Loading...
HomeMy WebLinkAbout18- RFP - Bozeman Water Reclamation Facility Solids Handling Expansion  Bozeman WRF Solids Handling Expansion RFP   Page | 1        REQUEST FOR PROPOSALS  BOZEMAN WATER RECLAMATION FACILITY SOLIDS HANDLING EXPANSION  INTRODUCTION    The City of Bozeman (“COB”) requests proposals from consultants qualified to provide professional engineering  services to expand the solids handling facility at the Bozeman Water Reclamation Facility (WRF).  The solids  process at the WRF consists of: primary clarification; primary sludge gravity thickening and fermentation;  primary sludge anaerobic digestion; secondary clarification; secondary sludge rotating screen thickening; scum  collection and dissolved air floatation/thickening; secondary sludge and scum anaerobic digestion; and screw  press thickening of digested solids.  The solids process feeds primary sludge in series through anaerobic  digesters No. 1 and No. 2.  Primary sludge is then combined with thickened secondary sludge and scum in  aerobic digester No. 3.  Digester 3 solids are dewatered through a single screw press to form a sludge cake  product that is routed on an overhead conveyor belt to the bed of a haul truck housed within an enclosed truck  bay.  The cake is then hauled off to Logan Landfill for final disposal.  The existing solids handling building is a two‐level structure consisting of basement and main‐level spaces.  The  basement is generally occupied with solids process piping, digester gas piping, a heat exchanger, high‐strength  waste tank, pumps and I&C equipment.  The main level of the building houses secondary sludge rotating screen  thickeners, coagulant storage and feed system, and a single screw press.  Current solids handling capacity is  limited by the output of the single screw press.  In the event of the screw press malfunctioning, or it being down  for routine maintenance, solids continue to accumulate in the digesters leaving limited time to put the screw  press back online before digester overflow.  Lack of screw press redundancy is the Achilles heel of the plant.  This project seeks to increase the solids handling capacity through the addition of a second/redundant screw  press.  The existing solids handling building must be expanded to provide sufficient space to place and operate  this equipment.  Additional building expansion space is also desired to shelter the two trucks used in rotation to  collect and haul sludge cake to the landfill.    With the expansion to the solids handling building, the HVAC system of the building needs evaluation and  upgrade.  The existing building HVAC is designed to operate as a 55degF space during cold weather periods.  The  existing building also suffers from inadequate ventilation, which is likely due to an imbalance in makeup and  exhaust air to and from the building.  This condition is believed to pull makeup air from the building drain  system, which has produced elevated concentrations of hydrogen sulfide in the main building space.  These  HVAC issues must be corrected with the building expansion, including upgrading the system to operate as a  68degF space during cold weather periods.    The budget available for design and construction is $1,500,000.  Attached to this RFP to aid in proposal  preparation are process diagrams and design criteria for the existing WRF facility.    Bozeman WRF Solids Handling Expansion RFP   Page | 2        PRELIMINARY SCOPE OF WORK  The preliminary scope of work involved for this project is outlined below.  Additional tasks and work elements  may be added or removed during contract negotiations with the selected consultant.  The scope below is  intended to be a guide for RFP preparation and constitutes the general scope of professional services for the  project.  In describing its particular understanding and approach for the project, respondents to this RFP may  recommend adding/removing tasks, or modification of task elements.      Proposals must clearly identify any elements of the proposed scope of work that will not be provided by the  prime consultant.  Any sub‐consultants which comprise the consultant team must be identified and a description  of past working history and relevant projects between the firms shall be provided.    The COB desires the design work be completed in a diligent manner.  Proposals must clearly indicate the  consultant’s anticipated schedule given their staffing and current and projected work load commitments.    Task 1 – Pre‐Design Investigation Phase  Consult with COB to define and clarify requirements for the project, including design objectives and constraints,  space, capacity, and performance requirements, flexibility and expandability, and any budgetary limitations, and  identify available data, information, reports, facilities plans, and site evaluations.  Prepare a report which will, as  appropriate, contain schematic layouts, sketches, and conceptual design criteria with appropriate exhibits to  indicate agreed‐to requirements, considerations involved, and Engineer’s recommended solution(s).  For each  recommended solution, Engineer will provide the following: opinion of probably construction cost, proposed  allowances for contingencies, the estimated total costs of design, professional, and related services to be  provided by Engineer.    Task 2 – Preliminary Design Phase   Conduct any necessary field investigation and survey and prepare preliminary design phase documents  consisting of final design criteria, preliminary drawings, outline specifications and written descriptions of the  project.  Based on information contained in the preliminary design phase documents, prepare a revised opinion  of probable construction cost and assist with tabulating the various cost categories which comprise total project  costs.  Task 3 – Final Design Phase  Obtain any necessary approvals from governmental authorities having jurisdiction to review or approve the final  design.  Prepare final drawings and specifications, construction contract documents and bidding related  documents and make any necessary adjustments to the opinion of probable construction cost.  Task 4 – Bidding or Negotiating Phase   Assist COB in obtaining bids for the project, attend pre‐bid conference, prepare and issue Addenda as  appropriate to clarify, correct, or change the issued bidding documents.  Review bids and Contractor references  and qualifications for performing the work and provide a recommendation to COB for contract award.    Task 5 – Construction Phase  Consult with COB and act as COB’s construction representative as provided in the construction contract.  Provide  the services of a resident project representative for extensive observation of the Contractor’s work.  Receive,  review, and determine the acceptability of any and all schedules that Contractor is required to submit to    Bozeman WRF Solids Handling Expansion RFP   Page | 3        Engineer.  Review and approve or take other appropriate action with respect to Shop Drawings, Samples, and  other required Contractor submittals.  Recommend Change Orders and Work Change Directives to COB.  Review  and respond to Change Proposals or claims.  Review Contractor’s applications for payment and make  recommendations to COB for payments to Contractor.  