Loading...
HomeMy WebLinkAboutRFQ - Special Inspections - Library Renovation and Fire Station 2 ConstructionPage 1 of 13 REQUEST FOR QUALIFICATIONS (RFQ) SPECIAL INSPECTIONS AND MATERIALS TESTING BOZEMAN PUBLIC LIBRARY RENOVATION AND FIRE STATION 2 CONSTRUCTION CITY OF BOZEMAN Bozeman, MT City of Bozeman PO Box 1230 Bozeman, MT 59771-1230 FEBRUARY 2023 Page 2 of 13 NOTICE IS HEREBY given that the City of Bozeman (City) is seeking qualifications from firms to perform Special Inspection and Materials Testing Services for both the Bozeman Public Library Renovation and the construction of the new Fire Station 2. Copies of the Request for Qualifications are available on the City’s website All proposals must be provided as a single, searchable PDF document file and be submitted digitally as an email attachment to the RFQ Recipient email address below. Respondents are advised that Recipient’s email attachment size limit is 25MB and that only one PDF file will be allowed per response. The subject line of the transmittal email shall clearly identify the RFQ title, company name and due date/time. File sizes greater than 25MB in size may be uploaded to bzncloud.bozeman.net upon special arrangement of the Recipient; however, it is the respondent’s sole responsibility to ensure the file upload is completed, and that the Recipient is separately notified via email of same, prior to the given deadline. Deliver RFQs via email to the City Clerk by March 9 at 2:00 PM MST It is the sole responsibility of the proposing party to ensure that proposals are received prior to the closing time as late submittals will not be accepted and will be returned unopened. The email address for submission is: agenda@bozeman.net NON-DISCRIMINATION AND EQUAL PAY The City of Bozeman is an Equal Opportunity Employer. Discrimination in the performance of any agreement awarded under this RFQ on the basis of race, color, religion, creed, sex, age, marital status, national origin, or actual or perceived sexual orientation, gender identity or disability is prohibited. This prohibition shall apply to the hiring and treatment of the awarded entity’s employees and to all subcontracts. As such, each entity submitting under this notice shall include a provision wherein the submitting entity, or entities, affirms in writing it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, gender identity or disability and which also recognizes the eventual contract will contain a provision prohibiting discrimination as described above and that this prohibition on discrimination shall apply to the hiring and treatment of the submitting entity’s employees and to all subcontracts. In addition, pursuant to City Commission Resolution 5169, the entity awarded a contract under this RFQ and any subcontractors must abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and affirm it will abide by the above and that it has visited the State of Montana Equal Pay for Equal Work “best practices” website, or equivalent “best practices publication and has read the material. Failure to comply with the above may be cause for the City to deem the submittal non-responsive. Any administrative questions regarding proposal procedures should be directed to: Mike Maas, City Clerk (406) 582-2321, agenda@bozeman.net. Questions relating to the RFQ should be directed to: Max Ziegler, Facilities Project Coordinator, (406) 582- 2439, wziegler@bozeman.net. DATED at Bozeman, Montana, this February 12th 2023. Mike Maas City Clerk City of Bozeman For publication on: Sunday, February 12, 2023 Sunday, February 26, 2023 I. INTRODUCTION The City of Bozeman (Owner), is seeking qualifications from firms to undertake Construction Material Testing and Special Inspections. The Owner intends to enter into contracts with the selected firm that will include providing Special Inspection and Materials Testing Services for both the Bozeman Public Library Renovation and the construction of the new Fire Station 2. This RFQ shall not commit the Owner to enter into an agreement, to pay any expenses incurred in preparation of any response to this request, or to procure or contract for any supplies, goods or services. The Owner reserves the right to accept or reject all responses received as a result of this RFQ if it is in the Owner’s best interest to do so. This procurement is governed by the laws of the State of Montana and venue for all legal proceedings shall be in the 18th Judicial District Court, Gallatin County. By offering to perform services under this RFQ, all Submitters agree to be bound by the laws of the State of Montana and of the Owner, including, but not limited to, applicable wage rates, payments, gross receipts taxes, building codes, equal opportunity employment practices, safety, non-discrimination, etc. II. SCOPE OF PROJECT - PROJECT BACKGROUND AND DESCRIPTION Introduction The City of Bozeman is currently underway on on a renovation of the Bozeman Public Library, and is preparing to break ground on a replacement for the City’s Fire Station #2 which is to be constructed on the Montanta State University campus off of West Kagy Ave. The internal renovation of the Bozeman Public Library includes the reconfiguration of a number of rooms in the building as well as the replacement of aging finishes and fixtures, including the installation of new entry vestibules. The project team includes the City of Bozeman (Owner), MSR Architects (Architect), and Martel Construction (General Contractor/Construction Manager). Construction of Fire Station #2 is a greenfield new construction project expected to break ground in April 2023. The fire station will be located on the south end of the Montana State University Campus, off of Kagy Ave, and will provide fire and EMS response from that location. The project team includes the City of Bozeman (Owner), ThinkOne Architects (Architect) and Martel Construction (General Contractor/Construction Manager). The Owner is soliciting special inspection and materials testing services from a qualified engineering firm as required by the IBC on both the Library Renovation and the construction of Fire Station #2. The successful firm will work directly for the Owner to ensure these elements and work performed at the site meet the applicable code requirements. III. SCOPE OF SERVICES Release of this RFQ with the preliminary scope of services contained herein does not commit the City to contracting with a selected firm for all scope items identified. For purposes of this RFQ the term ‘selected firm’ can mean a single engineering consulting firm, or a prime engineering consulting firm together with sub-consultant engineering firm(s) forming a respondent team. The preliminary scope of work involved for this project is outlined below. The City desires for the scope of work to be completed in a diligent manner. Additional tasks and work elements may be inserted into the scope of work during contract negotiations with the selected firm. It is also possible that tasks or elements could be removed during negotiations or not included in an initial contract because of regulatory uncertainty, budget limitations, contracting strategy or any combination thereof. In its proposal, a firm may recommend addition/deletion of tasks and/or modification of tasks in describing its particular understanding and approach for the project. Proposals must clearly identify any elements of the proposed scope of work that would not be provided by the prime engineering consulting firm. Any sub-consultants which comprise the respondent team must be identified along with a description of past working history between the firms. Bozeman Public Library Renovation SCOPE The Materials Testing Services will generally provide Special Inspections required by the 2018 International Building Code and Materials Testing including, but not limited to: • Testing of soil compaction, structural, below site civil hardscape, utility trenches. • Testing of cast in place concrete strength (shall include, air, slump, unit weight and temp.) for structural concrete and site civil hardscape • Inspection and verification of soils (foundation, foundation backfill, site civil hardscape, and utility trench backfill) • Inspecting structural concrete construction (reinforcing, anchorages, placement, etc.) • Inspection of structural steel construction (bolting, welding, erection, etc.) See sheet S002 of the Construction Documents for additional Special Inspection and Testing requirements (Appendix B). Bozeman Fire Station #2 SCOPE The Materials Testing Services will generally provide Special Inspections required by the 2018 International Building Code and Materials Testing including, but not limited to: • Testing of soil compaction, structural, below site civil hardscape, utility trenches. • Testing of cast in place concrete strength testing (shall