between the City of Bozeman and the successful Contractor will incorporate the Contractor's scope of service and work schedule as part of the agreement (see Appendix B for sample form of construction agreement. The professional services agreement presented to the Contractor may differ from this form as appropriate for the scope of services). F. This RFP does not commit the City to award a contract. The City assumes no liability or responsibility for costs incurred by firms in responding to this request for proposals or request for interviews, additional data, or other information with respect to the selection process, prior to the issuance of an agreement, contract or purchase order. The Contractor, by submitting a response to this RFP, waives all right to protest or seek any legal remedies whatsoever regarding any aspect of this RFP. G. The City reserves the right to cancel, in part or in its entirety, this RFP including, but not limited to: selection procedures, submittal date, and submittal requirements. If the City cancels or revises this RFP, all Contractors who submitted proposals will be notified using email. H. Projects under any contract are subject to the availability of funds. XII. NONDISCRIMINATION AND EQUAL PAY POLICY The City of Bozeman requires each entity submitting under this notice shall affirm, on a separate form provided, that it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, sexual preference, gender identity, or disability in fulfillment of a contract entered into for the services identified herein and that this prohibition on discrimination shall apply to the hiring and treatment of the submitting entity’s employees and to all subcontracts it enters into in the fulfillment of the services identified herein. Failure to comply with this requirement shall be cause for the submittal to be deemed nonresponsive. The City also requires each entity submitting under this notice shall affirm it will abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and has visited the State of Montana Equal Pay for Equal Work “best practices” website, https://equalpay.mt.gov/BestPractices/Employers, or equivalent “best practices publication and has read the material. XIII. MISCELLANEOUS A. No Oral Agreements. No conversations or oral agreements with any officer, employee, or agent of the City shall affect or modify any term of this solicitation. Oral communications or any written/email communication between any person and City officer, employee or agent shall not be considered binding. B. No Partnership/Business Organization. Nothing in this solicitation or in any subsequent agreement, or any other contract entered into as a result of this solicitation, shall constitute, create, give rise to or otherwise be recognized as a partnership or formal business organization of any kind between or among the respondent and the City. C. Employment Restriction and Indemnity. No person who is an owner, officer, employee, contractor, or consultant of a respondent shall be an officer or employee of the City. No rights of the City’s retirement or personnel rules accrue to a respondent, its officers, employees, contractors, or consultants. Respondents shall have the responsibility of all salaries, wages, bonuses, retirement, withholdings, worker’s compensation and occupational disease compensation, insurance, unemployment compensation other benefits and taxes and premiums appurtenant thereto concerning its officers, employees, contractors, and consultants. Each Respondent shall save and hold the City harmless with respect to any and all claims for payment, compensation, salary, wages, bonuses, retirement, withholdings, worker’s compensation and occupational disease compensation, insurance, unemployment compensation other benefits and taxes and premiums in any way related to each respondent’s officers, employees, contractors and consultants. D. Accessibility. Upon reasonable notice, the City will provide assistance for those persons with sensory impairments. For further information please contact the ADA Coordinator Mike Gray at 406-582-3232 or the City’s TTY line at 406-582-2301. E. Procurement. When discrepancies occur between words and figures in this solicitation, the words shall govern. No responsibility shall attach to a City employee for the premature opening of an RFP not properly addressed and identified in accordance with these documents. F. Governing Law. This solicitation and any disputes arising hereunder or under any future agreement shall be governed and construed and enforced in accordance with the laws of the State of Montana, without reference to principles of choice or conflicts of laws. XIV. ATTACHMENTS The following exhibits are incorporated in this RFP: Appendix A: Non-Discrimination Affirmation Appendix B: Sample Form of Construction Agreement Appendix C: Otis Elevator Company Scope of Services END OF RFP Attachment A NONDISCRIMINATION AND EQUAL PAY AFFIRMATION ____________________________________(name of entity submitting) hereby affirms it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, gender identity or disability and acknowledges and understands the eventual contract will contain a provision prohibiting discrimination as described above and this prohibition on discrimination shall apply to the hiring and treatments or proposer’s employees and to all subcontracts. In addition, ____________________________________(name of entity submitting) hereby affirms it will abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and has visited the State of Montana Equal Pay for Equal Work “best practices” website, https://equalpay.mt.gov/BestPractices/Employers, or equivalent “best practices publication and has read the material. ______________________________________ Name and title of person authorized to sign on behalf of submitter EXHIBIT B Construction Agreement for __________ FY2020-2021 Page 1 of 16 CONSTRUCTION AGREEMENT This Construction Agreement is made and entered into this _____ day of ____________, 202__ (“Effective Date”), by and between the CITY OF BOZEMAN, MONTANA, a self- governing municipal corporation organized and existing under its Charter and the laws of the State of Montana, 121 North Rouse Street, Bozeman, Montana, with a mailing address of PO Box 1230, Bozeman, MT 59771, hereinafter referred to as “City,” and, ____________, _______________, hereinafter referred to as “Contractor.” The City and Contractor may be referred to individually as “Party” and collectively as “Parties.” In consideration of the covenants, agreements, representations, and warranties contained herein, the parties agree as follows: 1. Work to be Performed: a. A description of the work to be performed to _____________________ (the “Construction Project”) and Contractor’s duties is set forth in the Scope of Services attached hereto as Exhibit A and by this reference made a part hereof, and in the drawings, plans, and specifications provided by the City, which are included in the Scope of Services attached hereto as Exhibit A. b. Prior to the commencement of any work on the Construction Project, Contractor’s representatives and City’s representatives shall hold a meeting to establish a working understanding among the parties as to the scope of the Construction Project and duties of the Contractor. At this meeting, Contractor and City