Receive from Contractor, review and transmit to COB  maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of  insurance required by construction contract.  Task 6 – Post Construction Phase  Together with COB, visit the project prior to the close of the required 2‐year warranty period to observe any  apparent defects in the work, make recommendations as to replacement or correction of defective work or the  need to repair any damage to the site or adjacent areas and assist COB in consultations and discussions with  Contractor concerning correction of any such defective work.  PROPOSAL REQUIREMENTS  Five (5) copies of the proposal, and one electronic searchable PDF file, must be submitted no later than 5:00 pm  on December 13, 2018 to the City Clerk at the physical address below.  Proposals shall be individually bound and  presented in a neat and orderly fashion.  Please note that the USPS will not deliver mail to this location.   Proposals must be shipped or hand delivered.  Late proposals will not be considered.     City Clerk, City of Bozeman   121 N. Rouse Ave., Suite 200   Bozeman, MT  59715    Proposals shall, at a minimum, include the following items:     A narrative describing the consultant’s particular understanding and approach for the project.  Specific  challenges should be identified along with unique solutions proposed to complete project tasks and  achieve project goals.     A proposed work plan indicating tasks to be accomplished, work schedule, consultant personnel and  sub‐consultants expected to perform each major task element, prior work history of consultant and sub‐ consultants, and the involvement anticipated of COB staff (and timing and nature of that involvement).       Qualifications of key individuals assigned to the project, their availability during the relevant time  periods, and their recent experience on similar projects.     References for key individuals of the consultant and sub‐consultants whom have performed similar work  within the last five years, and two examples of work produced under similar contracts (examples of  projects utilizing the key personnel identified for this proposal are preferred).     A completed and signed Non‐Discrimination Affirmation Form (see Attachment A).      Bozeman WRF Solids Handling Expansion RFP   Page | 4         A marked‐up version of desired changes, if any, to the COB’s template professional services agreement.   Changes desired shall be made using the Track Changes feature in MS Word.  If no changes are desired,  then a statement to this affect shall be provided with the proposal response.      CONSULTANT SELECTION  A consultant selection committee consisting of key COB staff will choose, in its opinion, the most qualified  consultant to provide services required for the project.  Proposals will be evaluated on the following criteria and  the requirements of MCA 18‐8‐201 et seq.       The consultant’s specific project approach and understanding;     Qualifications of professional personnel to be assigned to the project;     Capability to meet project time and budget requirements;     Location of the consultant in relation to project;     Present and projected workloads;     Related experience on similar projects;     Recent and current work for the COB.    A determination of finalists will be made by the selection committee based on review and evaluation of the  written proposals received.  The COB reserves the right to interview finalists to aid in its consultant selection but  does not guarantee that interviews will occur.  The selection committee will choose, in its sole determination,  the most‐qualified consultant to perform professional services for the project.  Contract negotiations will  proceed after selection and will take into account the estimated value of services to be rendered, as well as the  scope, complexity and professional nature thereof, in order to arrive at a contract which the COB determines to  be fair and reasonable.    If the COB is unable to negotiate a satisfactory contract with the consultant initially selected at a price the COB  determines to be fair and reasonable, negotiations with that consultant will be formally terminated and the COB  will select another consultant in accordance with MCA 18‐8‐204 and continue until an agreement is reached or  the process is terminated.  ADDITIONAL INFORMATION AND CONDITIONS  COB CONTACT:  Questions or requests for additional information regarding this project or RFP requirements  may be directed to:       Bozeman WRF Solids Handling Expansion RFP   Page | 5         Brian Heaston, PE   City of Bozeman – Engineering   PO Box 1230   Bozeman, MT  59771 ‐1230     406‐582‐2280   bheaston@bozeman.net    NON‐DISCRIMINATION POLICY:  Discrimination in the performance of any contract awarded under this  request for proposal on the basis of race, color, religion, creed, sex, age, marital status, national origin, or actual  or perceived sexual orientation, gender identity or disability is prohibited.  This prohibition shall apply to the  hiring and treatment of the awarded entity’s employees and to all subcontracts. Every entity submitting under  this request for proposal must sign and return the attached affirmation statement with their bound response to  this request for proposal.    ATTACHMENTS:   Non‐Discrimination Affirmation Form (must be signed and submitted with RFP response)   Existing WRF process diagrams and design criteria   Template Professional Services Agreement (email bheaston@bozeman.net for editable MS Word  Document)       Bozeman WRF Solids Handling Expansion RFP   Page | 6        ATTACHMENT A: NON‐DISCRIMINATION AFFIRMATION FORM             [name of entity proposing] hereby affirms it will not  discriminate on the basis of race, color, religion, creed, sex, age, marital status, national origin, or because of  actual or perceived sexual orientation, gender identity, or disability in the performance of work performed for  the City of Bozeman, if a contract is awarded to it, and also recognizes the eventual contract, if awarded, will  contain a provision prohibiting discrimination as described above and that this prohibition shall apply to the  hiring and treatment of the        [name of entity proposing] employees  and to all subcontracts it enters into in the performance of the agreement with the City of Bozeman.      