include, air, slump, unit weight and temp.) for structural concrete and site civil hardscape • Inspection and verification of soils (foundation, foundation backfill, site civil hardscape, and utility trench backfill) • Inspecting structural concrete construction (reinforcing, anchorages, placement, etc.) • Inspection of structural steel construction (bolting, welding, erection, etc.) • Inspection of steel construction other than structural steel (cold formed metal deck) • Testing of masonry grout (shall include, air, slump, unit weight and temp.) for structural masonry. • Inspecting structural masonry construction (reinforcing, anchorages, placement, etc.) • Inspection of wood construction • Inspection of wood construction for wind resistance • Inspection of wood construction for seismic resistance See sheet S0.2 and S0.3 of the Construction Documents for additional Special Inspection and Testing requirements (Appendix C). IV. TIMELINES, DELIVERY DEADLINE, AND INSTRUCTIONS Deliver RFQs via email to the City Clerk (agenda@bozeman.net) by March 9th, 2023 at 2PM MST. It is the sole responsibility of the proposing party to ensure that proposals are received prior to the closing time as late submittals will not be accepted and will be returned. All proposals must be provided as a single, searchable PDF document file and be submitted digitally as an email attachment to the RFQ Recipient email address agenda@bozeman.net. Respondents are advised that Recipient’s email attachment size limit is 25MB and that only one PDF file will be allowed per response. The subject line of the transmittal email shall clearly identify the RFQ title, company name and due date/time. File sizes greater than 25MB in size may be uploaded to an alternate submission method upon special arrangement of the Recipient; however, it is the respondent’s sole responsibility to ensure the file upload is completed, and that the Recipient is separately notified via email of same, prior to the given deadline. A. Contact Information ALL QUESTIONS AND CONTACTS REGARDING THIS RFQ MUST BE SUBMITTED IN WRITING TO: Max Ziegler – Facilities Project Coordinator P.O. Box 1230 Bozeman, MT 59771-1230 (406) 582-2439 wziegler@bozeman.net Amendments to Solicitation Any interpretation or correction of this request will be published on the City’s webpage. The deadline for questions related to this document is 12:00 PM MST on March 6th, 2023. B. Selection Timeline Advertising dates: February 12 and 26, 2023 Receipt of RFQs: No later than 2:00 p.m. MST March 9th , 2023 RFQ Review Complete by Committee: March 22, 2023 Interviews: March 27, 2023 Selection: March 31, 2023 With the exception of the advertising dates and advertised due date, the City reserves the right to modify the above timeline. V. SELECTION PROCEDURE A. STATEMENT OF QUALIFICATIONS Respondents must comply with the mandatory requirements provided in this solicitation. The selection process shall be conducted pursuant to all applicable Montana law including those criteria set forth in §18-8-204, MCA and applicable City policy. 1. Evaluation of RFQs. The selection committee shall consist of no less than three persons representing the City. The selection committee will review conforming RFQ responses using the criteria listed above. RFQ responses that do not contain the required documentation will be deemed nonresponsive to this solicitation and may be rejected. 2. Revisions. Responses will be accorded fair and equal treatment with respect to opportunity for discussion and revision of responses, and such revisions may be permitted, after submissions and prior to award for the purpose of obtaining best and final responses. 3. Evaluation & Elimination. After evaluating all conforming responses based on the criteria herein the selection committee may eliminate one or more or all Respondents from further review if they do not meet the qualification criteria specified herein. Any Respondents eliminated by the selection committee, at any time, or for any reason, shall have no opportunity to make revisions or participate further in the selection process. 4. Interviews. After reviewing conforming RFQ responses, the selection committee may decide to schedule interviews with qualified respondents. Interviews will be held on March 27, 2023 at the Professional Building, 20 East Olive Street, Bozeman MT 59715. Each firm selected for interview will be notified of the specific time for their interview. The format of the interview will be left up to the proposing firm; however, interviews will be [45] minutes inclusive of questions from the selection committee, with 15 minutes between interviews for transitions and set up between Respondents. 5. Selection and Final Recommendation. The selection committee will tally the scores for the RFQ. At that time contract negotiations will take place between the City and successful Respondent. The City may negotiate a contract with the next highest ranked Respondent if a contract cannot be made. B. RFQ – FORM AND CONTENTS Deliver one (1) digital copy prepared as follows: i. General Instructions: a. RFQ responses must be signed by an officer or principal of your firm. b. RFQ responses must be contained in a single searchable PDF document not to exceed 20 pages total including whatever pictures, charts, graphs, tables, and text the firm deems appropriate to be part of the review of the firm's qualifications. A separate transmittal letter, cover page, cover sheets, and dividers are exempted from the page limit. c. Schedules may be submitted in addition to the page limit. ii. Firm Information: a. Experience. Respondent must demonstrate successful experience and capacity to act as a contractor on projects of similar size, type and complexity. Provide the name and location of each project, the client, and the contact person and phone number. Describe experience and qualifications of the professional personnel to be assigned to this project. Describe your recent and current work for the City of Bozeman, if any. b. Firm Background. Provide information about the firm, including location. Describe the firm’s history. Include information identifying the firm’s annual volume of business, financial/bonding capacities, and speak to the firm’s stability in the marketplace. Information identifying the firm’s strengths and weaknesses along with special capabilities that may be appropriate to the Project will assist in the evaluation. c. Firm Workload. Provide the status of current and anticipated work within the firm in terms of time and magnitude for the anticipated Project schedule as it relates to availability of key personnel and your firm. Describe the firm’s capability to meet time and project budget requirements. d. Claims. At any time in the last ten (10) years has your firm been assessed and paid liquidated damages after completion of a project under a contract with a public owner? e. References. Provide detailed contact information for the Owner for at least five (5) project undertaken by your firm within the past five years. C. EVALUATION CRITERIA Qualifications will be evaluated by the Selection Committee who will individually score them out of a total of 100 possible points based on the criteria below.The scoring criteria and possible point values are: 1. Respondent’s experience with projects of similar size and design: Possible Points: 40 2. Firm’s Qualifications: Possible Points: 20 3. Capabilities to meet time schedule and project budget requirements. Possible Points: 20 4. Present and projected workloads: Possible Points: 10 5. Past projects/experience working with the City of Bozeman: Possible Points: 5 6. Office(s) location: Possible Points: 5 VI. FORM OF AGREEMENT The final form of the contract documents will be disclosed to Respondents during contract negotiations. VII. CITY RESERVATION OF RIGHTS All proposals submitted in response to this RFQ become the property of the City and public records and, as such, may be subject to public review. A SUBMISSION IN RESPONSE TO THIS REQUEST FOR QUALIFICATIONS CONFERS NO RIGHTS UPON ANY RESPONDENTS AND SHALL NOT OBLIGATE THE CITY IN ANY MANNER WHATSOEVER. THE CITY RESERVES THE RIGHT TO MAKE NO AWARD AND TO SOLICIT ADDITIONAL REQUEST FOR QUALIFICATIONS AT A LATER DATE. A. This RFQ may be canceled or any or all responses may be rejected in whole or in part, as specified herein, when it is in the best interests of the City. If the City cancels or revises this RFQ, all Respondents who submitted will be notified using email. B. The City reserves the right to accept or reject any and all submissions; to add or delete items and/or quantities; to amend the RFQ; to waive any minor irregularities, informalities, or failure to conform to the RFQ; to extend the deadline for submitting proposals; to postpone award for up to 60 days; to award one or more contracts, by item or