shall resolve any outstanding issues related to the plans, designs, drawings, and specifications. If the parties are unable to resolve these issues and the City fails, refuses, or is unable to approve the same, no work shall commence on the Construction Project until such issues are resolved and the City approves the related plans, designs, drawings, and specifications. c. Except as provided elsewhere in this Agreement, Contractor shall furnish all the labor, materials, equipment, tools, and services necessary to perform and complete the Construction Project. d. During work on the Construction Project, and as part of the final completion of the Construction Project, Contractor shall clean up the Project site, including the removal and satisfactory disposal of all waste, garbage, excess materials, and equipment, and the performance of any other work necessary to restore the site to at least as good order and condition as at the commencement of the Construction Project. Construction Agreement for __________ FY2020-2021 Page 2 of 16 2. City-Supplied Materials: The City may supply materials from time to time in furtherance of the Construction Project. Such materials will be noted as an addendum to this Agreement. 3. Time of Performance: Contractor shall begin the Construction Project after receiving a Notice to Proceed from City and shall complete the Construction Project no later than ______________________. Time is of the essence of completion of all work and each phase of the Construction Project. 4. Liquidated Damages: If the Construction Project is not completed within the time provided by this Agreement, the City may deduct for each day the Construction Project remains uncompleted the sum of Five Hundred Dollars ($500.00) from the compensation hereinafter specified and retain that sum as payment for liquidated damages sustained by reason of the Contractor’s failure to complete the Construction Project on time. 5. Compensation: a. City shall pay to Contractor, and Contractor shall accept as full payment for the performance of this Agreement and the Construction Project, the amount of _____________________________ Dollars ($_____________). b. If work not included within the original Construction Documents is requested by City, such additional work and the related compensation shall be agreed to in writing by both parties prior to commencement of the additional work (“Change Order”). c. City shall retain five percent (5%) of the total amount of compensation to be paid to the Contractor to ensure compliance with the terms and conditions of this Agreement and the timely completion of the Construction Project and any and all “punch list” items (“Retainage Amount”). The Retainage Amount shall be paid to Contractor thirty (30) days after the City’s final acceptance of the portion of work for which a separate price is stated in the specifications for the Construction Project. e. Upon acceptance of final payment and for other good and valuable consideration, Contractor shall and hereby does release and forever discharge City, its officers, agents, and employees of and from any and all claims, demands, actions, causes of action, obligations, and liabilities of every kind and character whatsoever, in law and in equity, whether now known or in the future discovered, arising from or related to this Agreement or the Construction Project that Contractor may have or assert against City, its officers, agents, and employees. 6. Inspection and Testing: a. City has the right to inspect and test any and all work performed by Contractor on the Construction Project. Contractor shall allow City and its agents access to the Construction Project at all times and shall provide every reasonable facility for the purpose of such inspection and testing, including temporarily discontinuing portions of the Construction Agreement for __________ FY2020-2021 Page 3 of 16 work or uncovering or taking down portions of the finished work. Any inspection and testing performed by the City and its agents is for the sole benefit of the City and shall not relieve the Contractor of its duty, responsibility, and obligation to ensure that the work strictly complies with the Agreement terms and conditions and all applicable laws and building and safety codes. City’s inspection and testing shall not be deemed or considered acceptance by the City of any portion of the Construction Project. City’s inspection and testing shall not serve to nullify, amend, or waive any warranties provided by the Contractor under this Agreement. b. Contractor shall, without charge, replace any material or correct any work found by the City or its agents to be defective or otherwise not in compliance with the terms and conditions of this Agreement. In the event Contractor fails to replace or correct any defective work or materials after reasonable written notice by the City to do so, the City may take such corrective action, either with its own materials and employees or by retaining any third party to do so, and deduct the cost and expense of such corrective action from the Contractor’s compensation. 7. Partial Utilization of Construction Project: City shall have the right to use or occupy any portion of the Construction Project that City and Contractor mutually agree is substantially completed and constitutes a separately functioning and usable part of the Construction Project for its intended purpose without significant interference with Contractor’s performance of the remaining portions of the Construction Project. In the event City takes possession of any portion of the Construction Project, such possession shall not be deemed an acceptance of the Construction Project, in whole or in part. City’s use of any portion of the Construction Project shall not be grounds for extensions of any construction deadlines or a change in the Contractor’s compensation. Contractor’s warranties shall run from the completion of the total Construction Project and not from the date the City may take possession of selected portions of the Construction Project. 8. Related Work at the Site: Nothing in this Agreement shall prevent or preclude City, through its own employees or by contract with any third party, from performing other work related to the Construction Project at the construction site; provided such related work is not otherwise addressed in this Agreement and provided such related work does not otherwise interfere with Contractor’s performance of this Agreement or the completion of the Construction Project. Contractor shall afford any City employee, agent or representative, or any third party under contract with the City to perform the related work, proper and safe access to the construction site, a reasonable opportunity for the introduction and storage of materials and equipment, the opportunity to perform the related work, and shall properly coordinate the Contractor’s work on the Construction Project with the related work. 9. Contractor’s Warranties: Contractor represents and warrants as follows: a. Unless otherwise specified by the terms of this Agreement, all materials and equipment used by Contractor on the Construction Project shall be new and where not otherwise specified, of the most suitable grade for their intended uses. Construction Agreement for __________ FY2020-2021 Page 4 of 16 b. All workmanship