Signature of Proposer:              Person authorized to sign on behalf of the proposer    A/C AIR CONDITIONING CLKG CAULKING F TO F FACE TO FACE ID INSIDE DIAMETER, INTERIOR DIMENSION N NORTH, NEUTRAL R&R REMOVE AND REPLACE TOB TOP OF BOLT, TOP OF BANK, TOP OF BEAM, TOP OF BERM A/E ARCHITECT/ENGINEER CLR CLEAR F&B FACE AND BYPASS IE INVERT ELEVATION, FOR EXAMPLE NA NOT APPLICABLE R&S REMOVE AND SALVAGE TOC TOP OF CURB, TOP OF CONCRETEA AMPERE CMH COMMUNICATION MANHOLE FAB FABRICATE IF INSIDE FACE NAT NATURAL, NATIONAL R RADIUS, REGISTER, RISER TOD TOP OF DUCTAB ANCHOR BOLT CMP CORRUGATED METAL PIPE FB FLOOR BEAM IH INTAKE HOOD NC NORMALLY CLOSED RA RETURN AIR TOF TOP OF FOOTINGABAN ABANDON CMU CONCRETE MASONRY UNIT FBD FIBERBOARD IMP IMPACT NEG NEGATIVE RB RESILIENT BASE, ROCK BERM TOG TOP OF GRATINGABC AGGREGATE BASE COURSE CO CLEANOUT, CONCRETE OPENING FBG FIBERGLASS IN INCH NF NEAR FACE, NON-FUSED RCPT RECEPTACLE TOL TOLERANCE, TOP OF LEDGERABT ABOUT COL COLUMN FBM BOARD FOOT MEASURE INC INCLUDE, INCANDESCENT NIC NOT IN CONTRACT RD ROOF DRAIN TOM TOP OF MASONRYAC ALTERNATING CURRENT COMB COMBINATION FBO FURNISHED BY OWNER INF INLFUENT NO NORMALLY OPEN, NUMBER REC RECESS TOP TOP OF PLATE ACK ACKNOWLEDGE COMM COMMUNICATION FC FLUSHING CONNECTION INSTR INSTRUMENTATION NOM NOMINAL RECD RECEIVED TOPO TOPOGRAPHY ACP ACOUSTIC CEILING PANEL, ASPHALTIC CONCRETE PAVEMENT COMP COMPOSITION, COMPRESSIBLE, COMPOSITE FCA FLANGED COUPLING ADAPTER INSUL INSULATION NPS NOMINAL PIPE SIZE RECT RECTANGULAR TOS TOP OF SLAB, TOP OF STEEL, TOE OF SLOPE ACST ACOUSTIC CON CONCENTRIC FD FLOOR DRAIN INT INTERIOR, INTERSECTION NPT NATIONAL PIPE THREAD RED REDUCER TOW TOP OF WALLAD ADDENDUM, AREA DRAIN CONC CONCRETE FDC FLEXIBLE DUCT CONNECTION INTR INTERMEDIATE, INTERIOR NS NEAR SIDE REF REFERENCE TP TOILET PARTITION, TELEPHONE POLE,TOE PLATE, TRAP PRIMERADDL ADDITIONAL CONN CONNECTION FDR FEEDER INV INVERT NTS NOT TO SCALE REINF REINFORCING TPD TOILET PAPER DISPENSERADH ADHESIVE CONST CONSTRUCTION FDTN FOUNDATION IPS IRON PIPE SIZE NWL NORMAL WATER LEVEL REM REMOVE TPG TOPPING, THROUGH PLATE GIRDERADJ ADJUSTABLE, ADJACENT CONT CONTINUOUS FE FLANGED END IPT INTERNAL PIPE THREAD REQD REQUIRED TR TRANSOM AF AMP FRAME, AMP FUSE COOR COORDINATE FEC FIRE EXTINGUISHER CABINET IR INSIDE RADIUS, IRON ROD O TO O OUT TO OUT RESIL RESILIENT TRANS TRANSITION AFF ABOVE FINISH FLOOR CORR CORROSIVE, CORRUGATED FES FLARED END SECTION IRR IRRIGATION OA OUTSIDE AIR, OVERALL RET RETAINING, RETURN TRD TRENCH DRAIN AFG ABOVE FINISH GRADE CP CHECKER PLATE, CONTROL POINT FEXT FIRE EXTINGUISHER ISO ISOMETRIC OC ON CENTER REV REVISION, REVERSE TYP TYPICAL AGGR AGGREGATE CPLG COUPLING FF FAR FACE, FACTORY FINISH, FLAT FACE OCPD OVER CURRENT PROTECTION DEVICE RF RESILIENT FLOORINGAI AREA INLET, ANALOG INPUT CRL CORROSION-RESISTANT LINING FG FINISHED GRADE JB JUNCTION BOX OD OUTSIDE DIAMETER RFG ROOFING U URINALAIC AMPS INTERRUPTING CAPACITY CSC COMPRESSION SLEEVE COUPLING FH FIRE HYDRANT JCT JUNCTION OED OPEN END DUCT RFL REFLECTED, REFLECTOR UG UNDERGROUNDALIG ALIGNMENT CSK COUNTERSINK FIG FIGURE JF JOINT FILLER OF OUTSIDE FACE, OFFICE FURNISHING RGH ROUGH ULT ULTIMATEALT ALTERNATE, ALTITUDE CSS CLINIC SERVICE SINK FIN FINISH JST JOIST OFCI OWNER FURNISHED CONTRACTOR INSTALLED RGS RIGID GALVANIZED STEEL UNFN UNFINISHED ALUM ALUMINUM CT CERAMIC TILE FJT FLUSH JOINT JT JOINT OFOI OWNER FURNISHED OWNER INSTALLED RGS-PVC PVC COATED RGS UNO UNLESS NOTED OTHERWISE AM ACOUSTICAL MATERIAL CTJ CONTRACTION JOINT FL FLOW, FLOW LINE OG ORIGINAL GROUND RH RELIEF HOOD, RIGHT HAND, RELATIVE HUMIDITY UTIL UTILITY AMB AMBIENT CTR CENTER FLEX FLEXIBLE K KIP OH OVERHEAD RL REQUIRED LAP ANC ANCHOR CTRL CONTROL FLG FLANGE KB KNEE BRACE OPNG OPENING RLFA RELIEF AIR V VENT, VELOCITY, VOLTAO ANALOG OUTPUT CVT CULVERT FLOR FLOURESCENT KCMIL THOUSAND CIRCULAR MILS OPP OPPOSITE RND ROUND VA VOLT AMPEREAP ACCESS PANEL CU COPPER, CUBIC FLR FLOOR KD KNOCK DOWN OPT OPTIONAL RNG RUNNING VAC VACUUMAPRX APPROXIMATE CW CLOCKWISE FLS FLASHING, FLUSH KO KNOCK OUT OR OUTSIDE RADIUS RO ROUGH OPENING VAR VARNISH, VARIABLE,VOLT AMPERES REACTIVEAPVD APPROVED CY CUBIC YARD FN FENCE KSI KIPS PER SQUARE INCH ORD OVERFLOW ROOF DRAIN ROW RIGHT-OF-WAY VB VAPOR BARRIER, VINYL BASE, VALVE BOX ARCH ARCHITECTURAL FO FINISHED OPENING KW KILOWATT ORIG ORIGINAL RPM REVOLUTIONS PER MINUTE VC VERTICAL CURVE ASSY ASSEMBLY d PENNY (NAIL MEASURE) FOB FLAT ON BOTTOM OVFL OVERFLOW RR RAILROAD VCP VITRIFIED CLAY PIPE AT ACOUSTICAL TILE, AMP TRIP D DEEP, DIFFUSER, DRAIN FOC FACE OF CONCRETE, FACE OF CURB L ANGLE, LENGTH, LAVATORY, LINTEL OVHG OVERHANG RSP ROCK SLOPE PROTECTION VCT VINYL COMPOSITION TILE, VERTICAL CENTERLINEATC ACOUSTICAL TILE CEILING DB DUCT BANK, DECIBEL, DRY BULB FOF FACE OF FINISH LAD LADDER OZ OUNCE RT RIGHT VEL VELOCITYATM ATMOSPHERE DBA DEFORMED BAR ANCHOR FOM FACE OF MASONRY LAM LAMINATE RVT RESILIENT VINYL TILE VENT VENTILATIONAUTO AUTOMATIC DBL DOUBLE FOS FACE OF STUDS LATL LATERAL P PAINT RY READY VERT VERTICALAUX AUXILIARY DC DIRECT CURRENT FOT FLAT ON TOP LB LAG BOLT, POUND PA PUBLIC ADDRESS VERTS VERTICAL REINFORCINGAVE AVENUE DEG DEGREE FPT FEMALE PIPE THREAD LCTB LIQUID CHALK AND TACK BOARD PAR PARALLEL, PARAPET S SOUTH, SINK VG VERTICAL GRAIN AVG AVERAGE DEG C DEGREE CENTIGRADE FR FRAME LDG LANDING PB PANIC BAR, PULL BOX SA SUPPLY AIR VIF VERIFY IN FIELD AWG AMERICAN WIRE GAGE DEG F DEGREE FAHRENHEIT FRP FIBERGLASS REINFORCED PLASTIC LDR LEADER PBD PARTICLE BOARD SAMU SOUND-ABSORBING MASONRY UNIT VIN VINYL AWT ACOUSTICAL WALL TILE DEMO DEMOLITION FRTM FIRE RETARDANT TREATED MATERIAL LE LIFTING EYE PC POINT OF CURVE, PIECE, PRECAST SAN SANITARYVOLVOLUME DEP DEPRESSED FS FLOOR SINK, FAR SIDE LF LINEAR FOOT PCC POINT OF COMPOUND CURVATURE SB SPLASH BLOCK VPC VERTICAL POINT OF CURVATURE DEPT DEPARTMENT FT FEET, FOOT LG LONG PCF POUNDS PER CUBIC FOOT SC SOLID CORE VPI VERTICAL POINT OF INTERSECTIONB TO B BACK TO BACK DET DETAIL FTG FOOTING, FITTING LH LEFT HAND PCT PERCENT SCH SCHEDULE VPT VERTICAL POINT OF TANGENCYBAL BALANCE DI DROP INLET, DUCTILE IRON, DIGITAL INPUTFUR FURRED, FURRING LIN LINEAR PE PLAIN END SCHEM SCHEMATIC VS VERSUS, VAPOR SEALBBD BULLETIN BOARD DIA DIAMETER FURN FURNITURE, FURNISH LIQ LIQUID PED PEDESTAL SCN SCREEN VTR VENT THROUGH ROOFBC BASE CABINET, BOTTOM CHORD.BOLT CENTER, BOLT CIRCLE DIAG DIAGONAL, DIAGRAM FUT FUTURE LLH LONG LEG HORIZONTAL PEN PENETRATION SE STEEL/ALUMINUM EDGE VWC VINYL WALL COVERING BD BOARD DIFF DIFFERENTIAL, DIFFERENCE FV FACE VELOCITY LLV LONG LEG VERTICAL PERF PERFORATED SEC SECONDARY, SECONDS BE BOTH ENDS, BELL END DIM DIMENSION FW FIELD WELD, FIRE WALL LMLU LIQUID MARKER LECTURE UNIT PERM PERMANENT SECT SECTION W/ WITH BF BOTH FACES, BOTTOM FACE, BLIND FLANGE, BOARD FEET DISCH DISCHARGE FWD FORWARD LNG LONGITUDINAL PERP PERPENDICULAR SEP SEPARATE W/O WITHOUT BITUM BITUMINOUS DIST DISTANCE, DISTRIBUTION FEW FURNISHED WITH EQUIPMENT LOC LOCATION PF POWER FACTOR SF SQUARE FOOT, SILT FENCE W WATT, WEST, WIDE, WINDOW, WIREWIDE FLANGE BEAMBKG BACKING DIV DIVISION FXTR FIXTURE LP LOW POINT PFMU PREFACED MASONRY UNIT SG SHEET GLASS, SEALANT GROOVE WB WOOD BASEBL BASE LINE DL DEAD LOAD LPS LOW-PRESSURE SODIUM PH PHASE SH SHOWER WC WATER CLOSET, WATER COLUMNBLDG BUILDING DMJ DOUBLE MECHANICAL JOINT G GRILLE, GROUND LR LONG RADIUS PI POINT OF INTERSECTION SHT SHEET WD WOOD, WIDTHBLK BLOCK DMPF DAMP PROOFING GA GAGE (METAL THICKNESS) LT LEFT PKG PACKAGE SHTG SHEATHING WF WIDE FLANGE, WASH FOUNTAIN BLKG BLOCKING DN DOWN GAL GALLON LTD LIMITED PL PLATE, PROPERTY LINE, PRECAST LINTEL SIL SILENCE WG WIRE GLASS, WATER GAGE BM BENCHMARK, BEAM DO DISSOLVED OXYGEN, DIGITAL OUTPUT DITTO GALV GALVANIZED LTG LIGHTING PLAS PLASTER SIM SIMILAR WH WALL HYDRANT, WEEP HOLE BOC BACK OF CURB DP DEPTH GB GRAB BAR, GRADE BREAK LTL LINTEL PLAT PLATFORM SJ SLAB JOINT WI WROUGHT IRONBOD BOTTOM OF DUCT DPDT DOUBLE POLE, DOUBLE THROW GC GROOVED COUPLING LTNG LIGHTING PLBG PLUMBING SL SLOPE, STEEL LINTEL WL WATER LEVELBOG BOTTOM OF GRILLE DPST DOUBLE POLE, SINGLE THROW GD GUARD LV LOW VOLTAGE PLF POUNDS PER LINEAR FOOT SLTD SLOTTED WLD WELDEDBOL BOTTOM OF LOUVER, BOLLARD DS DOWN SPOUT GEN GENERAL LVL LAMINATED VENEER LUMBER PNEU PNEUMATIC SLV SLEEVE WM WIRE MESHBOP BOTTOM OF PIPE DT DOUBLE TEE, DRIP TRAP ASSEMBLY GFCI GROUND FAULT CIRCUIT INTERRUPTER LVR LOUVER POL POLISH SMLS SEAMLESS WP WEATHERPROOFBOR BOTTOM OF REGISTER