task, or groups of items or tasks, if so provided in the RFQ and if multiple awards are determined by the City to be in the public interest. C. The City reserves the right to reject the submission of any person/firm who previously failed to perform properly to the satisfaction of the City, or complete on time agreements of similar nature, or to reject the submission of any person/firm who is not in a position to perform such an agreement satisfactorily as determined by the City. D. The City reserves the right to determine the best qualified Respondents and negotiate a final scope of service and cost, negotiate a contract with another Respondents if an agreement cannot be reached with the first selected Respondents, or reject all proposals. E. The successful Respondents will be required to enter into a contract with the City, which will incorporate the Respondents' scope of service and work schedule as part of the agreement. F. This RFQ does not commit the City to award a contract. The City assumes no liability or responsibility for costs incurred by Respondents in responding to this request for qualifications or request for interviews, additional data, or other information with respect to the selection process, prior to the issuance of an agreement, contract or purchase order. The Respondents, by submitting a response to this RFQ, waives all right to protest or seek any legal remedies whatsoever regarding any aspect of this RFQ. G. This project is subject to the availability of funds. VIII. NONDISCRIMINATION AND EQUAL PAY POLICY The City of Bozeman requires each entity submitting under this notice shall affirm, on a separate form provided, that it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, sexual preference, gender identity, or disability in fulfillment of a contract entered into for the services identified herein and that this prohibition on discrimination shall apply to the hiring and treatment of the submitting entity’s employees and to all subcontracts it enters into in the fulfillment of the services identified herein. Failure to comply with this requirement shall be cause for the submittal to be deemed nonresponsive. The City also requires each entity submitting under this notice shall affirm it will abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and has visited the State of Montana Equal Pay for Equal Work “best practices” website, https://equalpay.mt.gov/BestPractices/Employers, or equivalent “best practices publication and has read the material. IX. MISCELLANEOUS A. No Oral Agreements. No conversations or oral agreements with any officer, employee, or agent of the City shall affect or modify any term of this solicitation. Oral communications or any written/email communication between any person and City officer, employee or agent shall not be considered binding. B. No Partnership/Business Organization. Nothing in this solicitation or in any subsequent agreement, or any other contract entered into as a result of this solicitation, shall constitute, create, give rise to or otherwise be recognized as a partnership or formal business organization of any kind between or among the respondent and the City. C. Employment Restriction and Indemnity. No person who is an owner, officer, employee, contractor, or consultant of a respondent shall be an officer or employee of the City. No rights of the City’s retirement or personnel rules accrue to a respondent, its officers, employees, contractors, or consultants. Respondents shall have the responsibility of all salaries, wages, bonuses, retirement, withholdings, worker’s compensation and occupational disease compensation, insurance, unemployment compensation other benefits and taxes and premiums appurtenant thereto concerning its officers, employees, contractors, and consultants. Each Respondent shall save and hold the City harmless with respect to any and all claims for payment, compensation, salary, wages, bonuses, retirement, withholdings, worker’s compensation and occupational disease compensation, insurance, unemployment compensation other benefits and taxes and premiums in any way related to each respondent’s officers, employees, contractors and consultants. D. Accessibility. Upon reasonable notice, the City will provide assistance for those persons with sensory impairments. For further information please contact the ADA Coordinator Mike Gray at 406-582-3232 or the City’s TTY line at 406-582-2301. E. Procurement. When discrepancies occur between words and figures in this solicitation, the words shall govern. No responsibility shall attach to a City employee for the premature opening of an SOQ not properly addressed and identified in accordance with these documents. F. Governing Law. This solicitation and any disputes arising hereunder or under any future agreement shall be governed and construed and enforced in accordance with the laws of the State of Montana, without reference to principles of choice or conflicts of laws. X. ATTACHMENTS The following exhibits are incorporated in this RFQ: Appendix A: Non-Discrimination Affirmation Appendix B: Public Library Renovation - Special Inspection and Testing requirements Appendix C: Fire Station #2 Construction – Special Inspection and Testing requirements. END OF RFQ Attachment A NONDISCRIMINATION AND EQUAL PAY AFFIRMATION ____________________________________(name of entity submitting) hereby affirms it will not discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of actual or perceived sexual orientation, gender identity or disability and acknowledges and understands the eventual contract will contain a provision prohibiting discrimination as described above and this prohibition on discrimination shall apply to the hiring and treatments or proposer’s employees and to all subcontracts. In addition, ____________________________________(name of entity submitting) hereby affirms it will abide by the Equal Pay Act of 1963 and Section 39-3-104, MCA (the Montana Equal Pay Act), and has visited the State of Montana Equal Pay for Equal Work “best practices” website, https://equalpay.mt.gov/BestPractices/Employers, or equivalent “best practices publication and has read the material. ______________________________________ Name and title of person authorized to sign on behalf of submitter APPENDIX B STATEMENT OF SPECIAL INSPECTION AND TESTING NOTES: SPECIAL INSPECTIONS SHALL CONFORM TO CHAPTER 17 OF THE INTERNATIONAL BUILDING CODE (IBC), CONTRACT DOCUMENTS, AND APPROVED SUBMITTALS. THE OWNER SHALL EMPLOY ONE OR MORE APPROVED AGENCIES TO PERFORM INSPECTIONS AND TESTING DESCRIBED HEREIN. SPECIAL INSPECTIONS AND ASSOCIATED TESTING SHALL BE PERFORMED BY AN APPROVED AND ACCREDITED INDEPENDENT AGENCY MEETING THE REQUIREMENTS OF ASTM E329 (GENERAL), ASTM D3740 (SOILS), ASTM C1077 (CONCRETE), ASTM A880 (STEEL), AND ASTM E543 (NON-DESTRUCTIVE). THE INSPECTION AND TESTING AGENCY SHALL FURNISH TO THE ARCHITECT AND ENGINEER A COPY OF THEIR SCOPE OF ACCREDITATION. SPECIAL INSPECTORS SHALL BE APPROVED BY THE BUILDING OFFICIAL. WELDING INSPECTORS SHALL BE QUALIFIED PER AWS D1.1. THE CONSTRUCTION OR WORK FOR WHICH SPECIAL INSPECTION IS REQUIRED SHALL REMAIN ACCESSIBLE AND EXPOSED FOR SPECIAL INSPECTION PURPOSES UNTIL COMPLETION OF THE REQUIRED SPECIAL INSPECTIONS. THE SPECIAL INSPECTOR SHALL OBSERVE THE INDICATED WORK FOR COMPLIANCE WITH THE APPROVED CONTRACT DOCUMENTS. ALL DISCREPANCIES SHALL BE BROUGHT TO THE ATTENTION OF THE CONTRACTOR FOR CORRECTION AND NOTED IN THE INSPECTION REPORTS. ISSUES REQUIRING IMMEDIATE CORRECTIVE ACTIONS OR ENGINEERING INPUT ARE TO BE BROUGHT TO THE ENGINEER’S ATTENTION IMMEDIATELY UPON DISCOVERY. THE SPECIAL INSPECTOR SHALL FURNISH INSPECTION REPORTS FOR EACH INSPECTION TO THE BUILDING OFFICIAL, ARCHITECT, ENGINEER, CONTRACTOR, AND OWNER. THE SPECIAL INSPECTION AGENCY SHALL SUBMIT A FINAL REPORT STATING THAT THE WORK REQUIRING SPECIAL INSPECTION WAS INSPECTED, IS IN CONFORMANCE WITH THE APPROVED CONTRACT DOCUMENTS, AND THAT ALL DISCREPANCIES NOTED IN THE REPORTS HAVE BEEN CORRECTED. EACH CONTRACTOR RESPONSIBLE FOR THE CONSTRUCTION OF A MAIN WIND- OR SEISMIC FORCE-RESISTING SYSTEM, DESIGNATED SEISMIC SYSTEM, OR A WIND- OR SEISMIC-RESISTING COMPONENT LISTED SHALL SUBMIT A WRITTEN STATEMENT OF RESPONSIBILITY TO THE BUILDING OFFICIAL AND THE OWNER PRIOR TO COMMENCEMENT OF WORK ON THE SYSTEM OF COMPONENT. THE CONTRACTOR’S STATEMENT OF RESPONSIBILITY SHALL CONTAIN ACKNOWLEDGEMENT OF AWARENESS OF THE SPECIAL REQUIREMENTS CONTAINED HEREIN. INSPECTION FREQUENCY: A. CONTINUOUS INSPECTION: THE SPECIAL INSPECTOR SHALL BE PRESENT WHEN AND WHERE THE WORK IS BEING PERFORMED AT ALL TIMES. B. PERIODIC INSPECTION: THE SPECIAL INSPECTOR SHALL BE INTERMITTENTLY PRESENT WHEN AND WHERE THE WORK IS BEING PERFORMED. THE INSPECTOR SHALL OBSERVE THE WORK AT ITS COMMENCEMENT, AT PERIODIC INTERVALS THEREAFTER, AND WHEN THE