and materials shall be of a kind and nature acceptable to the City. c. All equipment, materials, and labor provided to, on, or for the Construction Project must be free of defects and nonconformities in design, materials, and workmanship for a minimum period beginning with the commencement of the work on the Construction Project and ending one (1) year from the final completion and acceptance by the City of the Construction Project, regardless of whether such equipment, materials, or labor were supplied directly by Contractor or indirectly by Contractor’s subcontractors or suppliers. Other express warranties on materials that provide for a warranty period longer than one year apply for the period of that express warranty and are not reduced by this provision. Upon receipt of City’s written notice of a defective or nonconforming condition during the warranty period, Contractor shall take all actions, including redesign and replacement, to correct the defective or nonconforming condition within a time frame acceptable to the City and at no additional cost to the City. Contractor shall also, at its sole cost, perform any tests required by City to verify that such defective or nonconforming condition has been corrected. Contractor warrants the corrective action taken against defective and nonconforming conditions for a period of an additional one (1) year from the date of City’s acceptance of the corrective action. d. Contractor and its sureties are liable for the satisfaction and full performance of all warranties. e. Contractor shall give its personal attention to the faithful prosecution of the completion of the Construction Project and Contractor, or its duly authorized representative assigned to serve as the Construction Project Manager, shall be personally present at the site of the Construction Project during working hours for the term of this Agreement until the completion of the Construction Project. f. Contractor shall have a complete, accurate, and up-to-date set of construction plans, drawings, and specifications on site at all times. g. Contractor has examined all available records and made field examinations of the site of the Construction Project. Contractor has knowledge of the field conditions to be encountered during the Construction Project. Contractor has knowledge of the types and character of equipment necessary for the work, the types of materials needed and the sources of such materials, and the condition of the local labor market. h. Contractor is responsible for the safety of the work and shall maintain all lights, guards, signs, temporary passages, or other protections necessary for that purpose at all times. i. All work must be performed at Contractor’s risk, and Contractor shall promptly repair or replace all damage and loss at its sole cost and expense regardless of the reason or cause of the damage or loss; provided, however, should the damage or loss be Construction Agreement for __________ FY2020-2021 Page 5 of 16 caused by an intentional or negligent act of the City, the risk of such loss shall be placed on the City. j. Contractor is responsible for any loss or damage to materials, tools, or other articles used or held for use in the completion of performance of the Construction Project. k. Contractor’s performance must be without damage or disruption to any other work or property of the City or of others and without interference with the operation of existing machinery or equipment. l. Title to all work, materials, and equipment covered by any payment of Contractor’s compensation by City, whether directly incorporated into the Construction Project or not, passes to City at the time of payment, free and clear of all liens and encumbrances. 10. Delays and Extensions of Time: If Contractor’s performance of this Agreement is prevented or delayed by any unforeseen cause beyond the control of the Contractor, including acts or omissions of the City, Contractor shall, within ten (10) days of the commencement of any such delay, give the City written notice thereof. Further, Contractor shall, within ten (10) days of the termination of such delay, give the City written notice of the total actual duration of the delay. If the City is provided with these required notices and if the City determines that the cause of the delay was not foreseeable, was beyond the control of the Contractor, and was not a result of the fault or negligence of the Contractor, then the City will determine the total duration of the delay and extend the time for performance of the Agreement accordingly. Unless the delay is caused by the intentional interference of the City with the Contractor’s performance, Contractor shall make no claim for damages or any other claim other than for an extension of time as herein provided by reason of any delays. 11. Suspension: a. The City may, by written notice to the Contractor and at its convenience for any reason, suspend the performance of all or any portion of the work to be performed on the Construction Project (“Notice of Suspension”). The Notice of Suspension shall set forth the time of suspension, if then known to the City. During the period of suspension, Contractor shall use its best efforts to minimize costs associated with the suspension. b. Upon Contractor’s receipt of any Notice of Suspension, unless the notice requires otherwise, Contractor shall: (1) immediately discontinue work on the date and to the extent specified in the Notice of Suspension; (2) place no further orders or subcontracts for materials, services, or equipment; (3) promptly make every reasonable effort to obtain suspension upon terms satisfactory to City of all orders, subcontracts, and rental agreements to the extent that they relate to the performance of the work suspended; and (4) continue to protect and maintain the Project, including those portions on which work has been suspended. Construction Agreement for __________ FY2020-2021 Page 6 of 16 c. As compensation for the suspended work, Contractor will be reimbursed for the following costs, reasonably incurred, without duplication of any item, and to the extent that such costs directly resulted from the suspension: (1) a standby charge paid during the period of suspension which will be sufficient to compensate Contractor for keeping, to the extent required in the Notice of Suspension, Contractor’s organization and equipment committed to the Project in standby status; (2) all reasonably incurred costs for the demobilization of Contractor’s and subcontractor’s crews and equipment; (3) an equitable amount to reimburse Contractor for the cost to protect and maintain the Project during the period of suspension; and (4) an equitable adjustment in the cost of performing the remaining portion of the work post-suspension if, as a direct result of the suspension, the cost to Contractor of subsequently performing the remaining work on the Construction Project has increased or decreased. d. Upon receipt of written notice by the City to resume the suspended work (“Notice to Resume Work”), Contractor shall immediately resume performance of the suspended work as to the extent required in the Notice to Resume Work. Any claim by Contractor for time or compensation described in Section 11(c) shall be made within fifteen (15) days after receipt of the Notice to Resume Work and Contractor shall submit a revised Construction Schedule for the City’s review and approval. Contractor’s failure to timely make such a claim shall result in a waiver of the claim. e. No compensation described in Section 11(c) shall be paid and no extension of time to complete the Construction Project shall be granted if the suspension results from Contractor’s non-compliance with or breach of the terms or requirements of this Agreement. 