DUP DUPLICATE GFMU GROUND FACE MASONRY UNIT LW LIGHTWEIGHT POS POSITIVE, POSITION SOG SLAB ON GRADE WS WATERSTOP, WATER SURFACEBOT BOTTOM DWG DRAWING GG GUTTER GRADE LWC LIGHTWEIGHT CONCRETE PP POLYPROPYLENE, POWER POLE SP SOUNDPROOF, STANDPIPE WSCT WAINSCOT BOU BOTTOM OF UNIT DWL DOWEL GJ GROOVED JOINT LWL LOW WATER LEVEL PRC POINT OF REVERSE CURVATURE SPA SPACING WT WEIGHT, WATER TIGHT BP BASE PLATE DWR DRAWER GL GLASS PREF PREFINISHED SPEC SPECIFICATION WTHP WATERPROOF, WORKING POINT BRG BEARING GLB GLASS BLOCK, GLULAM BEAM MA MIXED AIR PREFAB PREFABRICATED SPLY SUPPLY WWF WELDED WIRE FABRIC BRGP BEARING PLATE E EAST GND GROUND MACH MACHINED PRELIM PRELIMINARY SPST SINGLE POLE SINGLE THROWBRKT BRACKET EA EACH, EXHAUST AIR GP GUY POLE MAINT MAINTENANCE PREP PREPARE SPT SET POINT XP EXPLOSION-PROOFBS BOTH SIDES EC ELECTRICAL CONTRACTOR GR GRADE MAN MANUAL PRES PRESSURE SQ SQUARE XS EXTRA STRONGBTU BRITISH THERMAL UNIT ECC ECCENTRIC GRTG GRATING MATL MATERIAL PRI PRIMARY SR SHORT RADIUS XSECT CROSS SECTIONBTW BETWEEN ED EQUIPMENT DRAIN GSB GYPSUM SHEATHING BOARD MAX MAXIMUM PROP PROPERTY, PROPOSED SS SERVICE SINK XXS DOUBLE EXTRA STRONGBTWLD BUTT WELD EDB ELECTRICAL DUCT BANK GT GREASE TRAP MB MACHINE BOLT PROT PROTECTION SST STAINLESS STEELBU BELL UP, BUILT-UP EE EACH END GVL GRAVEL MBR MEMBER PS PIPE SUPPORT ST STREET YH YARD HYDRANT BUR BUILT-UP ROOFING EF EACH FACE GW GUY WIRE MC MECHANICAL CONTRACTOR, MECHANICAL COUPLING, MOMENT CONNECTION PSF POUNDS PER SQUARE FOOT STA STATION YS YIELD STRENGTH BW BOTH WAYS EFF EFFLUENT, EFFICIENCY GWB GYPSUM WALLBOARD MCB METAL CORNER BEAD PSI POUNDS PER SQUARE INCH STD STANDARDBYP BYPASS EHH ELECTRICAL HANDHOLE GYP GYPSUM HARDBOARD MCJ MASONRY CONTROL JOINT PSIA POUNDS PER SQUARE INCH ABSOLUTE STIF STIFFENEREIFS EXTERIOR INSULATION & FINISH SYSTEM MDMJ MODIFIED DOUBLE MECHANICAL JOINT PSIG POUNDS PER SQUARE INCH GAGE STIR STIRRUPC TO C CENTER TO CENTER EJ EXPANSION JOINT H HIGH MECH MECHANICAL PST PRESTRESSED STL STEELC&G CURB AND GUTTER EL ELBOW, ELEVATION HB HOSE BIBB MED MEDIUM PT POINT, POINT OF TANGENCY STOR STORAGEC CHANNEL SHAPE, CENTIGRADE, CONDUIT ELEC ELECTRICAL HBD HARDBOARD MFR MANUFACTURER PTN PARTITION STR STRUCTURAL, STRAIGHT CAB CABINET EMBD EMBEDDED HC HANDICAPPED, HOLLOW CORE, HORIZONTAL CURVE, HORIZONTAL CENTERLINE MH MANHOLE, METAL HALIDE PVC POLYVINYL CHLORIDE, POINT OF VERTICAL CURVE SUB SUBSTITUTE CAP CAPACITY EMER EMERGENCY HD HEAD, HOT DIP MIN MINIMUM PVMT PAVEMENT SUC SUCTIONCAT CATALOG, CATEGORY EMH ELECTRICAL MANHOLE HDR HEADER MIR MIRROR PWD PLYWOOD SUSP SUSPENDEDCAV CAVITY ENCL ENCLOSURE HDW HARDWARE MISC MISCELLANEOUS PWJ PLYWOOD WEB JOIST SY SQUARE YARDCB CATCH BASIN ENGR ENGINEER HEX HEXAGONAL MJ MECHANICAL JOINT PZ PIEZOMETER SYM SYMBOLCCB CONCRETE BLOCK ENTR ENTRANCE HGR HANGER ML MASONRY LINTEL SYMM SYMMETRICALCCW COUNTER CLOCKWISE EOP EDGE OF PAVEMENT HH HANDHOLE MLO MAIN LUGS ONLY Q RATE OF FLOW SYN SYNTHETIC CDF CONTROLLED-DENSITY FILL EQ EQUAL HID HIGH-INTENSITY DISCHARGE MMB MEMBRANE QT QUARRY TILE SYS SYSTEM CE CONCRETE EDGE EQUIP EQUIPMENT HM HOLLOW METAL MO MASONRY OPENING QTR QUARTER CER CERAMIC EQUIV EQUIVALENT HORIZ HORIZONTAL MOD MODULAR, MODIFY QTY QUANTITY T&B TOP AND BOTTOM CF CUBIC FEET (FOOT) ES EACH SIDE, EQUAL SPACE, EMERGENCY SHOWER HP HIGH POINT, HORSEPOWER MON MONUMENT QUAL QUALITY T&G TONGUE AND GROOVE CFL COUNTER FLASHING ESEW EMERGENCY SHOWER AND EYE WASH HPC HORIZONTAL POINT OF CURVATURE MPT MALE PIPE THREAD T TILE, TREADCHBD CHALKBOARD EST ESTIMATE HPS HIGH-PRESSURE SODIUM MRGWB MOISTURE-RESISTANTGYPSUM WALLBOARD TA TOILET ACCESSORY, TEMPERED AIR CHD CHORD EW EACH WAY, EMERGENCY EYE/FACE WASH HPT HORIZONTAL POINT OF TANGENCY MS MOP SINK TAN TANGENTCHFR CHAMFER EWC ELECTRIC WATER COOLER HR HOSE REEL, HOUR MSL MEAN SEA LEVEL TBM TEMPORARY BENCHMARK CHH COMMUNICATION HANDHOLE EWEF EACH WAY, EACH FACE HS HEADED STUD, HIGH STRENGTH MT MOUNT TCE TEMPORARY CONSTRUCTION EASEMENT CI CURB INLET EWTB EACH WAY,TOP AND BOTTOM HSS HOLLOW STRUCTURAL SHAPE MU MASONRY UNIT TEF TROWELED EPOXY FLOORING CIP CAST-IN-PLACE EXC EXCAVATION HT HEIGHT MULL MULLION TEMP TEMPORARY, TEMPERATURE CIPD CONCRETE INTERLOCKING PAVER BALLASEXH EXHAUST HTG HEATING MV MEDIUM VOLTAGE THD THREADCIRC CIRCULATION, CIRCULAR EXP EXPANSION, EXPOSED HV HIGH VOLTAGE MW MONITORING WELL THK THICKCJ CONSTRUCTION JOINT EXST EXISTING HVAC HEATING, VENTILATING AND AIR CONDITIONING THRESH THRESHOLD CKT CIRCUIT EXT EXTERIOR, EXTERNAL, EXTENSION HWD HARDWOOD TKBD TACK BOARDCL CENTERLINE, CLASS, CLOSE HWL HIGH WATER LEVELCLG CEILING HYD HYDRAULIC HZ HERTZ, CYCLES PER SECOND GENERAL NOTES: 1. THESE ABBREVIATIONS APPLY TO THE ENTIRE SET OF CONTRACT DRAWINGS. 2. LIST OF ABBREVIATIONS DOES NOT IMPLY THAT ALL ABBREVIATIONS ARE USED IN THE CONTRACT. 3. ABBREVIATIONS SHOWN ON THIS SHEET INCLUDE VARIATIONS OF A WORD. FOR EXAMPLE, "MOD" MAY MEAN MODIFY OR MODIFICATION; "INC" MAY MEAN INCLUDED OR INCLUDING AND "REINF" MAY MEAN EITHER REINFORCE OR REINFORCING. 4. SEE INSTRUMENTATION LEGEND SHEET FOR PROJECT-SPECIFIC EQUIPMENT SYMBOLS, EQUIPMENT ABBREVIATIONS, AND PIPING SYSTEM ABBREVIATIONS. 1 PROFESSIONAL SERVICES AGREEMENT THIS IS AN AGREEMENT made as of , between THE CITY OF BOZEMAN, a Municipal Corporation, Bozeman, Montana, 59715 (OWNER) and , Montana, (ENGINEER). Whereas the accomplishment of the work and services described in this Agreement is essential to the OWNER'S public works improvement program. Whereas the OWNER intends to and has selected the ENGINEER to provide necessary and professional engineering services for the project. Whereas the ENGINEER represents that it is willing and qualified to perform the professional engineering services for this project described in this Agreement. Therefore, in consideration of the foregoing recitals and the mutual covenants and conditions contained herein, the parties agree as follows: The conditions and provisions set forth in the attached EXHIBIT A (insert title), EXHIBIT B (insert title) , and EXHIBIT C (insert title) , are hereby incorporated in and made part of this Agreement. ARTICLE 1 - ENGINEERING SERVICES 1.1. The detailed description of the specific project components is described as follows: (Insert detailed project description) 1.2. The scope of services under this contract is set forth in this agreement and the attached EXHIBITS. ARTICLE 2 - ENGINEER'S RESPONSIBILITIES 2.1. ENGINEER shall perform for OWNER professional engineering services in all phases of the Project to which this Agreement applies as hereinafter provided. These services will include, but not be limited to, serving as OWNER's professional engineering representative for the Project, providing professional engineering consultation and advice and furnishing customary civil and structural engineering services incidental thereto. 2.2. The ENGINEER shall furnish all labor, materials, equipment, supplies, and incidentals necessary to conduct and complete the ENGINEER'S portions of the Project and to prepare and deliver to the OWNER all data, reports, plans, specifications, and recommendations as designated herein. 2.3. The ENGINEER shall ascertain such information as may have a bearing on the work from local units of government, public, and private organizations and shall be authorized to procure information from other authorities as to the extent of these contacts and the results thereof. 