WORK IS COMPLETED. C. OBSERVE: THE INSPECTOR SHALL OBSERVE THESE FUNCTIONS ON A RANDOM BASIS. OPERATIONS NEED NOT BE DELAYED PENDING OBSERVATIONS (REFERENCE AISC 360 AND AISC 341 FOR ADDITIONAL INFORMATION). D. PERFORM: THESE INSPECTIONS SHALL BE PERFORMED PRIOR TO FINAL ACCEPTANCE OF THE ITEM (REFERENCE AISC 360 AND AISC 341 FOR ADDITIONAL INFORMATION). E. DOCUMENT: THE INSPECTOR SHALL PREPARE REPORTS INDICATING THAT THE WORK HAS BEEN PERFORMED IN ACCORDANCE WITH THE CONTRACT DOCUMENTS (REFERENCE AISC 360 AND AISC 341 FOR ADDITIONAL INFORMATION). SPECIAL INSPECTIONS ARE NOT REQUIRED WHERE THE WORK IS DONE ON THE PREMISES OF A FABRICATOR REGISTERED AND APPROVED TO PERFORM SUCH WORK WITHOUT SPECIAL INSPECTION. APPROVAL SHALL BE BASED UPON REVIEW OF THE FABRICATOR’S WRITTEN PROCEDURAL AND QUALITY CONTROL MANUALS AND PERIODIC AUDITING OF FABRICATION PRACTICES BY AN APPROVED SPECIAL INSPECTION AGENCY. AT COMPLETION OF FABRICATION, THE APPROVED FABRICATOR SHALL SUBMIT A CERTIFICATE OF COMPLIANCE TO THE BUILDING OFFICIAL STATING THAT THE WORK WAS PERFORMED IN ACCORDANCE WITH THE APPROVED CONSTRUCTION DOCUMENTS. A. STEEL FABRICATORS AND INSTALLERS CERTIFIED THROUGH AISC COMPLY WITH THIS PROVISION. THE FABRICATOR AND OR INSTALLER MUST STILL COMPLETE AND DOCUMENT THE QUALITY CONTROL TASKS AND NON-DESTRUCTIVE TESTING OUTLINED IN AISC 360 AND AISC 341, AS APPLICABLE. LICEN S E D AMTNONA DAVID L. FRENCH No.16076PRO FESS IONA L E N GINEERDrawing 2021 Copyright Meyer, Scherer & Rockcastle, Ltd. Drawing 2021 Copyright Meyer, Scherer & Rockcastle, Ltd. ISSUE / REVISION I hereby certify that this plan, specification or report was prepared by me or under my direct supervision and that I am a duly Licensed Architect under the Laws of the State of Montana. Architect Seal Signature Print Name Date License No DateMark Description 510 Marquette Avenue South, Suite 200 Minneapolis, MN 55402 | 612.375.0336 PE No. 16076 1 6/13/2022 11:17:43 AMAutodesk Docs://2021005 Bozeman Public Library/BZN PUBLIC LIBRARY - STRUCTURAL_R22.rvtS002 STATEMENT OF SPECIAL INSPECTIONS CONSTRUCTION DOCUMENTS 2022.06.10 2022.06.10 Construction DocumentsProject No: 2021005BPLBozeman Public Library626 E Main St.Bozeman, MT 59715Architecture and Interiors Associate Architect 2880 Technology Blvd W | Bozeman, MT, 59718 | 406.587.0721 428 E Mendenhall St, Bozeman, MT 59715 | 406.219.2216 Civil, Structural, Mechanical, Electrical, Plumbing, Fire Protection, IT Audio / Visual 1800 Deming Way #200, Middleton, WI 53562 | 608.223.9600 Lighting Design 1999 Broadway UNIT 2205, Denver, CO 80202 | 720.644.5044 Landscape Architecture 111 N Tracy Ave, Bozeman, MT 59715 | 406.587.4873 David L. French PRIOR TO PLACEMENT OF COMPACTED FILL, OBSERVE SUBGRADE AND VERIFY THAT THE SITE HAS BEEN PREPARED PROPERLY PERIODIC VERIFY USE OF PROPER MATERIALS, DENSITIES, AND LIFT THICKNESSES DURING PLACEMENT AND COMPACTION OF COMPACTED FILL CONTINUOUS VERIFY EXCAVATIONS ARE EXTENDED TO PROPER DEPTH AND HAVE REACHED PROPER MATERIAL PERIODIC VERIFY MATERIALS BELOW SHALLOW FOUNDATION ARE ADEQUATE TO ACHIEVE THE DESIGN BEARING CAPACITY TABLE 1705.6 GEOTECHNICAL REPORT PERIODIC BY THE GEOTECHNICAL ENGINEER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTIONS AND TESTS OF SOILS INSPECT FORMWORK FOR SHAPE, LOCATION AND DIMENSIONS OF THE CONCRETE MEMBER BEING FORMED ACI 318: 26.11.1.2(b)PERIODIC VERIFICATION OF IN-SITU CONCRETE STRENGTH PRIOR TO REMOVAL OF SHORES AND FORMS FROM BEAMS AND STRUCTURAL SLABS PERIODIC VERIFICATION OF IN-SITU CONCRETE STRENGTH PRIOR TO STRESSING TENDONS IN POST-TENSIONED CONCRETE ACI 318: 26.11.2 PERIODIC ERECTION OF PRECAST CONCRETE MEMBERS ACI 318: 26.9 PERIODIC PRESTRESSED CONCRETE: GROUTING OF BONDED PRESTRESSING TENDONS IN THE SEISMIC FORCE RESISTING SYSTEM CONTINUOUS PRESTRESSED CONCRETE: APPLICATION OF PRESTRESSING FORCE ACI 318: 26.10 CONTINUOUS INSPECTION FOR MAINTENANCE OF SPECIFIED CURING TEMPERATURE AND TECHNIQUES ACI 318: 26.5.3-25.5.5 PERIODIC INSPECTION OF SHOTCRETE PLACEMENT FOR PROPER APPLICATION TECHNIQUES CONTINUOUS INSPECTION OF CONCRETE PLACEMENT FOR PROPER APPLICATION TECHNIQUES ACI 318: 26.5, 26.12 CONTINUOUS VERIFY USE OF REQUIRED MIX DESIGN ACI 318: CH. 19, 26.4.3, 26.4.4 PERIODIC INSPECTION OF ANCHORS POST-INSTALLED IN HARDENED CONCRETE: VERIFY ANCHOR PRODUCT NAME, TYPE, AND DIMENSIONS, HOLE DIMENSIONS, COMPLIANCE WITH DRILL BIT REQUIREMENTS, CLEANLINESS OF THE HOLE AND ANCHOR, PRODUCT EXPIRATION DATE (IF APPLICABLE), COMPLIANCE WITH MANUFACTURER'S INSTALLATION INSTRUCTIONS, ANCHOR EMBEDMENT, AND TIGHTENING TORQUE (IF APPLICABLE) FOR: b) MECHANICAL ANCHORS AND ADHESIVE ANCHORS NOT DEFINED IN a) ACI 318: 17.8.2 PRODUCT EVALUATION REPORT PERIODIC INSPECTION OF ANCHORS POST-INSTALLED IN HARDENED CONCRETE: VERIFY ANCHOR PRODUCT NAME, TYPE, AND DIMENSIONS, HOLE DIMENSIONS, COMPLIANCE WITH DRILL BIT REQUIREMENTS, CLEANLINESS OF THE HOLE AND ANCHOR, PRODUCT EXPIRATION DATE (IF APPLICABLE), COMPLIANCE WITH MANUFACTURER'S INSTALLATION INSTRUCTIONS, ANCHOR EMBEDMENT, AND TIGHTENING TORQUE (IF APPLICABLE) FOR: a) ADHESIVE ANCHORS INSTALLED IN HORIZONTALLY OR UPWARDLY INCLINED ORIENTATIONS TO RESIST SUSTAINED TENSION LOADS ACI 318: 17.8.2.4 PRODUCT EVALUATION REPORT CONTINUOUS INSPECTION OF ANCHORS CAST-IN CONCRETE TABLE 1705.3 ACI 318: 17.8.2 PERIODIC WELDING REINFORCING: OTHER STEEL NOT PREVIOUSLY LISTED PERIODIC WELDING REINFORCING: TRANSVERSE REINFORCING IN BEAMS AND COLUMNS CONTINUOUS WELDING REINFORCING: LONGITUDINAL AND TRANSVERSE REINFORCING IN BOUNDARY ELEMENTS OF SPECIAL STRUCTURAL WALLS CONTINUOUS WELDING REINFORCING: LONGITUDINAL REINFORCING IN BEAMS AND COLUMNS OF INTERMEDIATE AND SPECIAL MOMENT FRAMES CONTINUOUS WELDING REINFORCING: VERIFICATION OF WELDABILITY OF REINFORCING STEEL OTHER THAN ASTM A706 TABLE 1705.3 AWS D1.4 ACI 318: 26.6.4 PERIODIC INSPECTION OF PRESTRESSING TENDONS AND PLACEMENT PERIODIC INSPECTION OF REINFORCING STEEL AND PLACEMENT TABLE 1705.3 ACI 318: Ch. 20, 25.2, 25.3, 26.6.1-26.6.3 PERIODIC TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTIONS AND TESTS OF CONCRETE CONSTRUCTION DOCUMENT ACCEPTANCE OR REJECTION OF MECHANICAL FASTENERS PERFORM VERIFY REPAIR ACTIVITIES PERFORM CHECK SPACING, TYPE AND INSTALLATION OF SUPPORT, SIDELAP AND PERIMETER FASTENERS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.8 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS AFTER MECHANICAL FASTENING FASTENERS ARE INSTALLED IN ACCORDANCE WITH MANUFACTURER’S INSTRUCTIONS OBSERVE FASTENERS ARE POSITIONED AS REQUIRED 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.7 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS DURING MECHANICAL FASTENING PROPER STORAGE FOR MECHANICAL FASTENERS OBSERVE PROPER TOOLS AVAILABLE FOR FASTENER INSTALLATION OBSERVE MANUFACTURER INSTALLATION INSTRUCTIONS AVAILABLE FOR MECHANICAL FASTENERS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.6 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS PRIOR TO MECHANICAL FASTENING DOCUMENT ACCEPTANCE OR REJECTION OF WELDS PERFORM VERIFY REPAIR ACTIVITIES PERFORM WELDS MEET VISUAL ACCEPTANCE CRITERIA PERFORM VERIFY SIZE AND LOCATION OF WELDS, INCLUDING SUPPORT, SIDELAP, AND PERIMETER WELDS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.5 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS AFTER WELDING WPS FOLLOWED OBSERVE ENVIRONMENTAL CONDITIONS (WIND SPEED, MOISURE, TEMPERATURE)OBSERVE CONTROL AND HANDLING OF WELDING CONSUMABLES OBSERVE USE OF QUALIFIED WELDERS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.4 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS DURING WELDING CHECK WELDING EQUIPMENT OBSERVE MATERIAL IDENTIFICATIONS (TYPE/GRADE)OBSERVE MANUFACTURER CERTIFICATIONS FOR WELDING CONSUMABLES AVAILABLE OBSERVE WELDING PROCEDURE SPECIFICATIONS (WPS) AVAILABLE 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.3 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS PRIOR TO WELDING DOCUMENT ACCEPTANCE OR REJECTION OF INSTALLATION OF DECK AND DECK ACCESORIES PERFORM VERIFY DECK MATERIALS ARE REPRESENTED BY THE MILL CERTIFICATIONS THAT COMPLY WITH THE APPROVED CONSTRUCTION DOCUMENTS PERFORM VERIFY COMPLIANCE OF DECK AND ALL DECK ACCESSORIES INSTALLATION WITH APPROVED CONSTRUCTION DOCUMENTS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.2 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS AFTER DECK PLACEMENT DOCUMENT ACCEPTANCE OR REJECTION OF DECK AND DECK ACCESSORIES PERFORM VERIFY COMPLIANCE OF MATERIALS (DECK AND ALL DECK ACCESSORIES) WITH APPROVED CONSTRUCTION DOCUMENTS, INCLUDING PROFILES, MATERIAL PROPERTIES, AND BASE METAL THICKNESS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.1 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS PRIOR TO DECK PLACEMENT VERIFY THAT THE TEMPORARY INSTALLATION RESTRAINT/BRACING AND THE PERMANENT INDIVIDUAL TRUSS MEMBER RESTRAINT/BRACING ARE INSTALLED IN