12. Termination for Contractor’s Fault: a. If Contractor refuses or fails to timely do the work, or any part thereof, or fails to perform any of its obligations under this Agreement, or otherwise breaches any terms or conditions of this Agreement, the City may, by written notice, terminate this Agreement and the Contractor’s right to proceed with all or any part of the Construction Project (“Termination Notice Due to Contractor’s Fault”). The City may then take over the Construction Project and complete it, either with its own resources or by re-letting the contract to any other third party, and may immediately take possession of and use such materials, appliances, tools, and equipment as may be on the site and which may be necessary for the completion of the Construction Project. b. In the event of a termination pursuant to this Section 12, Contractor shall be entitled to payment only for those services Contractor actually rendered. In the case of a lump sum or unit price contract, Contractor shall not be entitled to any further payment until the Construction Project has been completed. Upon completion of the Construction Project, if the unpaid balance of the Contractor’s compensation exceeds the cost to the City of completing the work, including all costs paid to any subcontractors or third parties retained by the City to complete the Construction Project and all administrative costs resulting from the termination (“City’s Cost for Completion”), such excess shall be paid to Construction Agreement for __________ FY2020-2021 Page 7 of 16 the Contractor. If the City’s Cost for Completion exceeds the unpaid balance of the Contractor’s compensation, then Contractor and its sureties shall be liable for and shall pay the difference, plus interest at the rate applicable to court judgments, to the City. c. Any termination provided for by this Section 12 shall be in addition to any other remedies to which the City may be entitled under the law or at equity. d. In the event of termination under this Section 12, Contractor shall, under no circumstances, be entitled to claim or recover consequential, special, punitive, lost business opportunity, lost productivity, field office overhead, general conditions costs, or lost profits damages of any nature arising, or claimed to have arisen, as a result of the termination. 13. Termination for City’s Convenience: a. Should conditions arise which, in the sole opinion and discretion of the City, make it advisable to the City to cease work on the Construction Project, the City may terminate this Agreement by written notice to Contractor (“Notice of Termination for City’s Convenience”). The termination shall be effective in the manner specified in the Notice of Termination for City’s Convenience and shall be without prejudice to any claims that the City may otherwise have against Contractor. b. Upon receipt of the Notice of Termination for City’s Convenience, unless otherwise directed in the Notice, the Contractor shall immediately cease work on the Construction Project, discontinue placing orders for materials, supplies, and equipment for the Construction Project, and make every reasonable effort to cancel all existing orders or contracts upon terms satisfactory to the City. Contractor shall do only such work as may be necessary to preserve, protect, and maintain work already completed, in progress, or in transit to the construction site. c. In the event of a termination pursuant to this Section 13, Contractor is entitled to payment only for those services Contractor actually rendered and materials actually purchased or which Contractor has made obligations to purchase on or before the receipt of the Notice of Termination for City’s Convenience, and reasonably incurred costs for demobilization of Contractor’s and any subcontractor’s crews. It is agreed that any materials that City is obligated to purchase from Contractor will remain the City’s sole property. d. The compensation described in Section 13(c) is the sole compensation due to Contractor for its performance of this Agreement. Contractor shall, under no circumstances, be entitled to claim or recover consequential, special, punitive, lost business opportunity, lost productivity, field office overhead, general conditions costs, or lost profits damages of any nature arising, or claimed to have arisen, as a result of the termination. Construction Agreement for __________ FY2020-2021 Page 8 of 16 14. Limitation on Contractor’s Damages; Time for Asserting Claim: a. In the event of a claim for damages by Contractor under this Agreement, Contractor’s damages shall be limited to contract damages and Contractor hereby expressly waives any right to claim or recover consequential, special, punitive, lost business opportunity, lost productivity, field office overhead, general conditions costs, or lost profits damages of any nature or kind. b. In the event Contractor wants to assert a claim for damages of any kind or nature, Contractor shall provide City with written notice of its claim, the facts and circumstances surrounding and giving rise to the claim, and the total amount of damages sought by the claim, within ten (10) days of the facts and circumstances giving rise to the claim. In the event Contractor fails to provide such notice, Contractor shall waive all rights to assert such claim. 15. Representatives and Notices: a. City’s Representative: The City’s Representative for the purpose of this Agreement shall be _____________________or such other individual as City shall designate in writing. Whenever approval or authorization from or communication or submission to City is required by this Agreement, such communication or submission shall be directed to the City’s Representative and approvals or authorizations shall be issued only by such Representative; provided, however, that in exigent circumstances when City’s Representative is not available, Contractor may direct its communication or submission to other designated City personnel or agents and may receive approvals or authorization from such persons. b. Contractor’s Representative: The Contractor’s Representative for the purpose of this Agreement shall be ________________ or such other individual as Contractor shall designate in writing. Whenever direction to or communication with Contractor is required by this Agreement, such direction or communication shall be directed to Contractor’s Representative; provided, however, that in exigent circumstances when Contractor’s Representative is not available, City may direct its direction or communication to other designated Contractor personnel or agents. c. Notices: All notices required by this Agreement shall be in writing and shall be provided to the Representatives named in this Section. Notices shall be deemed given when delivered, if delivered by courier to Party’s address shown above during normal business hours of the recipient; or