2.4. The ENGINEER'S work shall be in accordance with the standards of sound engineering practices. 2.5. The ENGINEER shall name a Principal-In-Charge for the duration of the project. The Principal-In-Charge shall be . 2.6. The ENGINEER shall name a Project Manager who shall be the liaison between the ENGINEER and the OWNER. The Project Manager shall be . The OWNER may name a Task Director 2 who would be the liaison between the ENGINEER and the OWNER during the design segment of the Project. 2.7. The ENGINEER shall submit an estimated progress schedule at the beginning of the work, and monthly progress reports thereafter until the project is completed. ARTICLE 3 - OWNER'S RESPONSIBILITIES 3.1 The OWNER shall name a Task Director who shall be the liaison between the ENGINEER and the OWNER during DESIGN segment of the Project. The Task Director designated shall be . 3.2 The OWNER shall have the right of review and examination of the ENGINEER'S work at all times. 3.3 The OWNER shall make available all records (record drawings, construction records, etc.) indicating the existing configuration of the city utilities. 3.4 The OWNER will be responsible for Advertising Bid Openings. 3.5 The OWNER shall attend the pre-bid conferences, bid openings, pre-construction conferences, construction progress and other job related meetings, substantial completion inspections and final payment inspections. ARTICLE 4 - BASIC ENGINEERING SERVICES The ENGINEER shall render professional Engineering Services as follows: 4.1 PRE-DESIGN INVESTIGATION PHASE After written authorization to proceed, ENGINEER shall: 4.1.1 Consult with OWNER to clarify and define OWNER's requirements for the Project and review available data. 4.1.2 Advise OWNER as to the necessity of OWNER's providing or obtaining from others, data or services and assist OWNER in obtaining such data or services. 4.1.3 Identify and analyze requirements of governmental authorities having jurisdiction to approve the design of the Project and participate in consultations with such authorities. 4.1.4. Provide analyses of OWNER's needs, planning surveys, site evaluations and comparative studies of prospective sites and solutions. 4.1.5. Provide a general economic analysis of OWNER's requirements applicable to various alternatives. 4.1.6 Assist in formation of Special Improvement Districts (SID) by preparing district boundary descriptions and maps, preparing a property owner's and assessments role lists including project assessment costs based on the preliminary project cost estimates, and providing technical information at SID public hearings, if applicable. 4.1.7. Prepare a Report containing schematic layouts, sketches and conceptual design criteria with appropriate exhibits to indicate clearly the considerations involved (including applicable requirements of governmental authorities having jurisdiction as aforesaid) and the alternative solutions available to OWNER and setting forth ENGINEER's findings and recommendations. This Report will be accompanied by ENGINEER's opinion of probable costs for the Project, including the following which will be separately itemized: Construction Cost, allowance for engineering costs and contingencies, and (on the basis of information furnished by OWNER) allowances for such other items as charges of all other professionals and consultants, for the cost of land and rights-of-way, for compensation for or damages to properties, for interest and financing charges and for other services to be provided by others for Owner. The total of all 3 such costs, allowance, etc. are hereinafter called "Total Project Costs". 4.1.8. Furnish copies and an electronic copy of the Study and Report documents and review them in person with OWNER. The Pre-design Investigation Phase will be completed and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.2 PRELIMINARY DESIGN PHASE After acceptance of the pre-design report and receipt of written authorization to proceed with the Preliminary Design Phase, ENGINEER shall: 4.2.1. In consultation with OWNER determine general scope, extent and character of the Project. 4.2.2. ENGINEER shall then prepare a Preliminary Design Report, preliminary plans and specifications and a written description for the Project. 4.2.3. Preliminary Design Report: Specific items to be addressed in the design report will include, but not be limited to: 4.2.3.1. Summary of construction requirements with appropriate drawings for each task included in the project. 4.2.3.2. Plans for providing water and sewer services for affected properties during construction. 4.2.3.3. Summary geotechnical report for specific tasks, if needed. 4.2.3.4. Special design considerations for Project tasks with conditions not covered in standard construction methods or specifications. 4.2.3.5. A traffic control plan for each project task, if necessary. 4.2.4. Design and Construction Survey: The ENGINEER shall conduct a design field survey of the project areas, as necessary, for locating existing utilities (such as gas, power, telephone, TV cables, water and sewer lines, irrigation facilities, fences, and approach driveways), existing right-of-way and easements, and making measured drawings of or investigating conditions of existing facilities. The ENGINEER shall provide suitable horizontal and vertical reference control points for the construction phase. 4.2.5. Permits and Rights-of-Way: The ENGINEER shall obtain approved permits, licenses, and/or easement agreements from private landowners and any other agencies or entities requiring similar approvals prior to bidding. These approvals will be coordinated with the OWNER and will be made on easement and permit documents approved by the OWNER. Information and easement descriptions provided in the Basic Engineering Services will be based on data available from design surveys and courthouse records. 4.2.6. Geotechnical Explorations and Analysis: The ENGINEER shall conduct such geotechnical explorations and analysis as necessary for project design and bidding. A geotechnical report will be prepared with recommendations relating to conditions pertinent to the design and construction of the Project. Subsurface information will be obtained by reviewing any existing geotechnical data available and using additional backhoe test pits and soil borings as necessary. The ENGINEER shall furnish copies of a geotechnical report as requested to OWNER for use by OWNER and Contractors, and review the results of the report with Contractors in a pre-bid meeting. The report is to be prepared for design purposes; ENGINEER will not be responsible if it is used by others for other purposes. 4 4.2.7. Preliminary Plans and Specifications. Prepare preliminary construction plans and specifications with information which addresses the special features of each project task. 4.2.8. Based on the information contained in the preliminary design documents, ENGINEER will submit a revised opinion of probable Total Project Costs to the OWNER. 