ACCORDANCE WITH THE APPROVED TRUSS SUBMITTAL PACKAGE FOR COLD-FORMED STEEL TRUSSES SPANNING 60 FEET OR GREATER 1705.2.4 APPROVED TRUSS SUBMITTAL PERIODIC INSPECTION OF WELDING REINFORCING STEEL 1705.3.1 PER CONCRETE CONSTRUCTION TABLE 1705.3 TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF STEEL CONSTRUCTION OTHER THAN STRUCTURAL STEEL DOCUMENT ACCEPTANCE OR REJECTION OF STEEL ELEMENTS PERFORM PLACEMENT AND INSTALLATION OF STEEL HEADED STUD ANCHORS PERFORM PLACEMENT AND INSTALLATION OF STEEL DECK 1705.2.1 AISC TABLE N6.1 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF STRUCTURAL STEEL ELEMENTS OF COMPOSITE CONSTRUCTION PRIOR TO... DOCUMENT ACCEPTANCE OR REJECTION OF BOLTED CONNECTIONS 1705.2.1 AISC TABLE N5.6-3 PERFORM SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS AFTER BOLTING STRUCTURAL STEEL FASTENERS ARE PRETENSIONED IN ACCORDANCE WITH THE RCSC SPECIFICATION, PROGRESSING SYSTEMATICALLY FROM THE MOST RIGID POINT TOWARD THE FREE EDGES OBSERVE FASTENER COMPONENT NOT TURNED BY THE WRENCH PREVENTED FROM ROTATING OBSERVE JOINT BROUGHT TO SNUG-TIGHT CONDITION PRIOR TO THE PRETENSIONING OPERATION OBSERVE FASTENER ASSEMBLIES, OF SUITABLE CONDITION, PLACED IN ALL HOLES AND WASHERS (IF REQUIRED) ARE POSITIONED AS REQUIRED 1705.2.1 AISC TABLE N5.6-2 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS DURING BOLTING STRUCTURAL STEEL (NOT REQUIRED FOR SNUG-TIGHT JOINTS) PROPER STORAGE PROVIDED FOR BOLTS, NUTS, WASHERS, AND OTHER FASTENER COMPONENTS OBSERVE PRE-INSTALLATION VERIFICATION TESTING BY INSTALLATION PERSONNEL OBSERVED AND DOCUMENTED FOR FASTENER ASSEMBLIES AND METHODS USED OBSERVE CONNECTING ELEMENTS, INCLUDING THE APPROPRIATE FAYING SURFACE CONDITION AND HOLE PREPARATION, IF SPECIFIED, MEET APPLICABLE REQUIREMENTS OBSERVE PROPER BOLTING PROCEDURE SELECTED FOR JOINT DETAIL OBSERVE PROPER FASTENERS SELECTED FOR THE JOINT DETAIL (GRADE, TYPE, BOLT LENGTH IF THREADS ARE TO BE EXCLUDED FROM SHEAR PLANE) OBSERVE FASTENERS MARKED IN ACCORDANCE WITH ASTM REQUIREMENTS 1705.2.1 AISC TABLE N5.6-1 PERFORM SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS PRIOR TO BOLTING STRUCTURAL STEEL NO PROHIBITED WELDS HAVE BEEN ADDED WITHOUT THE APPROVAL OF THE EOR OBSERVE DOCUMENT ACCEPTANCE OR REJECTION OF WELDED JOINT OR MEMBER PERFORM REPAIR ACTIVITIES PERFORM BACKING REMOVED AND WELD TABS REMOVED (IF REQUIRED BY THE CONSTRUCTION DOCUMENTS)PERFORM WELD ACCESS HOLES IN ROLLED HEAVY SHAPES AND BUILT-UP SHAPES: AFTER ROLLED HEAVY SHAPES (SEE SECTION A3.1c) AND BUILT-UP HEAVY SHAPES (SEE SECTION A3.1d) ARE WELDED, VISUALLY INSPECT THE WELD ACCESS HOLE FOR CRACKS PERFORM K-AREA: WHEN WELDING DOUBLER PLATES, CONTINUITY PLATES, OR STIFFENERS HAS BEEN PERFORMED IN THE k-AREA OF ROLLED SHAPES, VISUALLY INSPECT THE WEB FOR k-AREA CRACKS WITHIN 3” OF THE WELD PERFORM ARC STRIKES PERFORM WELDS MEET VISUAL ACCEPTANCE CRITERIA: CRACK PROHIBITION, WELD/BASE-METAL FUSION, CRATER CROSS SECTION, WELD PROFILES, WELD SIZE, UNDERCUT, POROSITY PERFORM SIZE, LENGTH, AND LOCATION OF WELDS PERFORM WELDS CLEANED 1705.2.1 AISC TABLE N5.4-3 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS AFTER WELDING STRUCTURAL STEEL PLACEMENT AND INSTALLATION OF STEEL HEADED STUD ANCHORS PERFORM WELDING TECHNIQUES: INTERPASS AND FINAL CLEANING, EACH PASS WITHIN PROFILE LIMITATIONS, EACH PASS MEETS QUALITY REQUIREMENTS OBSERVE WPS FOLLOWED: SETTINGS ON WELDING EQUIPMENT, TRAVEL SPEED, SELECTED WELDING MATERIALS, SHIELDING GAS TYPE/FLOW RATE, PREHEAT APPLIED, INTERPASS TEMPERATURE MAINTAINED, PROPER WELDING POSITION OBSERVE ENVIRONMENTAL CONDITIONS: WIND SPEED WITHIN LIMITS, PRECIPITATION AND TEMPERATURE OBSERVE NO WELDING OVER CRACKED TACK WELDS OBSERVE CONTROL AND HANDLING OF WELDING CONSUMABLES: PACKAGING, EXPOSURE CONTROL 1705.2.1 AISC TABLE N5.4-2 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS DURING WELDING STRUCTURAL STEEL FIT-UP OF FILLET WELDS: DIMENSIONS (ALIGNMENT, GAPS AT ROOT), CLEANLINESS (CONDITION OF STEEL SURFACE), TACKING (TACK WELD QUALITY AND LOCATION) OBSERVE CONFIGURATION AND FINISH OF ACCESS HOLES OBSERVE FIT-UP OF CJP GROOVE WELDS OF HSS T-, Y- AND K-JOINTS WITHOUT BACKING (INCLUDING JOINT GEOMETRY): JOINT PREPARATIONS, DIMENTIONS (ALIGNMENT, ROOT OPENING, ROOT FACE, BEVEL), CLEANLINESS (CONDITION OF STEEL SURFACES), TACKING (TACK WELD QUALITY AND LOCATION) OBSERVE FIT-UP OF GROOVE WELDS (INCLUDING JOINT GEOMETRY): JOINT PREPARATION, DIMENSIONS (ALIGNMENT, ROOT OPENING, ROOT FACE, BEVEL), CLEANLINESS (CONDITION OF STEEL SURFACES), TACKING (TACK WELD QUALITY AND LOCATION), BACKING TYPE AND FIT (IF APPLICABLE) OBSERVE WELDER IDENTIFICATION SYSTEM OBSERVE MATERIAL IDENTIFICATION (TYPE/GRADE)OBSERVE MANUFACTURER CERTIFICATIONS FOR WELDING CONSUMABLES AVAILABLE PERFORM WELDING PROCEDURE SPECIFICATIONS AVAILABLE PERFORM WELDER QUALIFICATION RECORDS AND CONTINUITY RECORDS 1705.2.1 AISC TABLE N5.4-1 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS PRIOR TO WELDING STRUCTURAL STEEL INSPECT THE FABRICATED STEEL OR ERECTED STEEL FRAME TO VERIFY COMPLIANCE WITH THE DETAILS AS SHOWN ON THE CONSTRUCTIONS DOCUMENTS, SUCH AS BRACES, STIFFENERS, MEMBER LOCATIONS, AND PROPER APPLICATION OF JOINT DETAILS AT EACH CONNECTION PERIODIC PLACEMENT OF ANCHOR RODS AND OTHER EMBEDMENTS SUPPORTING STRUCTURAL STEEL: VERIFY THE DIAMETER, GRADE, TYPE, AND LENGTH OF THE ANCHOR ROD OR EMBEDDED ITEM AND THE EXTENT OR DEPTH OF EMBEDMENT INTO THE CONCRETE PRIOR TO PLACEMENT OF CONCRETE AISC N5.8 PERIODIC REVIEW THE MATERIAL TEST REPORTS AND CERTIFICATIONS FOR STEEL COMPONENTS FOR COMPLIANCE WITH THE CONSTRUCTION DOCUMENTS, INCLUDING PRIMARY STEEL ELEMENTS, STEEL CASTINGS AND FORGINGS, FASTENERS, DECK FASTENERS, ANCHOR RODS AND THREADED RODS, WELDING CONSUMABLES, HEADED STUD ANCHORS, WELDING FILLER METAL AND FLUXES, WELDING PROCEDURE SPECIFICATIONS (WPS), PROCEDURE QUALIFICATION RECORDS FOR WPS THAT ARE NOT PREQUALIFIED, WELDING PERSONNEL QUALIFICATION RECORDS AND CONTINUITY RECORDS, FABRICATOR’S WRITTEN QUALITY CONTROL MANUAL, AND ERECTOR’S QUALITY CONTROL MANUAL 1705.2.1 AISC N5.2 PERIODIC PERFORM A ONE-TIME REVIEW OF EACH APPLICABLE ITEM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTIONS OF STRUCTURAL STEEL CONSTRUCTION PROOF TESTING OF DEEP FOUNDATION ELEMENTS PROJECT GEOTECHNICAL REPORT PERFORM CLASSIFICATION AND TESTING OF COMPACTED FILL MATERIALS TABLE 1705.6 PROJECT GEOTECHNICAL REPORT PERIODIC TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY TESTING OF SOILS AND FOUNDATIONS AT THE TIME FRESH CONCRETE IS SAMPLED TO FABRICATE SPECIMENS FOR STRENGTH TESTS, PERFORM SLUMP AND AIR CONTENT TESTS, AND DETERMINE TEMPERATURE OF CONCRETE ASTM C172 ACI 318-14: 26.4 AND 26.12 FOR EACH SPECIMEN CONCRETE STRENGTH TEST SPECIMENS TABLE 1705.3 ASTM C31 AND C39 FOR EACH CLASS OF CONCRETE (E.G. FOOTINGS, WALLS, OR SLAB ON GRADE), ONE SET OF SPECIMENS EACH DAY OR LESSER OF: ONE SET FOR EACH 150 YDS OF CONCRETE OR ONE SET FOR EACH 5,000 SQUARE FEET OF SLABS OR WALL TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY TESTING OF CONCRETE CONSTRUCTION APPENDIX C STATEMENT OF SPECIAL INSPECTION AND TESTING NOTES: SPECIAL INSPECTIONS SHALL CONFORM TO CHAPTER 17 OF THE INTERNATIONAL BUILDING CODE (IBC), CONTRACT DOCUMENTS, AND APPROVED SUBMITTALS. THE OWNER SHALL EMPLOY ONE OR MORE APPROVED AGENCIES TO PERFORM INSPECTIONS AND TESTING DESCRIBED HEREIN. SPECIAL INSPECTIONS AND ASSOCIATED TESTING SHALL BE PERFORMED BY AN APPROVED AND ACCREDITED INDEPENDENT AGENCY MEETING THE REQUIREMENTS OF ASTM E329 (GENERAL), ASTM D3740 (SOILS), ASTM C1077 (CONCRETE), ASTM A880 (STEEL), AND ASTM E543 (NON-DESTRUCTIVE). THE INSPECTION AND TESTING AGENCY SHALL FURNISH TO THE ARCHITECT AND ENGINEER A COPY OF THEIR SCOPE OF ACCREDITATION. SPECIAL INSPECTORS SHALL BE APPROVED BY THE BUILDING OFFICIAL. WELDING INSPECTORS SHALL BE QUALIFIED PER AWS D1.1. THE CONSTRUCTION OR WORK FOR WHICH SPECIAL INSPECTION IS REQUIRED SHALL REMAIN ACCESSIBLE AND EXPOSED FOR SPECIAL INSPECTION PURPOSES UNTIL COMPLETION OF THE REQUIRED SPECIAL INSPECTIONS. THE SPECIAL INSPECTOR SHALL OBSERVE THE INDICATED WORK FOR COMPLIANCE WITH THE APPROVED CONTRACT DOCUMENTS. ALL DISCREPANCIES SHALL BE BROUGHT TO THE ATTENTION OF THE CONTRACTOR FOR CORRECTION AND NOTED IN THE INSPECTION REPORTS. ISSUES REQUIRING IMMEDIATE CORRECTIVE ACTIONS OR ENGINEERING INPUT ARE TO BE BROUGHT TO THE ENGINEER’S ATTENTION IMMEDIATELY UPON DISCOVERY. THE SPECIAL INSPECTOR SHALL FURNISH INSPECTION REPORTS FOR EACH INSPECTION TO THE BUILDING OFFICIAL, ARCHITECT, ENGINEER, CONTRACTOR, AND OWNER. THE SPECIAL INSPECTION AGENCY SHALL SUBMIT A FINAL REPORT STATING THAT THE WORK REQUIRING SPECIAL INSPECTION WAS INSPECTED, IS IN CONFORMANCE WITH THE APPROVED CONTRACT DOCUMENTS, AND THAT ALL DISCREPANCIES NOTED IN THE REPORTS HAVE BEEN CORRECTED. EACH CONTRACTOR RESPONSIBLE FOR THE CONSTRUCTION OF A MAIN WIND- OR SEISMIC