when sent, if sent by email or fax (with a successful transmission report) to the email address or fax number provided by the Party’s Representative; or on the fifth business day following mailing, if mailed by ordinary mail to the address shown above, postage prepaid. Construction Agreement for __________ FY2020-2021 Page 9 of 16 16. Locating Underground Facilities: Contractor shall be responsible for obtaining and determining the location of any underground facilities, including but not limited to, the location of any pipelines or utility supply, delivery, or service lines in accordance with the provisions of §69-4-501, et seq., Montana Code Annotated (MCA). Contractor shall make every effort to avoid damage to underground facilities and shall be solely responsible for any damage that may occur. If City personnel assume responsibility for locating any underground facilities, this fact shall be noted in writing prior to commencement of such location work. 17. Permits: Contractor shall provide all notices, comply with all applicable laws, ordinances, rules, and regulations, obtain all necessary permits, licenses, including a City of Bozeman business license, and inspections from applicable governmental authorities, pay all fees and charges in connection therewith, and perform all surveys and locations necessary for the timely completion of the Construction Project. 18. Ownership of Documents; Indemnification: All plans, designs, drawings, specifications, documents, sample results and data, in whatever medium or format, originated or prepared by or for Contractor in contemplation of, or in the course of, or as a result of this Agreement or work on the Construction Project, shall be promptly furnished to the City (“City Documents and Information”). All City Documents and Information shall be the exclusive property of the City and shall be deemed to be works-for-hire. Contractor hereby assigns all right, title, and interest in and to the City Documents and Information, including but not limited to, all copyright and patent rights in and to the City Documents and Information. Neither party grants to the other any express or implied licenses under any patents, copyrights, trademarks, or other intellectual property rights, except to the extent necessary to complete its obligations to the other under this Agreement. 19. Laws and Regulations: Contractor shall comply fully with all applicable state and federal laws, regulations, and municipal ordinances including, but not limited to, all workers’ compensation laws, all environmental laws including, but not limited to, the generation and disposal of hazardous waste, the Occupational Safety and Health Act (OSHA), the safety rules, codes, and provisions of the Montana Safety Act in Title 50, Chapter 71, MCA, all applicable City, County, and State building and electrical codes, the Americans with Disabilities Act, and all non- discrimination, affirmative action, and utilization of minority and small business statutes and regulations. 20. Nondiscrimination and Equal Pay: The Contractor agrees that all hiring by Contractor of persons performing this Agreement shall be on the basis of merit and qualifications. The Contractor will have a policy to provide equal employment opportunity in accordance with all applicable state and federal anti-discrimination laws, regulations, and contracts. The Contractor will not refuse employment to a person, bar a person from employment, or discriminate against a person in compensation or in a term, condition, or privilege of employment because of race, color, religion, creed, political ideas, sex, age, marital status, national origin, actual or perceived sexual orientation, gender identity, physical or mental disability, except when the reasonable demands of the position require an age, physical or mental disability, marital status or sex distinction. The Construction Agreement for __________ FY2020-2021 Page 10 of 16 Contractor shall be subject to and comply with Title VI of the Civil Rights Act of 1964; Section 140, Title 2, United States Code, and all regulations promulgated thereunder. Contractor represents it is, and for the term of this Agreement will be, in compliance with the requirements of the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act). Contractor must report to the City any violations of the Montana Equal Pay Act that Contractor has been found guilty of within 60 days of such finding for violations occurring during the term of this Agreement. Contractor shall require these nondiscrimination terms of its subcontractors providing services under this Agreement. 21. Intoxicants; DOT Drug and Alcohol Regulations: Contractor shall not permit or suffer the introduction or use of any intoxicants, including alcohol or illegal drugs, upon the site of the Construction Project. Contractor acknowledges it is aware of and shall comply with its responsibilities and obligations under the U.S. Department of Transportation (DOT) regulations governing anti-drug and alcohol misuse prevention plans and related testing. City shall have the right to request proof of such compliance and Contractor shall be obligated to furnish such proof. The Contractor shall be responsible for instructing and training the Contractor's employees and agents in proper and specified work methods and procedures. The Contractor shall provide continuous inspection and supervision of the work performed. The Contractor is responsible for instructing its employees and agents in safe work practices. 22. Labor Relations: a. In the event that, during the term of this Agreement and throughout the course of Contractor’s performance of the Construction Project, any labor problems or disputes of any type arise or materialize which in turn cause any work on the Construction Project to cease for any period of time, Contractor specifically agrees to take immediate steps, at its own expense and without expectation of reimbursement from City, to alleviate or resolve all such labor problems or disputes. The specific steps Contractor shall take to resume work on the Construction Project shall be left to the discretion of Contractor; provided, however, that Contractor shall bear all costs of any related legal action. Contractor shall provide immediate relief to the City so as to permit the work on the Construction Project to resume and be completed within the time frames set forth in the Construction Schedule at no additional cost to City. b. Contractor shall indemnify, defend, and hold the City harmless from any and all claims, demands, costs, expenses, damages, and liabilities arising out of, resulting from, or occurring in connection with any labor problems or disputes or any delays or stoppages of work associated with such problems or disputes. Construction Agreement for __________ FY2020-2021 Page 11 of 16 23. Subcontractors: a. Contractor may employ subcontractors for any work on the Construction Project. Contractor shall provide City with a list of all subcontractors employed. b. Contractor remains fully responsible for the acts and omissions of any subcontractor, just as Contractor is for its own acts and omissions, and Contractor shall remain fully responsible and liable for the timely completion of the Construction Project. c. Contractor is solely liable for any and all payments to subcontractors. Contractor shall hold all payments received from the City in trust for the benefit of subcontractors, and all such payments shall be used to satisfy obligations of the Construction Project before being used for any other purpose. Contractor shall make any payments due to any subcontractor within seven (7) days of Contractor’s receipt of payment, including a proportional part of the retainage Contractor has received from the City. In the event of a dispute regarding any subcontractor’s invoice, Contractor shall promptly pay the undisputed amount to the subcontractor and notify the subcontractor in writing of the amount in dispute and the reasons for the dispute. Any withholding of payment must comply with the requirements of §28-2-2103, MCA. In the event Contractor is unwilling or unable to make timely and proper payment to any subcontractor, City may elect to withhold any payment otherwise due to Contractor and upon seven (7) days’ written notice to Contractor, may pay subcontractor by direct or joint payment. 