4.2.9. ENGINEER shall prepare and furnish complete paper and electronic copies of preliminary bidding documents and design report as requested to OWNER and at the same time furnish copies as directed by OWNER to agencies and/or parties having regulatory responsibilities or direct financial participation in any part of the Project; provide any technical criteria, written descriptions and design data necessary for securing permits or approval from authorities having jurisdiction to review and approve the design, and assist owner in securing such approvals; and review documents in person with OWNER and review authorities, and, if necessary, conduct a plan-in-hand site review. All changes agreed to between ENGINEER and OWNER will be noted in a memorandum from the ENGINEER to the OWNER and incorporated into the final plans and specifications. The Preliminary Design Phase will be completed and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.3 FINAL DESIGN PHASE After written authorization to proceed with the Final Design Phase, ENGINEER shall: 4.3.1. On the basis of the accepted Preliminary Design documents and the revised opinion of probable Total Project Costs, prepare for incorporation in the Contract Documents final drawings and Technical Specifications of sufficient detail to show the general scope, extent and detailed character of the work to be furnished and performed by the Contractor(s) suitable for use in the project bidding and construction. 4.3.2. Advise OWNER of any adjustments to the latest opinion of probable Total Project Costs caused by changes in general scope, extent or character or design requirements of the Project or Construction Costs. Furnish to OWNER a revised opinion of probable Total Project Costs based on the Drawings and Specifications. 4.3.3. Prepare for review and approval by OWNER, its legal counsel and other advisors, contract agreement forms, general conditions and supplementary conditions, and (where appropriate) bid forms, invitations to bid and instructions to bidders, special provisions, technical specifications, and standard drawings, and other related contract documents in conformance with the latest edition of the Montana Public Works Standard Specifications (MPWSS) and City of Bozeman Modifications to MPWSS adopted by the City of Bozeman. 4.3.4. Furnish OWNER six copies and an electronic copy of the Contract Documents (including design drawings, specifications and contracts). The Final Phase will be complete and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.4 BIDDING OR NEGOTIATING PHASE After written authorization to proceed with the Bidding or Negotiating Phase, ENGINEER shall: 4.4.1. Assist OWNER in advertising for and obtaining bids or negotiating proposals for construction contract(s) and record prospective bidders to whom Bidding Documents have been issued, receive and process deposits for Bidding Documents and conduct pre-bid conferences. 4.4.2. Provide interpretation or clarification to prospective bidders regarding the Bidding Documents, and issue addenda as appropriate. 5 4.4.3. Consult with and advise OWNER as to the acceptability of the prime contractor, subcontractors, suppliers and other persons and organizations proposed by the prime contractor(s) (herein call "Contractor(s)") for those portions of the work as to which such acceptability is required by the Bidding Documents. 4.4.4. Consult with OWNER concerning and determine the acceptability of substitute materials and equipment proposed by Contractor(s) when substitution prior to the award of contracts is allowed by the Bidding Documents. 4.4.5. Attend the Bid opening, prepare bid tabulation, evaluate bids, assess bidders' responsiveness and responsibility and make award recommendation to OWNER. 4.4.6 Facilitate contract award, and the execution and distribution of the contract documents for construction, materials, equipment and services. Furnish Owner two original signature sets of executed contract documents (including design drawings, specifications and contracts). Furnish contractor with one set of original signature executed contract documents and up to three sets of construction documents. 4.5 CONSTRUCTION PHASE The responsibilities of the ENGINEER during the Construction Phase are summarized as follows: 4.5.1. General Administration of Construction Contract. ENGINEER shall consult with and advise OWNER and act as OWNER'S representative as provided in EXHIBIT A - ENGINEER'S STATUS DURING CONSTRUCTION, attached to and made part of this Agreement and may be further provided under the General Conditions of the contract documents. The extent and limitations of the authority, duties, and responsibilities of the ENGINEER on the construction job site as assigned here-in shall not be modified except as the ENGINEER may otherwise agree in writing. All of OWNER's instruction to Contractor(s) will be issued through ENGINEER who will have authority to act on behalf of OWNER to the extent provided in the General Conditions except as otherwise provided in writing. In addition to the services provided under Article 10 (Exhibit A) the ENGINEER shall provide the following services during construction: 4.5.1.1 Schedule and conduct a pre-construction conference. 4.5.1.2 Provide personnel, equipment and supplies for construction layout and control, including establishment of line, grade, and blue top control staking. 4.5.1.3 Review Contractors' construction schedules and operations, and the Contractors' traffic control plans and its implementation prior to the start of construction. 4.5.1.4 Ascertain that the Contractor has secured required permits needed to accomplish his work. 4.5.1.5 Prepare and provide weekly activity and progress reports to the City's Task Director. 4.5.1.6 ENGINEER shall provide OWNER copies of all correspondence between the ENGINEER and Contractor. 4.5.1.7 Issue stop and resume work orders, in whole or in part, when work is not or cannot be performed in accordance with the Contract Documents. 4.5.1.8 Review and approve, for conformance with the project technical specifications all shop drawings, and other Contractor submittals required by the Contract Documents. 4.5.1.9 During construction review Contractors' construction schedules and evaluate conformance and progress under the Contract time provisions. 6 4.5.1.10 Prepare for OWNER'S approval any plan and specification changes which due to any initial design or engineering deficiencies are required to complete the project original design concept. 4.5.1.11 Inspect the project and when appropriate, and after conferring with OWNER, issue a Certificate of Substantial Completion to the Contractor. 4.5.1.12 Prior to recommending final payment, schedule and conduct with the OWNER a final project inspection and submit a report to the OWNER documenting any outstanding items or deficiencies requiring correction prior to final payment. Upon satisfactory project completion ENGINEER shall certify in writing to the OWNER, and any required regulatory agencies, that the construction was completed in accordance with the approved plans and specifications and is performing in accordance with the design concept. 4.5.1.13 Twenty-three months after project substantial completion schedule and conduct with the Owner a Two Year Warranty Inspection of the project and advise the owner in writing whether project deficiencies exist and if the project is performing in accordance with the design concept. 