FORCE-RESISTING SYSTEM, DESIGNATED SEISMIC SYSTEM, OR A WIND- OR SEISMIC-RESISTING COMPONENT LISTED SHALL SUBMIT A WRITTEN STATEMENT OF RESPONSIBILITY TO THE BUILDING OFFICIAL AND THE OWNER PRIOR TO COMMENCEMENT OF WORK ON THE SYSTEM OF COMPONENT. THE CONTRACTOR’S STATEMENT OF RESPONSIBILITY SHALL CONTAIN ACKNOWLEDGEMENT OF AWARENESS OF THE SPECIAL REQUIREMENTS CONTAINED HEREIN. INSPECTION FREQUENCY: A. CONTINUOUS INSPECTION: THE SPECIAL INSPECTOR SHALL BE PRESENT WHEN AND WHERE THE WORK IS BEING PERFORMED AT ALL TIMES. B. PERIODIC INSPECTION: THE SPECIAL INSPECTOR SHALL BE INTERMITTENTLY PRESENT WHEN AND WHERE THE WORK IS BEING PERFORMED. THE INSPECTOR SHALL OBSERVE THE WORK AT ITS COMMENCEMENT, AT PERIODIC INTERVALS THEREAFTER, AND WHEN THE WORK IS COMPLETED. C. OBSERVE: THE INSPECTOR SHALL OBSERVE THESE FUNCTIONS ON A RANDOM BASIS. OPERATIONS NEED NOT BE DELAYED PENDING OBSERVATIONS (REFERENCE AISC 360 AND AISC 341 FOR ADDITIONAL INFORMATION). D. PERFORM: THESE INSPECTIONS SHALL BE PERFORMED PRIOR TO FINAL ACCEPTANCE OF THE ITEM (REFERENCE AISC 360 AND AISC 341 FOR ADDITIONAL INFORMATION). E. DOCUMENT: THE INSPECTOR SHALL PREPARE REPORTS INDICATING THAT THE WORK HAS BEEN PERFORMED IN ACCORDANCE WITH THE CONTRACT DOCUMENTS (REFERENCE AISC 360 AND AISC 341 FOR ADDITIONAL INFORMATION). SPECIAL INSPECTIONS ARE NOT REQUIRED WHERE THE WORK IS DONE ON THE PREMISES OF A FABRICATOR REGISTERED AND APPROVED TO PERFORM SUCH WORK WITHOUT SPECIAL INSPECTION. APPROVAL SHALL BE BASED UPON REVIEW OF THE FABRICATOR’S WRITTEN PROCEDURAL AND QUALITY CONTROL MANUALS AND PERIODIC AUDITING OF FABRICATION PRACTICES BY AN APPROVED SPECIAL INSPECTION AGENCY. AT COMPLETION OF FABRICATION, THE APPROVED FABRICATOR SHALL SUBMIT A CERTIFICATE OF COMPLIANCE TO THE BUILDING OFFICIAL STATING THAT THE WORK WAS PERFORMED IN ACCORDANCE WITH THE APPROVED CONSTRUCTION DOCUMENTS. A. STEEL FABRICATORS AND INSTALLERS CERTIFIED THROUGH AISC COMPLY WITH THIS PROVISION. THE FABRICATOR AND OR INSTALLER MUST STILL COMPLETE AND DOCUMENT THE QUALITY CONTROL TASKS AND NON-DESTRUCTIVE TESTING OUTLINED IN AISC 360 AND AISC 341, AS APPLICABLE. TNMO AAN SERPOFS GNDR MENUEZ NATE J. No.15739 PE A T N IGSI E O L EREE ERIENCOPYRIGHT 2022 12/19/2022 10:17:21 AMS0.2 ISSUE FOR PERMIT 19 DEC 22 2105CITY OF BOZEMANFIRE STATION #2575 WEST KAGY BLVD, BOZEMAN, MONTANA 59715STATEMENT OF SPECIALINSPECTIONSPRIOR TO PLACEMENT OF COMPACTED FILL, OBSERVE SUBGRADE AND VERIFY THAT THE SITE HAS BEEN PREPARED PROPERLY PERIODIC VERIFY USE OF PROPER MATERIALS, DENSITIES, AND LIFT THICKNESSES DURING PLACEMENT AND COMPACTION OF COMPACTED FILL CONTINUOUS VERIFY EXCAVATIONS ARE EXTENDED TO PROPER DEPTH AND HAVE REACHED PROPER MATERIAL PERIODIC VERIFY MATERIALS BELOW SHALLOW FOUNDATION ARE ADEQUATE TO ACHIEVE THE DESIGN BEARING CAPACITY TABLE 1705.6 GEOTECHNICAL REPORT PERIODIC BY THE GEOTECHNICAL ENGINEER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTIONS AND TESTS OF SOILS INSPECT FORMWORK FOR SHAPE, LOCATION AND DIMENSIONS OF THE CONCRETE MEMBER BEING FORMED ACI 318: 26.11.1.2(b)PERIODIC VERIFICATION OF IN-SITU CONCRETE STRENGTH PRIOR TO REMOVAL OF SHORES AND FORMS FROM BEAMS AND STRUCTURAL SLABS PERIODIC VERIFICATION OF IN-SITU CONCRETE STRENGTH PRIOR TO STRESSING TENDONS IN POST-TENSIONED CONCRETE ACI 318: 26.11.2 PERIODIC ERECTION OF PRECAST CONCRETE MEMBERS ACI 318: 26.9 PERIODIC PRESTRESSED CONCRETE: GROUTING OF BONDED PRESTRESSING TENDONS IN THE SEISMIC FORCE RESISTING SYSTEM CONTINUOUS PRESTRESSED CONCRETE: APPLICATION OF PRESTRESSING FORCE ACI 318: 26.10 CONTINUOUS INSPECTION FOR MAINTENANCE OF SPECIFIED CURING TEMPERATURE AND TECHNIQUES ACI 318: 26.5.3-25.5.5 PERIODIC INSPECTION OF SHOTCRETE PLACEMENT FOR PROPER APPLICATION TECHNIQUES CONTINUOUS INSPECTION OF CONCRETE PLACEMENT FOR PROPER APPLICATION TECHNIQUES ACI 318: 26.5, 26.12 CONTINUOUS VERIFY USE OF REQUIRED MIX DESIGN ACI 318: CH. 19, 26.4.3, 26.4.4 PERIODIC INSPECTION OF ANCHORS POST-INSTALLED IN HARDENED CONCRETE: VERIFY ANCHOR PRODUCT NAME, TYPE, AND DIMENSIONS, HOLE DIMENSIONS, COMPLIANCE WITH DRILL BIT REQUIREMENTS, CLEANLINESS OF THE HOLE AND ANCHOR, PRODUCT EXPIRATION DATE (IF APPLICABLE), COMPLIANCE WITH MANUFACTURER'S INSTALLATION INSTRUCTIONS, ANCHOR EMBEDMENT, AND TIGHTENING TORQUE (IF APPLICABLE) FOR: b) MECHANICAL ANCHORS AND ADHESIVE ANCHORS NOT DEFINED IN a) ACI 318: 17.8.2 PRODUCT EVALUATION REPORT PERIODIC INSPECTION OF ANCHORS POST-INSTALLED IN HARDENED CONCRETE: VERIFY ANCHOR PRODUCT NAME, TYPE, AND DIMENSIONS, HOLE DIMENSIONS, COMPLIANCE WITH DRILL BIT REQUIREMENTS, CLEANLINESS OF THE HOLE AND ANCHOR, PRODUCT EXPIRATION DATE (IF APPLICABLE), COMPLIANCE WITH MANUFACTURER'S INSTALLATION INSTRUCTIONS, ANCHOR EMBEDMENT, AND TIGHTENING TORQUE (IF APPLICABLE) FOR: a) ADHESIVE ANCHORS INSTALLED IN HORIZONTALLY OR UPWARDLY INCLINED ORIENTATIONS TO RESIST SUSTAINED TENSION LOADS ACI 318: 17.8.2.4 PRODUCT EVALUATION REPORT CONTINUOUS INSPECTION OF ANCHORS CAST-IN CONCRETE TABLE 1705.3 ACI 318: 17.8.2 PERIODIC WELDING REINFORCING: OTHER STEEL NOT PREVIOUSLY LISTED PERIODIC WELDING REINFORCING: TRANSVERSE REINFORCING IN BEAMS AND COLUMNS CONTINUOUS WELDING REINFORCING: LONGITUDINAL AND TRANSVERSE REINFORCING IN BOUNDARY ELEMENTS OF SPECIAL STRUCTURAL WALLS CONTINUOUS WELDING REINFORCING: LONGITUDINAL REINFORCING IN BEAMS AND COLUMNS OF INTERMEDIATE AND SPECIAL MOMENT FRAMES CONTINUOUS WELDING REINFORCING: VERIFICATION OF WELDABILITY OF REINFORCING STEEL OTHER THAN ASTM A706 TABLE 1705.3 AWS D1.4 ACI 318: 26.6.4 PERIODIC INSPECTION OF PRESTRESSING TENDONS AND PLACEMENT PERIODIC INSPECTION OF REINFORCING STEEL AND PLACEMENT TABLE 1705.3 ACI 318: Ch. 20, 25.2, 25.3, 26.6.1-26.6.3 PERIODIC TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTIONS AND TESTS OF CONCRETE CONSTRUCTION INSPECTION OF ANCHORS POST-INSTALLED IN MASONRY CONSTRUCTION. VERIFY ANCHOR PRODUCT NAME, TYPE, AND DIMENSIONS, HOLE DIMENSIONS, COMPLIANCE WITH DRILL BIT REQUIREMENTS, CLEANLINESS OF THE HOLE AND ANCHOR, PRODUCT... PERIODIC INSPECTION DURING CONSTRUCTION, VERIFICATION OF PROPORTIONS OF MATERIALS AS DELIVERED TO THE PROJECT SITE FOR PREMIXED OR PREBLENDED MORTAR, PRESTRESSING GROUT, AND GROUT OTHER THAN SELF-CONSOLIDATING GROUT NR NR R ART. 1.4B DURING CONSTRUCTION, VERIFICATION OF f’m AND f’ACC, FOR EVERY 5,000 SQ. FT. (465 SQ. M) NR NR R ART. 1.4B DURING CONSTRUCTION, VERIFICATION OF SLUMP FLOW AND VISUAL STABILITY INDEX (VSI) WHEN SELF-CONSOLIDATION GROUT IS DELIVERED TO THE PROJECT SITE NR R R ART 1.5, 1.6.3 PRIOR TO CONSTRUCTION, VERIFICATION OF f’m AND f’ACC, EXCEPT WHERE SPECIFICALLY EXEMPTED BY THE CODE NR R R ART 1.4B PRIOR TO CONSTRUCTION, VERIFICATION OF COMPLIANCE OF SUBMITTALS R R R ART. 1.5 LEVEL 1 LEVEL 2 LEVEL 3 TMS 602 MINIMUM VERIFICATION REQUIRED FOR QA REFERENCE FOR CRITERIA REMARKS SPECIAL INSPECTION OF MASONRY CONSTRUCTION MINIMUM VERIFICATION REQUIREMENTS APPENDIX A LEVEL 1 NOT PERMITTED PART 4 LEVEL 2 LEVEL 2 TMS 402-16 PART 3 OR APPENDIX B OR APPENDIX C LEVEL 2 LEVEL 3 THE QUALITY ASSURANCE PROGRAM SHALL COMPLY WITH THE LEVEL DEFINED IN TABLE3.1, DEPENDING ON HOW THE MASONRY WAS DESIGNED AND THE RISK CATEGORY, AS DEFINED IN ASCE 7 OR THE LEGALLY ADOPTED BUILDING CODE DESIGNED IN ACCORDANCE WITH RISK CATEGORY I, II OR III RISK CATEGORY IV REMARKS SPECIAL INSPECTION OF MASONRY CONSTRUCTION MINIMUM QUALITY ASSURANCE LEVEL OBSERVE PREPARATION OF GROUT SPECIMENS, MORTAR SPECIMENS, AND/OR PRISMS NR P C ART. 1.4 B.2.a.3, 1.4 B.2.b.3, 1.4 B.2.c.3, 1.4 B.3, & 1.4 B.4 LEVEL 1 LEVEL 2 LEVEL 3 TMS 402 TMS 602 INSPECTION TASK FREQUENCY REFERENCE FOR CRITERIA REMARKS SPECIAL INSPECTION TASKS DURING MASONRY TESTING PLACEMENT OF AAC MASONRY UNITS AND CONSTRUCTION OF THIN-BED MORTAR JOINTS NR C / P C ART. 3.3 B.9 & 3.3 F.1.B CONTINUOUS REQUIRED FOR THE FIRST 5000 SQ. FT. (465 SQ. METERS) OF AAC MASONRY; PERIODIC REQUIRED AFTER THE FIRST 5000 SQ. FT. (465 SQ. METERS) OF AAC MASONRY PLACEMENT OF GROUT AND PRESTRESSING GROUT FOR BONDED TENDONS IN COMPLIANCE NR C C ART. 3.5 & 3.6C APPLICATION AND MEASUREMENT OF PRESTRESSING FORCE NR C C ART. 3.6B PREPARATION, CONSTRUCTION, AND PROTECTION OF MASONRY DURING COLD WEATHER (TEMPERATURE BELOW 40 DEGREES FAHRENHEIT (4.4 DEGREES CELSIUS)) OR HOT WEATHER (TEMPERATURE ABOVE 90 DEGREES FAHRENHEIT (32.2 DEGREES CELSIUS)) NR P P ART. 1.8C & 1.8D WELDING OF REINFORCEMENT NR C C SEC. 6.1.6.1.2 TYPE, SIZE, AND LOCATION OF ANCHORS, INCLUDING OTHER DETAILS OF ANCHORAGE OF MASONRY TO STRUCTURAL MEMBERS, FRAMES, OR OTHER CONSTRUCTION NR P C SEC. 1.2.1(E), 6.2.1, & 6.3.1 SIZE AND LOCATION OF STRUCTURAL MEMBERS NR P P ART. 3.3F PLACEMENT OF MASONRY UNITS AND MORTAR JOINT CONSTRUCTION NR P P ART. 3.3B MATERIALS AND PROCEDURES WITH THE APPROVED SUBMITTALS NR P P ART. 1.5 LEVEL 1 LEVEL 2 LEVEL 3 TMS 402 TMS 602 INSPECTION TASK FREQUENCY REFERENCE FOR CRITERIA REMARKS SPECIAL INSPECTION TASKS DURING MASONRY