24. Indebtedness and Liens: Before City may make any final payment to Contractor, Contractor shall furnish City with satisfactory proof that there are no outstanding debts or liens in connection with the Construction Project. If the Contractor allows any indebtedness to accrue to subcontractors or others during the progress of the work, and fails to pay or discharge the same within five (5) days after demand, then City may either withhold any money due to Contractor until such indebtedness is paid or apply the same towards the discharge of the indebtedness. If any lien or claim is filed or made by any subcontractor, material supplier, or any other person, the Contractor shall immediately notify the City and shall cause the same to be discharged of record within thirty (30) days after its filing. 25. Hazard Communication: Contractor shall comply with all hazard communication requirements dictated by the Environmental Protection Agency, the Montana Department of Agriculture, OSHA, Hazard Communications Standard, 29 CFR 1910.1200, and applicable City ordinances. Contractor shall supply a chemical list, the associated material safety data sheets (MSDS), and other pertinent health exposure data for chemicals that the Contractor’s, subcontractor’s or the City’s employees may be exposed to while working on City property during the course of the Construction Project. One copy of this documentation must be delivered to City to the attention of the City’s Representative. This documentation must be delivered before work involving these chemicals may commence. 26. Accounts and Records: During the term of this Agreement and for two (2) years following the City’s final acceptance of the Construction Project, Contractor shall maintain accounts and records related to the Construction Project. Upon reasonable notice, City shall have Construction Agreement for __________ FY2020-2021 Page 12 of 16 the right to inspect all such accounts and records, including but not limited to, Contractor’s records, books, correspondence, instructions, drawings, specifications, field and site notes, receipts, invoices, bills, contracts, or other documents relating to the Construction Project. 27. Indemnification; Insurance; Bonds: a. Contractor agrees to release, defend, indemnify, and hold harmless the City, its agents, representatives, employees, and officers (collectively referred to for purposes of this Section as the City) from and against any and all claims, demands, actions, fees and costs (including attorney’s fees and the costs and fees of and expert witness and consultants), losses, expenses, liabilities (including liability where activity is inherently or intrinsically dangerous) or damages of whatever kind or nature connected therewith and without limit and without regard to the cause or causes thereof or the negligence of any party or parties that may be asserted against, recovered from or suffered by the City occasioned by, growing or arising out of or resulting from or in any way related to: (i) the negligent, reckless, or intentional misconduct of the Contractor; or (ii) any negligent, reckless, or intentional misconduct of any of the Contractor’s agents. b. Such obligations shall not be construed to negate, abridge, or reduce other rights or obligations of indemnity that would otherwise exist. The indemnification obligations of this Section must not be construed to negate, abridge, or reduce any common-law or statutory rights of the indemnitee(s) which would otherwise exist as to such indemnitee(s). c. Contractor’s indemnity under this Section shall be without regard to and without any right to contribution from any insurance maintained by City. d. Should the City be required to bring an action against the Contractor to assert its right to defense or indemnification under this Agreement or under the Contractor’s applicable insurance policies required below the City shall be entitled to recover reasonable costs and attorney fees incurred in asserting its right to indemnification or defense but only if a court of competent jurisdiction determines the Contractor was obligated to defend the claim(s) or was obligated to indemnify the City for a claim(s) or any portion(s) thereof. e. In the event of an action filed against the City resulting from the City’s performance under this Agreement, the City may elect to represent itself and incur all costs and expenses of suit. f. Contractor also waives any and all claims and recourse against the City, including the right of contribution for loss or damage to person or property arising from, growing out of, or in any way connected with or incident to the performance of this Agreement except “responsibility for [City’s] own fraud, for willful injury to the person or property of another, or for violation of law, whether willful or negligent” as per 28-2-702, MCA. Construction Agreement for __________ FY2020-2021 Page 13 of 16 g. These obligations shall survive termination of this Agreement and the services performed hereunder. h. In addition to and independent from the above, Contractor shall at Contractor’s expense secure insurance coverage through an insurance company or companies duly licensed and authorized to conduct insurance business in Montana which insures the liabilities and obligations specifically assumed by the Contractor in this Section. The insurance coverage shall not contain any exclusion for liabilities specifically assumed by the Contractor in subsection (a) of this Section. The insurance shall cover and apply to all claims, demands, suits, damages, losses, and expenses that may be asserted or claimed against, recovered from, or suffered by the City without limit and without regard to the cause therefore and which is acceptable to the City. Contractor shall furnish to the City an accompanying certificate of insurance and accompanying endorsements in amounts not less than as shown below:  Workers’ Compensation – not less than statutory limits;  Employers’ Liability - $1,000,000 per occurrence; $2,000,000 annual aggregate;  Commercial General Liability - $1,000,000 per occurrence; $2,000,000 annual aggregate;  Products and Completed Operations – $1,000,000;  Automobile Liability - $1,000,000 property damage/bodily injury; $2,000,000 annual aggregate (all owned, hired, non-owned vehicles);  Builder’s