4.5.2. Resident Project Representative. ENGINEER shall provide a qualified Resident Project Representative at the job site to provide observation of the work as provided in EXHIBIT B - A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE, attached to and made part of this Agreement. The ENGINEER shall submit to the OWNER, for review and acceptance, the resume of each Resident Project Representative who may be assigned to the job site during the course of the Project not less than 10 calendar days prior to the pre-construction meeting. Any subsequent change in the resident representative shall also be subject to the OWNER'S approval. 4.5.3 Limitations of Responsibilities. ENGINEER will not be responsible for CONTRACTOR's means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, and ENGINEER will not be responsible for CONTRACTOR's failure to perform or furnish the Work in accordance with the Contract Documents; however, nothing contained in this agreement shall be construed to release ENGINEER from liability for failure to properly perform duties and responsibilities assumed by ENGINEER in the Contract Documents. 4.6. PROJECT DOCUMENTATION ENGINEER shall furnish OWNER with (a) one mylar copy, two paper copies, and an electronic copy of the Project Record Drawings ("As-Builts"), (b) written monthly progress reports, and (c) a project notebook containing such correspondence and documentation as requested by OWNER. 4.7. CONSTRUCTION TESTING The inspection services shall include material testing and verification of contract compliance with job site requirements, plans and specifications. The ENGINEER shall provide and maintain detailed documentation of the following material testing: 1) Concrete strength, air content and slump 2) Embankment, trench backfill, and gravel and pavement densities 3) Aggregate gradations 4) Plant mix strength, flow and asphalt content 7 ARTICLE 5 - ADDITIONAL SERVICES 5.1. If OWNER wishes ENGINEER to perform any of the following Additional Services, OWNER shall so instruct ENGINEER in writing, and ENGINEER shall perform or obtain from others such services and will be paid therefor as provided in the Agreement: 5.1.1. Legal land surveys performed to obtain data for preparing easements and rights-of-way descriptions. 5.1.2. Preparation of applications and supporting documents for governmental agencies in addition to those required under Basic Services; preparation or review of environmental studies and related services; and assistance in obtaining environmental approvals. 5.1.3. Services resulting from significant changes in the general scope, extent or character of the Project or major changes in documentation previously accepted by OWNER where changes are due to causes beyond ENGINEER's control. 5.1.4. Providing renderings or models. 5.1.5. Preparing documents for alternate bids requested by OWNER for work not executed or for out-of- sequence work. 5.1.6. Providing other services not otherwise provided for in the Agreement, including services normally furnished by the OWNER as elsewhere herein described. 5.1.7. Furnishing the services of independent professional associates or consultants for other than Basic Services. 5.2. When required by the Contract Documents in circumstances beyond ENGINEER's control, ENGINEER shall perform or obtain from others any of the following Additional Services as circumstances require during construction and without waiting for specific instructions from OWNER, and ENGINEER will be paid therefor as provided in this Agreement: 5.2.1. Services in connection with work directive changes and change orders to reflect the changes requested by OWNER if the resulting change in compensation for Basic Services is not commensurate with the additional services rendered. 5.2.2. Services in making revisions to Drawings and Specifications occasioned by the OWNER'S acceptance of substitutions proposed by Contractor(s); services after the award of each contract in evaluating and determining the acceptability of an unreasonable or excessive number of substitutions proposed by Contractor; and evaluating an unreasonable or extensive number of claims submitted by Contractor(s) or others in connection with the work. 5.2.3. Services resulting from significant delays, changes or price increases occurring as a direct result of materials, equipment or energy shortages. 5.2.4. Additional or extended services during construction made necessary by (1) work damage by fire or other causes during construction, (2) a significant amount of defective or neglected work of any Contractor, (3) acceleration of the progress schedule involving services beyond normal working hours, (4) default by any Contractor. ARTICLE 6 - COMPENSATION FOR ENGINEERING SERVICE 8 6.1 LUMP SUM AGREEMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER 6.1.1 Payment. The OWNER shall for design phase services performed as Basic Engineering Services under sections 4.1 through 4.3 of this agreement pay a total sum in the amount of $ for such services. 6.1.2 Payment Schedule. Total cumulative payments for the design phase engineering services (sections 4.1 through 4.4) shall not exceed the following ceilings: $ (10 % of design fee) until the Pre-design Investigation and Preliminary Design Report have been submitted to the OWNER. $ (50% of design fee) until the Preliminary Plans and Specifications have been submitted to the OWNER and review authorities. $ (90% of design fee) until the Final Plans and Specifications have been submitted to the OWNER and review authorities. 6.1.3 General. Engineer shall submit monthly statements for services rendered. The statements shall be based upon Engineer's estimate of the proportion of the total services actually completed at the time of billing, subject to any limitations on Payments based on completion of tasks or specific retainage requirements pursuant to the payment provisions of the Agreement. 6.1.4 Reimbursable Expenses. Only those expenses specifically identified for payment under section 6.2 of this Agreement are reimbursable. All other design related expenses are included in the Lump Sum Payment for the Basic services (4.1 through 4.4) and are not separately reimbursable. Additional Services specifically identified under the scope of design services for payment under 6.1 are not separately reimbursable. 6.2 DIRECT LABOR COST PAYMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER. Construction and project documentation services performed as Basic Engineering Services under sections 4.4 through 4.7 including General Administration of Construction Contract, Resident Project Representation, Project Documentation, and Construction Testing, shall be compensated in accordance with the following: 6.2.1 The OWNER shall pay for Construction Phase and Project Documentation Services an amount not to exceed except as provided under 6.2.1.2 and 6.2.4. 6.2.1.1 Costs Compensation. Compensation for these services shall be based on the ENGINEER's Direct Labor Cost times a factor of for services rendered which shall cover Direct Labor, Direct Labor Overhead, General & Administrative Overhead and Profit. 