CONSTRUCTION PROPORTIONS OF SITE-PREPARED GROUT AND PRESTRESSING GROUT FOR BONDED TENDONS NR P P ART. 2.6 B & 2.4 G.1.b PLACEMENT OF REINFORCEMENT, CONNECTORS, AND ANCHOR BOLTS NR P C SEC. 6.1, 6.3.1, 6.3.6, & 6.3.7 ART. 3.2 E & 3.4 PLACEMENT OF PRESTRESSING TENDONS AND ANCHORAGES NR P P SEC. 10.8 & 10.9 ART. 2.4 & 3.6 GROUT SPACE NR P C ART. 3.2 D & 3.2 F LEVEL 1 LEVEL 2 LEVEL 3 TMS 402 TMS 602 INSPECTION TASK FREQUENCY REFERENCE FOR CRITERIA REMARKS SPECIAL INSPECTION OF MASONRY CONSTRUCTION MINIMUM VERIFICATION REQUIREMENTS SAMPLE PANEL CONSTRUCTION NR P C ART. 1.6 D PROPERTIES OF THIN-BED MORTAR FOR AAC MASONRY NR C / P C ART. 2.1 C.1 CONTINUOUS REQUIRED FOR THE FIRST 5000 SQ. FT. (465 SQ. METERS) OF AAC MASONRY; PERIODIC REQUIRED AFTER THE FIRST 5000 SQ. FT. (465 SQ. METERS) OF AAC MASONRY PRESTRESSING TECHNIQUE NR P P ART. 3.6 B GRADE, TYPE AND SIZE OF REINFORCEMENT, CONNECTORS, ANCHOR BOLTS, AND PRESTRESSING TENDONS AND ANCHORAGES NR P P ART. 3.4 & 3.6 A GRADE AND SIZE OF PRESTRESSING TENDONS AND ANCHORAGES NR P P ART. 2.4 B & 2.4 H PROPORTIONS OF SITE-PREPARED MORTAR NR P P ART. 2.1, 2.6 A, & 2.6C LEVEL 1 LEVEL 2 LEVEL 3 TMS 402 TMS 602 INSPECTION TASK FREQUENCY REFERENCE FOR CRITERIA REMARKS SPECIAL INSPECTION TASKS AS MASONRY CONSTRUCTION BEGINS DOCUMENT ACCEPTANCE OR REJECTION OF MECHANICAL FASTENERS PERFORM VERIFY REPAIR ACTIVITIES PERFORM CHECK SPACING, TYPE AND INSTALLATION OF SUPPORT, SIDELAP AND PERIMETER FASTENERS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.8 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS AFTER MECHANICAL FASTENING FASTENERS ARE INSTALLED IN ACCORDANCE WITH MANUFACTURER’S INSTRUCTIONS OBSERVE FASTENERS ARE POSITIONED AS REQUIRED 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.7 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS DURING MECHANICAL FASTENING PROPER STORAGE FOR MECHANICAL FASTENERS OBSERVE PROPER TOOLS AVAILABLE FOR FASTENER INSTALLATION OBSERVE MANUFACTURER INSTALLATION INSTRUCTIONS AVAILABLE FOR MECHANICAL FASTENERS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.6 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS PRIOR TO MECHANICAL FASTENING DOCUMENT ACCEPTANCE OR REJECTION OF WELDS PERFORM VERIFY REPAIR ACTIVITIES PERFORM WELDS MEET VISUAL ACCEPTANCE CRITERIA PERFORM VERIFY SIZE AND LOCATION OF WELDS, INCLUDING SUPPORT, SIDELAP, AND PERIMETER WELDS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.5 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS AFTER WELDING WPS FOLLOWED OBSERVE ENVIRONMENTAL CONDITIONS (WIND SPEED, MOISURE, TEMPERATURE)OBSERVE CONTROL AND HANDLING OF WELDING CONSUMABLES OBSERVE USE OF QUALIFIED WELDERS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.4 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS DURING WELDING CHECK WELDING EQUIPMENT OBSERVE MATERIAL IDENTIFICATIONS (TYPE/GRADE)OBSERVE MANUFACTURER CERTIFICATIONS FOR WELDING CONSUMABLES AVAILABLE OBSERVE WELDING PROCEDURE SPECIFICATIONS (WPS) AVAILABLE 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.3 OBSERVE TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS PRIOR TO WELDING DOCUMENT ACCEPTANCE OR REJECTION OF INSTALLATION OF DECK AND DECK ACCESORIES PERFORM VERIFY DECK MATERIALS ARE REPRESENTED BY THE MILL CERTIFICATIONS THAT COMPLY WITH THE APPROVED CONSTRUCTION DOCUMENTS PERFORM VERIFY COMPLIANCE OF DECK AND ALL DECK ACCESSORIES INSTALLATION WITH APPROVED CONSTRUCTION DOCUMENTS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.2 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS AFTER DECK PLACEMENT DOCUMENT ACCEPTANCE OR REJECTION OF DECK AND DECK ACCESSORIES PERFORM VERIFY COMPLIANCE OF MATERIALS (DECK AND ALL DECK ACCESSORIES) WITH APPROVED CONSTRUCTION DOCUMENTS, INCLUDING PROFILES, MATERIAL PROPERTIES, AND BASE METAL THICKNESS 1705.2.2 SDI 2011 – STANDARD FOR QA/QC 1.3, APP. 1 TABLE 1.1 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION TASKS PRIOR TO DECK PLACEMENT VERIFY THAT THE TEMPORARY INSTALLATION RESTRAINT/BRACING AND THE PERMANENT INDIVIDUAL TRUSS MEMBER RESTRAINT/BRACING ARE INSTALLED IN ACCORDANCE WITH THE APPROVED TRUSS SUBMITTAL PACKAGE FOR COLD-FORMED STEEL TRUSSES SPANNING 60 FEET OR GREATER 1705.2.4 APPROVED TRUSS SUBMITTAL PERIODIC INSPECTION OF WELDING REINFORCING STEEL 1705.3.1 PER CONCRETE CONSTRUCTION TABLE 1705.3 TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF STEEL CONSTRUCTION OTHER THAN STRUCTURAL STEEL INSPECT THE FABRICATED STEEL OR ERECTED STEEL FRAME TO VERIFY COMPLIANCE WITH THE DETAILS AS SHOWN ON THE CONSTRUCTIONS DOCUMENTS, SUCH AS BRACES, STIFFENERS, MEMBER LOCATIONS, AND PROPER APPLICATION OF JOINT DETAILS AT EACH CONNECTION PERIODIC PLACEMENT OF ANCHOR RODS AND OTHER EMBEDMENTS SUPPORTING STRUCTURAL STEEL: VERIFY THE DIAMETER, GRADE, TYPE, AND LENGTH OF THE ANCHOR ROD OR EMBEDDED ITEM AND THE EXTENT OR DEPTH OF EMBEDMENT INTO THE CONCRETE PRIOR TO PLACEMENT OF CONCRETE AISC N5.8 PERIODIC REVIEW THE MATERIAL TEST REPORTS AND CERTIFICATIONS FOR STEEL COMPONENTS FOR COMPLIANCE WITH THE CONSTRUCTION DOCUMENTS, INCLUDING PRIMARY STEEL ELEMENTS, STEEL CASTINGS AND FORGINGS, FASTENERS, DECK FASTENERS, ANCHOR RODS AND THREADED RODS, WELDING CONSUMABLES, HEADED STUD ANCHORS, WELDING FILLER METAL AND FLUXES, WELDING PROCEDURE SPECIFICATIONS (WPS), PROCEDURE QUALIFICATION RECORDS FOR WPS THAT ARE NOT PREQUALIFIED, WELDING PERSONNEL QUALIFICATION RECORDS AND CONTINUITY RECORDS, FABRICATOR’S WRITTEN QUALITY CONTROL MANUAL, AND ERECTOR’S QUALITY CONTROL MANUAL 1705.2.1 AISC N5.2 PERIODIC PERFORM A ONE-TIME REVIEW OF EACH APPLICABLE ITEM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTIONS OF STRUCTURAL STEEL CONSTRUCTION ISSUE DATE DESCRIP. TNMO AAN SERPOFS GNDR MENUEZ NATE J. No.15739 PE A T N IGSI E O L EREE ERIENCOPYRIGHT 2022 12/19/2022 10:17:22 AMS0.3 ISSUE FOR PERMIT 19 DEC 22 2105CITY OF BOZEMANFIRE STATION #2575 WEST KAGY BLVD, BOZEMAN, MONTANA 59715STATEMENT OF SPECIALINSPECTIONSVERIFY THE TEMPORARY INSTALLATION RESTRAINT/BRACING AND THE PERMANENT INDIVIDUAL TRUSS MEMBER RESTRAINT/BRACING ARE INSTALLED IN ACCORDANCE WITH THE APPROVED TRUSS SUBMITTAL PACKAGE FOR METAL- PLATE CONNECTED WOOD TRUSSES SPANNING 60 FEET OR GREATER 1705.5.2 APPROVED TRUSS SUBMITTAL PERIODIC HIGH-LOAD DIAPHRAGMS: INSPECT THE WOOD STRUCTURAL PANEL SHEATHING FOR CONFORMANCE WITH THE APPROVED CONSTRUCTION DOCUMENTS. VERIFY THE NOMINAL SIZE OF FRAMING MEMBERS AT ADJOINING PANEL EDGES, THE NAIL OR STABLE DIAMETER AND LENGTH, THE NUMBER OF FASTENER LINES, AND THAT THE SPACING BETWEEN FASTENERS IN EACH LINE AND AT EDGE MARGINS CONFORMS TO THE APPROVED CONSTRUCTION DOCUMENTS. 1705.5.1 PERIODIC PREFABRICATED WOOD STRUCTURAL ELEMENTS AND ASSEMBLIES: INSPECTION OF FABRICATION AND IMPLEMENTATION PROCEDURES 1705.5 PERIODIC TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF WOOD CONSTRUCTION NAILING, BOLTING, ANCHORING, AND OTHER FASTENING OF COMPONENTS WITHIN THE SEISMIC FORCE-RESISTING SYSTEM, INCLUDING WOOD SHEAR WALLS, WOOD DIAPHRAGMS, DRAG STRUTS, BRACES, SHEAR PANELS, AND HOLD-DOWNS 1705.11.1 PERIODIC NOT REQUIRED FOR SHEARWALL OR DIAPHRAGMS WHERE FASTENER SPACING IS MORE THAN 4” ON CENTER FIELD GLUING OPERATIONS OF ELEMENTS OF THE SEISMIC FORCE-RESISTING SYSTEM 1705.11.1 CONTINUOUS TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF WOOD CONSTRUCTION FOR SEISMIC RESISTANCE ANCHORAGE OF STORAGE RACKS 8 FEET OR GREATER IN HEIGHT IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY D, E, OR F 1705.12.7 PERIODIC ANCHORAGE OF ACCESS FLOORS IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY D, E, OR F 1705.12.5.1 PERIODIC ERECTION AND FASTENING OF EXTERIOR CLADDING, INTERIOR AND EXTERIOR NONBEARING WALLS, AND INTERIOR AND EXTERIOR VENEER IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY D, E, OR F 1705.12.5 PERIODIC NOT REQUIRED FOR: EXTERIOR CLADDING, INTERIOR AND EXTERIOR NONBEARING WALLS, AND INTERIOR AND EXTERIOR VENEER 30 FEET OR LESS IN HEIGHT ABOVE GRADE OR WALKING SURFACE; EXTERIOR CLADDING AND INTERIOR AND EXTERIOR VENEER WEIGHING 5 PSF OR LESS; INTERIOR NONBEARING WALLS WEIGHING 15 PSF OR LESS TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF ARCHITECTURAL COMPONENTS FOR SEISMIC RESISTANCE INSTALLATION OF MECHANICAL AND ELECTRICAL EQUIPMNENT, INCLUDING DUCT WORK, PIPING SYSTEMS AND THEIR STRUCTURAL SUPPORTS, WHERE AUTOMATIC FIRE SPRINKER LYSTEMS ARE INSTALLED IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY C, D, E OR F TO VERIFY ONE OF THE FOLLOWING: MINIMUM CLEARANCES HAVE BEEN PROVIDED AS REQUIRED BY SECTION 13.2.3 ASCE/SEI 7 OR A NOMINAL CLEARANCE OF NOT LESS THAN 3 INCHES (76 MM) HAS BEEN PROVIDED BETWEEN FIRE PROTECTION SPRINKER SYSTEM DROPS AND SPRIGS AND: STRUCTURAL MEMBERS NOT USED COLLECTIVELY OR INDEPENDENTLY TO SUPPORT THE SPRINKLERS; EQUIPMENT ATTACHED TO THE BUILDING STRUCTURE; AND OTHER SYSTEMS’ PIPING 1705.12.6.6 ASCE 7-16 SECTION 13.2.3 