Risk/Property Insurance at least as broad as that provided by the ISO special causes of loss form (CP10 30) naming at a minimum the City in an amount equal to greater of Contractor’s compensation or full replacement value of the work (covering at a minimum all work, buildings, materials and equipment, whether on site or in transit, loss due to fire, lightening, theft, vandalism, malicious mischief, earthquake, collapse, debris removal, demolition occasioned by enforcement of laws, water damage, flood if site within a flood plain, repair or replacement costs, testing and start-up costs) on an all risk coverage basis. This insurance must include waivers of subrogation between the City and Contractor to the extent that damage to the Construction Project or City Hall is covered by other insurance;  Owner’s and Contractor’s Protective Liability: one policy designating the City (including its agents, representatives, employees, and officers) as the insured and another independent policy designated the City’s Representative (including its consultants, consultants, agents and employees) as the insured on the declarations with both policies covering: (i) operations performed by the Contractor under this Agreement for the City; and (ii) the City’s and City’s Representatives acts or omissions, including negligent acts, in connection with its general supervision of the work of the Contractor’s and its subcontractors - $1,000,000 per occurrence; $2,000,000 aggregate;  Contractual Liability Insurance (covering the Contractor’s indemnity obligations described in this Agreement) - $1,000,000 per occurrence $2,000,000 aggregate Construction Agreement for __________ FY2020-2021 Page 14 of 16 The amounts of insurance provided shall be exclusive of defense costs. The City of Bozeman shall be endorsed as an additional or named insured on a primary non- contributory basis on both the Commercial General and Automobile Liability policies. The insurance and required endorsements must be in a form suitable to City and shall include no less than a thirty (30) day notice of cancellation or non-renewal. Contractor shall notify City within two (2) business days of Contractor’s receipt of notice that any required insurance coverage will be terminated or Contractor’s decision to terminate any required insurance coverage for any reason. The City must approve all insurance coverage and endorsements prior to the Contractor commencing work. i. Pursuant to the City’s authority provided for in 18-2-201(4), the Contractor shall not be required to provide bonds as required by 18-2-201(1) under this Agreement. 28. Taxes: Contractor is obligated to pay all taxes of any kind or nature and make all appropriate employee withholdings. Contractor understands that all contractors or subcontractors working on a publicly funded project are required to pay or have withheld from earnings a license fee of one percent (1%) of the gross contract price if the gross contract price is Five Thousand Dollars ($5,000) or more. This license fee is paid to the Montana Department of Revenue. 29. Dispute Resolution: a. Any claim, controversy, or dispute between the parties, their agents, employees, or representatives shall be resolved first by negotiation between senior-level personnel from each party duly authorized to execute settlement agreements. Upon mutual agreement of the parties, the parties may invite an independent, disinterested mediator to assist in the negotiated settlement discussions. b. If the parties are unable to resolve the dispute within thirty (30) days from the date the dispute was first raised, then such dispute shall be resolved in a court of competent jurisdiction in compliance with the Applicable Law provisions of this Agreement. 30. Survival: Contractor’s indemnification and warranty obligations shall survive the termination or expiration of this Agreement for the maximum period allowed under applicable law. 31. Headings: The headings used in this Agreement are for convenience only and are not be construed as a part of the Agreement or as a limitation on the scope of the particular paragraphs to which they refer. 32. Waiver: A waiver by City of any default or breach by Contractor of any covenants, terms, or conditions of this Agreement does not limit City’s right to enforce such covenants, terms, or conditions or to pursue City’s rights in the event of any subsequent default or breach. Construction Agreement for __________ FY2020-2021 Page 15 of 16 33. Attorney’s Fees and Costs: In the event it becomes necessary for either Party to retain an attorney to enforce any of the terms or conditions of this Agreement or to give any notice required herein, then the prevailing Party or the Party giving notice shall be entitled to reasonable attorney's fees and costs, including fees, salary, and costs of in-house counsel including the City Attorney’s Office staff. 34. Severability: If any portion of this Agreement is held to be void or unenforceable, the balance thereof shall continue in effect. 35. Applicable Law: The parties agree that this Agreement is governed in all respects by the laws of the State of Montana. 36. Binding Effect: This Agreement is binding upon and inures to the benefit of the heirs, legal representatives, successors, and assigns of the parties. 37. Amendments: This Agreement may not be modified, amended, or changed in any respect except by a written document signed by all parties. 38. No Third-Party Beneficiary: This Agreement is for the exclusive benefit of the parties, does not constitute a third-party beneficiary agreement, and may not be relied upon or enforced by a third party. 38. Counterparts: This Agreement may be executed in counterparts, which together constitute one instrument. 39. Assignment: Contractor may not assign this Agreement in whole or in part without the prior written consent of the City. No assignment will relieve Contractor of its responsibility for the performance of the Agreement and the completion of the Construction Project. Contractor may not assign to any third party other than Contractor’s subcontractors on the Construction Project, the right to receive monies due from City without the prior written consent of City. 40. Authority: Each party represents that it has full power and authority to enter into and perform this Agreement and the person signing this Agreement on behalf of each party has been properly authorized and empowered to sign this Agreement. 41. Independent Contractor: The parties agree and acknowledge that in the performance of this Agreement and the completion of the Construction Project, Contractor shall render services as an independent contractor and not as the agent, representative, subcontractor, or employee of the City. The parties further agree that all individuals and companies retained by Contractor at all times will be considered the agents, employees, or independent contractors of Contractor and at no time will they be the employees, agents, or representatives of the City. 42. Integration: This Agreement and all Exhibits attached hereto constitute the entire agreement of the parties. Covenants or representations not contained therein or made a part thereof by reference, are not binding upon the parties. There are no understandings between the parties Construction Agreement for __________ FY2020-2021 Page 16 of 16 other than as set forth in this Agreement. All communications, either verbal or written, made prior to the date of this Agreement are hereby abrogated and withdrawn unless specifically made a part of this Agreement by reference. 43. Consent to Electronic Signatures: The Parties have consented to execute this Agreement electronically in conformance with the Montana Uniform Electronic Transactions Act, Title 30, Chapter 18, Part 1, MCA. **** END OF AGREEMENT EXCEPT FOR SIGNATURES **** IN WITNESS WHEREOF, Contractor and City have caused this Agreement to be executed, effective on the date written above, and intend to be legally bound thereby. CITY OF BOZEMAN, MONTANA CONTRACTOR By: _______________________________ By: Jeff Mihelich, City Manager Print Name: Title: APPROVED AS TO FORM: By: _______________________________ Greg Sullivan, City Attorney EXHIBIT C © OTIS ELEVATOR COMPANY, 2011 All Rights Reserved Proposal# QTE-001666948 Page 1 of 9 OTIS MODERNIZATION DATE:August 15, 2023 TO: FROM: Mike Gray 20 E Olive Bozeman, MT 59715 PROJECT LOCATION: Bozeman Professional Buildin 20 E Olive Bozeman, MT 59715 PROPOSAL NUMBER: QTE-001666948 Otis Elevator Company E. 510 North Foothills Dr. Spokane, WA 99207 Gregory Norris Phone: (406) 890-9054 Fax: (509) 545-2919 MACHINE NUMBER(S): 812469 Otis Hydro Accel We propose to furnish labor and material to provide a hydraulic microprocessor-based control system. It is specifically designed to meet the particular needs of modernizing hydraulic elevators. The system is integrated by communications over serial links and discrete wiring. The "Relative System Response Plus" software dispatches elevators based upon real-time response to actual demands on the elevator(s). Duty / Travel 2000# / 125 fpm Stops / Openings 3 / 3 Power Unit (Tank, Motor, Pump, Muffler and Valve) New Control Systems New – Microprocessor Start Configuration New Solid State Starter Emergency Operation Upgraded to Current Code Pit Stop Switch New © OTIS ELEVATOR COMPANY, 2011 All Rights Reserved Proposal# QTE-001666948 Page 2 of 9 OTIS MODERNIZATION Hoistway Access Switches or Lunar Key Access New, as prescribed by code Top of Car Inspection Station New Car Operating Panel New Fixtures Communications New ADA Phone Integral with COP Car Position Indicator (car) New Digital Car Position Indicator in COP Braille New on COP and Entrances Floor Passing Chime New, ADA compliant Emergency Lighting New 6 volt system Hall Station Buttons New Fixtures In-Car Lantern New In Car Lanterns to Indicate Direction of Travel Car Guides Retain Car Frame Retain Door Operator New Closed Loop Door Operator Interlocks Refurbish Door Restrictors New Code Compliant Restrictors Door Protection New Door Detector Car Door Tracks, Hangers Retain Car Door Retain Hoistway Door Tracks, Hangers Retain Hoistway Doors Retain © OTIS ELEVATOR COMPANY, 2011 All Rights Reserved Proposal# QTE-001666948 Page 3 of 9 OTIS MODERNIZATION Hoistway Door Closers Retain Hoistway Limit Switches Retain Traveling Cables New Hoistway Wire New Signage New New Car Door Relation Included Toe Guards New Code Compliant as Needed Seismic Rupture Valve New Maintenance Per Existing Maintenance Agreement (alt. to be supplied separately) Emergency power (ERU) Alternate 1 Cab Interior Finishes Alternate 2 Cab Air Purifier (new fan included)Alternate 3 © OTIS ELEVATOR COMPANY, 2011 All Rights Reserved Proposal# QTE-001666948 Page 4 of 9 OTIS MODERNIZATION MODERNIZATION DEFINITIONS PAGE Retain Equipment will be retained in the same working order currently found when the project was accepted. Any problems with this equipment while completing the modernization will require a change order to repair Refurbish “As New” Equipment will be cleaned, adjusted and repaired as necessary during the Modernization process Refurbish “As Needed” Same as Refurbish “As New”, but at the elevator Contractor’s discretion. New Completely new units to replace the existing will be installed as part of the modernization. These units may be identical to the existing or replacements from different manufactures unless listed. By Others This work is to be completed by contractors other than the Elevator contractor. The work must be completed, scheduled, and paid for by the building management. This work must be scheduled with the elevator contractor and must be completed before inspections on the modernized elevators can be completed. WORK BY OTHERS (NOT INCLUDED IN CONTRACT PRICE) Main Line Power Feeders The current main line piping and wiring from the disconnect to the new controller location May need to be relocated to accommodate the new controllers. A ground wire must be added if it does not already exist. Cab Lighting A single 110 circuit must be run to each controller. This circuit must be run through a disconnect or switch that is lockable in the on or off position. The location of this switch must be coordinated with the elevator mechanic on site. GFI Outlets All Outlets in the machine room and/or the pits must be retrofitted with GFI outlets per code. Light Guards All lighting in the machine room and/or the pit must be retrofitted with code compliant guards made of either grounded metal, plastic or comparable. Phone Code requires a single phone line per elevator to be run in conduit to each controller. This line must be a normal dial tone outside line. Unless otherwise agreed upon by the elevator contractor. Disconnects The main power elevator disconnects must be code compliant, fused or breakers, and must be lockable in the off positions. The disconnects must be located within clear site of each elevator motor. Fire Recall Combined with the modernization main floor and Alternate floor fire recall will be required. Smoke detectors must be installed if not currently operating, at every lobby, the machine room, and the hoistway (if sprinklers are present). Smoke detectors in the hoistway must be mounted on an access panel that is serviceable from the outside of the hoistway. This panel must be no greater than 2’ x 2’. © OTIS ELEVATOR COMPANY, 2011 All Rights Reserved Proposal# QTE-001666948 Page 5 of 9 OTIS MODERNIZATION Shunt trip Disconnect If sprinklers are altered or installed in the machine room and or the hoistway as part of the modernization, a heat detector must be installed within 18” of every sprinkler head in the machine room and the hoistway overhead. These heat detectors must activate a shunt trip disconnect located outside the elevator machine room, to remove all of the three phase elevator power prior to the power entering the machine room. Cutting and Patching Any cutting and patching required for the installation of this equipment, including but not limited to cutting walls for installation of new fixtures. Pit Ladder If not included in proposal. Add $750/ladder to contract price if Otis is to provide. Modifications to Machine Room Including but not limited to the following: x Machine room door must be self closing and self locking x Adequate lighting and proper location in machine room. x GFI outlets x Light Guards x Disconnects x Phone lines x 110 v cab lighting circuits and disconnects x Pit ladder x Pit Lighting and GFI x Sprinklers x Smoke detectors, heat detectors x Shunt Trip Disconnects x Ledges in hoistway x Windows in Hoistway x Vents in hoistway x Temperature control in machine room