PERIODIC WHERE FLEXIBLE SPRINKLER HOSE FITTINGS ARE USED, SPECIAL INSPECTION OF MINIMUM CLEARANCES IS NOT REQUIRED. INSTALLATION AND ANCHORAGE OF VIBRATION ISOLATION SYSTEMS IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY C, D, E OR F WHERE THE CONSTRUCTION DOCUMENTS REQUIRE A NOMINAL CLEARANCE OF 1/4 INCH OR LESS BETWEEN THE EQUIPMENT SUPPORT FRAME AND RESTRAINT 1705.12.6.5 PERIODIC INSTALLATION AND ANCHORAGE OF DUCTWORK DESIGNED TO CARRY HAZARDOUS MATERIALS IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY C, D, E OR F 1705.12.6.4 PERIODIC INSTALLATION AND ANCHORAGE OF PIPING SYSTEMS DESIGNED TO CARRY HAZARDOUS MATERIALS AND THEIR ASSOCIATED MECHANICAL UNITS IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY C, D, E OR F 1705.12.6.3 PERIODIC ANCHORAGE OF OTHER ELECTRICAL EQUIPMENT IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY E OR F 1705.12.6.2 PERIODIC ANCHORAGE OF ELECTRICAL EQUIPMENT FOR EMERGENCY OR STANDBY POWER SYSTEMS IN STRUCTURES ASSIGNED TO SEISMIC DESIGN CATEGORY C, D, E OR F 1705.12.6.1 PERIODIC TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF MECHANICAL AND ELECTRICAL COMPONENTS FOR SEISMIC RESISTANCE PROOF TESTING OF DEEP FOUNDATION ELEMENTS PROJECT GEOTECHNICAL REPORT PERFORM CLASSIFICATION AND TESTING OF COMPACTED FILL MATERIALS TABLE 1705.6 PROJECT GEOTECHNICAL REPORT PERIODIC TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY TESTING OF SOILS AND FOUNDATIONS AT THE TIME FRESH CONCRETE IS SAMPLED TO FABRICATE SPECIMENS FOR STRENGTH TESTS, PERFORM SLUMP AND AIR CONTENT TESTS, AND DETERMINE TEMPERATURE OF CONCRETE ASTM C172 ACI 318-14: 26.4 AND 26.12 FOR EACH SPECIMEN CONCRETE STRENGTH TEST SPECIMENS TABLE 1705.3 ASTM C31 AND C39 FOR EACH CLASS OF CONCRETE (E.G. FOOTINGS, WALLS, OR SLAB ON GRADE), ONE SET OF SPECIMENS EACH DAY OR LESSER OF: ONE SET FOR EACH 150 YDS OF CONCRETE OR ONE SET FOR EACH 5,000 SQUARE FEET OF SLABS OR WALL TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY TESTING OF CONCRETE CONSTRUCTION VERIFICATION OF f’m PRIOR TO CONSTRUCTION (BY THE UNIT STRENGTH METHOD) AND DURING CONSTRUCTION (BY THE PRISM METHOD) PRIOR TO CONSTRUCTION AND FOR EACH 5,000 SQUARE FEET DURING CONSTRUCTION VERIFICATION OF PROPORTIONS OF MATERIALS IN PREMIXED OR PREBLENDED MORTAR, PRESTRESSING GROUT, AND GROUT OTHER THAN SELF-CONSOLIDATING GROUT, AS DELIVERED TO THE PROJECT SITE CONTINUOUS VERIFICATION OF SLUMP FLOW AND VISUAL STABILITY INDEX AS DELIVERED TO THE PROJECT SITE FOR SELF CONSOLIDATING GROUT 1705.4 TMS TABLE 1.19.3 TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY TESTING OF MASONRY CONSTRUCTION LEVEL 3 QUALITY ASSURANCE VERIFICATION OF f’m BY THE PRISM METHOD (3) PRISMS FOR EACH 5,000 SQUARE FEET OF WALL AREA FROM MASONRY THAT IS AT LEAST 28 DAYS OLD. VERIFICATION OF f’m PRIOR TO CONSTRUCTION BY THE UNIT STRENGTH METHOD VERIFICATION OF SLUMP FLOW AND VISUAL STABILITY INDEX AS DELIVERED TO THE PROJECT SITE FOR SELF CONSOLIDATING GROUT 1705.4 TMS TABLE 1.19.2 TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY TESTING OF MASONRY CONSTRUCTION LEVEL 2 QUALITY ASSURANCE DOCUMENT ALL WELD NON-DESTRUCTIVE TESTING PERFORMED. WHEN A WELD IS REJECTED ON THE BASIS OF WELD NON-DESTRUCTIVE TESTING, THE WELD NON-DESTRUCTIVE TESTING RECORD SHALL INDICATE THE LOCATION OF THE DEFECT AND THE BASIS OF REJECTION. AISC N5.5G DOCUMENT THERMALLY CUT SURFACES OF ACCESS HOLES SHALL BE TESTED USING MAGNETIC PARTICLE TESTING OR PENETRANT TESTING, WHEN THE FLANGE THICKNESS EXCEEDS 2 INCHES FOR ROLLED SHAPES, OR WHEN THE WEB THICKNESS EXCEEDS 2 INCHES FOR BUILT-UP SHAPES. AISC M2.2 PERFORM CJP GROOVE WELD NON-DESTRUCTIVE TESTING: ULTRASONIC TESTING SHALL BE PERFORMED ON WELDS SUBJECT TO TRANSVERSELY APPLIED TENSION LOADING IN BUTT, T- AND CORNER JOINTS, IN MATERIALS 5/16 INCHES OR THICKER 1705.2 AISC N5.5.B ALL JOINTS FOR BUILDINGS IN RISK CATEGORY III OR IV BUILDINGS; 10% OF JOINTS IN RISK CATEGORY II (INCREASE OR DECREASE RATE PER AISC N5.5F AND N5.5E, AS REQUIRED) TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY TESTING OF STEEL CONSTRUCTION DOCUMENT ACCEPTANCE OR REJECTION OF STEEL ELEMENTS PERFORM PLACEMENT AND INSTALLATION OF STEEL HEADED STUD ANCHORS PERFORM PLACEMENT AND INSTALLATION OF STEEL DECK 1705.2.1 AISC TABLE N6.1 PERFORM TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS INSPECTION OF STRUCTURAL STEEL ELEMENTS OF COMPOSITE CONSTRUCTION PRIOR TO... DOCUMENT ACCEPTANCE OR REJECTION OF BOLTED CONNECTIONS 1705.2.1 AISC TABLE N5.6-3 PERFORM SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS AFTER BOLTING STRUCTURAL STEEL FASTENERS ARE PRETENSIONED IN ACCORDANCE WITH THE RCSC SPECIFICATION, PROGRESSING SYSTEMATICALLY FROM THE MOST RIGID POINT TOWARD THE FREE EDGES OBSERVE FASTENER COMPONENT NOT TURNED BY THE WRENCH PREVENTED FROM ROTATING OBSERVE JOINT BROUGHT TO SNUG-TIGHT CONDITION PRIOR TO THE PRETENSIONING OPERATION OBSERVE FASTENER ASSEMBLIES, OF SUITABLE CONDITION, PLACED IN ALL HOLES AND WASHERS (IF REQUIRED) ARE POSITIONED AS REQUIRED 1705.2.1 AISC TABLE N5.6-2 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS DURING BOLTING STRUCTURAL STEEL (NOT REQUIRED FOR SNUG-TIGHT JOINTS) PROPER STORAGE PROVIDED FOR BOLTS, NUTS, WASHERS, AND OTHER FASTENER COMPONENTS OBSERVE PRE-INSTALLATION VERIFICATION TESTING BY INSTALLATION PERSONNEL OBSERVED AND DOCUMENTED FOR FASTENER ASSEMBLIES AND METHODS USED OBSERVE CONNECTING ELEMENTS, INCLUDING THE APPROPRIATE FAYING SURFACE CONDITION AND HOLE PREPARATION, IF SPECIFIED, MEET APPLICABLE REQUIREMENTS OBSERVE PROPER BOLTING PROCEDURE SELECTED FOR JOINT DETAIL OBSERVE PROPER FASTENERS SELECTED FOR THE JOINT DETAIL (GRADE, TYPE, BOLT LENGTH IF THREADS ARE TO BE EXCLUDED FROM SHEAR PLANE) OBSERVE FASTENERS MARKED IN ACCORDANCE WITH ASTM REQUIREMENTS 1705.2.1 AISC TABLE N5.6-1 PERFORM SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS PRIOR TO BOLTING STRUCTURAL STEEL NO PROHIBITED WELDS HAVE BEEN ADDED WITHOUT THE APPROVAL OF THE EOR OBSERVE DOCUMENT ACCEPTANCE OR REJECTION OF WELDED JOINT OR MEMBER PERFORM REPAIR ACTIVITIES PERFORM BACKING REMOVED AND WELD TABS REMOVED (IF REQUIRED BY THE CONSTRUCTION DOCUMENTS)PERFORM WELD ACCESS HOLES IN ROLLED HEAVY SHAPES AND BUILT-UP SHAPES: AFTER ROLLED HEAVY SHAPES (SEE SECTION A3.1c) AND BUILT-UP HEAVY SHAPES (SEE SECTION A3.1d) ARE WELDED, VISUALLY INSPECT THE WELD ACCESS HOLE FOR CRACKS PERFORM K-AREA: WHEN WELDING DOUBLER PLATES, CONTINUITY PLATES, OR STIFFENERS HAS BEEN PERFORMED IN THE k-AREA OF ROLLED SHAPES, VISUALLY INSPECT THE WEB FOR k-AREA CRACKS WITHIN 3” OF THE WELD PERFORM ARC STRIKES PERFORM WELDS MEET VISUAL ACCEPTANCE CRITERIA: CRACK PROHIBITION, WELD/BASE-METAL FUSION, CRATER CROSS SECTION, WELD PROFILES, WELD SIZE, UNDERCUT, POROSITY PERFORM SIZE, LENGTH, AND LOCATION OF WELDS PERFORM WELDS CLEANED 1705.2.1 AISC TABLE N5.4-3 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS AFTER WELDING STRUCTURAL STEEL PLACEMENT AND INSTALLATION OF STEEL HEADED STUD ANCHORS PERFORM WELDING TECHNIQUES: INTERPASS AND FINAL CLEANING, EACH PASS WITHIN PROFILE LIMITATIONS, EACH PASS MEETS QUALITY REQUIREMENTS OBSERVE WPS FOLLOWED: SETTINGS ON WELDING EQUIPMENT, TRAVEL SPEED, SELECTED WELDING MATERIALS, SHIELDING GAS TYPE/FLOW RATE, PREHEAT APPLIED, INTERPASS TEMPERATURE MAINTAINED, PROPER WELDING POSITION OBSERVE ENVIRONMENTAL CONDITIONS: WIND SPEED WITHIN LIMITS, PRECIPITATION AND TEMPERATURE OBSERVE NO WELDING OVER CRACKED TACK WELDS OBSERVE CONTROL AND HANDLING OF WELDING CONSUMABLES: PACKAGING, EXPOSURE CONTROL 1705.2.1 AISC TABLE N5.4-2 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS DURING WELDING STRUCTURAL STEEL FIT-UP OF FILLET WELDS: DIMENSIONS (ALIGNMENT, GAPS AT ROOT), CLEANLINESS (CONDITION OF STEEL SURFACE), TACKING (TACK WELD QUALITY AND LOCATION) OBSERVE CONFIGURATION AND FINISH OF ACCESS HOLES OBSERVE FIT-UP OF CJP GROOVE WELDS OF HSS T-, Y- AND K-JOINTS WITHOUT BACKING (INCLUDING JOINT GEOMETRY): JOINT PREPARATIONS, DIMENTIONS (ALIGNMENT, ROOT OPENING, ROOT FACE, BEVEL), CLEANLINESS (CONDITION OF STEEL SURFACES), TACKING (TACK WELD QUALITY AND LOCATION) OBSERVE FIT-UP OF GROOVE WELDS (INCLUDING JOINT GEOMETRY): JOINT PREPARATION, DIMENSIONS (ALIGNMENT, ROOT OPENING, ROOT FACE, BEVEL), CLEANLINESS (CONDITION OF STEEL SURFACES), TACKING (TACK WELD QUALITY AND LOCATION), BACKING TYPE AND FIT (IF APPLICABLE) OBSERVE WELDER IDENTIFICATION SYSTEM OBSERVE MATERIAL IDENTIFICATION (TYPE/GRADE)OBSERVE MANUFACTURER CERTIFICATIONS FOR WELDING CONSUMABLES AVAILABLE PERFORM WELDING PROCEDURE SPECIFICATIONS AVAILABLE PERFORM WELDER QUALIFICATION RECORDS AND CONTINUITY RECORDS 1705.2.1 AISC TABLE N5.4-1 OBSERVE SEE NOTES FOR EXCEPTIONS WHEN WORK IS COMPLETED BY AN APPROVED FABRICATOR/ INSTALLER TASK IBC REFERENCE REFERENCE STANDARD FREQUENCY REMARKS REQUIRED SPECIAL INSPECTION TASKS PRIOR TO WELDING STRUCTURAL STEEL ISSUE DATE DESCRIP.