6.2.1.2 Notification. At any time during the construction that it becomes apparent that the Construction Phase and Project Documentation Services rendered under this Agreement will exceed the negotiated compensation for these services, and prior to performing services in excess of the contract ceiling, the ENGINEER shall give OWNER written notice thereof. Promptly thereafter OWNER and ENGINEER shall review the scope and progress of the project work. ENGINEER shall obtain written authorization from OWNER, prior to any additional costs being incurred under paragraph 6.2.1.3. If it is determined that due to a change in project scope under paragraph 5.2.1, the ENGINEER is entitled to additional compensation, OWNER and ENGINEER may negotiate terms as provided under 6.2.1.1. The amount and terms of any additional compensation under 6.2.1.1 or 6.2.1.3 shall be negotiated and agreed in writing pursuant to 9.16. 6.2.1.3 Costs Exceeding Estimated Compensation. Except as allowed under 5.2.1, when the total cost of the original scope Construction Phase and Project Documentation Services exceeds the negotiated 9 compensation for these services, the OWNER shall pay only for the direct costs incurred in excess of the estimated compensation. These costs consist of an amount equal to the ENGINEER'S Direct Labor Cost times a factor of for services rendered which shall include Direct Labor, the federally audited payroll Direct Labor Overhead, and General & Administrative Overhead costs, but shall not include any allowance for profit. 6.2.2. Reimbursable Expenses, as defined in section 7.4 of this Agreement, for Basic Services and Approved Additional Services shall be paid to the ENGINEER by the OWNER in the actual amount of the costs incurred up to an amount not to exceed $ which includes $ for consultants employed by the Engineer and $ for all other reimbursable expenses. The estimated reimbursable expenses are identified in Exhibit " ". 6.2.3. Failed Test Expenses. The ENGINEER shall maintain and provide to the OWNER, a record of the costs associated with failing quality control tests performed for the OWNER during the course of the construction of the project and recommend an amount the OWNER deduct from the contractor(s) payments. 6.2.4 The OWNER shall pay an amount for Additional Services rendered by the ENGINEER and approved in writing by the OWNER on the basis of the ENGINEER'S Direct Labor Costs times a factor of , or an amount otherwise negotiated at the time such services are requested and approved by the OWNER. ARTICLE 7 - MEANING OF TERMS 7.1 AGREEMENT As used herein the term "this Agreement" refers to the contents of this document and its Exhibits attached hereto and referred to as if they were part of one and the same document. 7.2 CONSTRUCTION COSTS The construction cost of the entire Project (herein referred to as "Construction Cost") means the total cost to OWNER of those portions of the entire Project designed and specified by ENGINEER, but it will not include ENGINEER's compensation and expenses, the cost of land, rights-of-way, or compensation for or damages to, properties unless this Agreement so specifies, nor will it include OWNER's legal, accounting, insurance counseling or auditing services, or interest and financing charges incurred in connection with the Project or the cost of other services to be provided by others to OWNER. 7.3 DIRECT LABOR COSTS Direct Labor Costs used as a basis for payment mean the actual salaries and wages paid to all ENGINEER's personnel engaged directly on the Project, including, but not limited to, engineers, architects, surveyors, designers, drafters, specification writers, estimators, other technical and business personnel; but does not include indirect payroll related costs or fringe benefits. For the purposes of this Agreement the principals and employees of the ENGINEER maximum billable Direct Labor Costs are: Principals $ /hour Project Manager $ /hour Senior Engineer $ /hour Staff Engineer $ /hour Senior Technicians $ /hour CADD Drafter $ /hour 10 Technicians $ /hour Construction Inspector $ /hour Two Person Survey Crew $ /hour Clerical $ /hour 7.4 REIMBURSABLE EXPENSES Reimbursable Expenses mean the actual expenses incurred by ENGINEER or ENGINEER's independent professional associates or consultants directly in connection with the Project, such as expenses for: transportation and subsistence incidental thereto; obtaining bids or proposals from Contractor(s); subsistence and transportation of Resident Project Representatives and their assistants; toll telephone calls and telegrams; reproduction of reports, Drawings, Specifications, Bidding Documents and similar Project-related items; and if authorized in advance by OWNER, overtime work requiring higher than regular rates. In addition, when compensation for Basic Services is on the basis of Direct Labor Costs method of payment, Reimbursable Expenses will also include the amount billed to ENGINEER by special consultants employed by ENGINEER and authorized by OWNER (other than as an authorized Additional Services) and will also include expenses incurred for computer time and other specialized equipment, including an appropriate charge for previously established programs and expenses of photographic production techniques. ARTICLE 8 - PAYMENT PROVISIONS 8.1 TIMES OF PAYMENTS. ENGINEER may submit monthly statements for Basic Services and approved Additional Services rendered and for Reimbursable Expenses incurred; however, payments shall not exceed the ceilings provided in 6.1 and 6.2. Final payment shall be made only after acceptance of the project by the OWNER. If OWNER disputes the amount of the billing, OWNER will notify the ENGINEER in writing within ten (10) calendar days of the receipt of bill of the dispute. 8.2 REQUESTS FOR PAYMENT. Each request for payment shall include a documentation summary of the period incremental man hours incurred, direct labor rates and billed rates, detail of reimbursable costs, total period billing, and total cumulative billing. When requested by OWNER services for distinct project segments shall be accounted and billed separately. 8.3 PAYMENT UNDER TERMINATION. In the event of termination by the OWNER upon the completion of any phase of the Basic Services, progress payments due ENGINEER for services rendered through such phase shall constitute total payment for such services. In the event of such termination by OWNER during any phase of the Basic Services, ENGINEER also will be reimbursed for the charges of pre-approved independent professional associates and consultants employed by ENGINEER to render Basic Services, and paid for services rendered during that phase on the basis of the payment provisions of the Agreement. In the event of any such termination, ENGINEER will be paid for unpaid pre- approved Additional Services and unpaid Reimbursable Expenses which are authorized under this agreement. ARTICLE 9 - GENERAL CONSIDERATIONS 9.1 TERMINATION OF AGREEMENT 9.1.1 The sole right is hereby reserved to the OWNER to terminate this Engineering Agreement for any and all causes or for its convenience at any time upon fifteen (15) days written notice to the ENGINEER. 11 9.1.2 If termination for default is effected by the OWNER, an equitable adjustment in the price provided for in this Agreement shall be made, but (1) no amount shall be allowed for anticipated profit on unperformed services or other work, and (2) any payment due to the ENGINEER at the time of termination may be adjusted to cover any additional costs to the OWNER because of the ENGINEER's default. If termination for convenience is effected by the OWNER, the equitable adjustment shall include a reasonable profit, as determined by owner, for services or other work performed. The equitable adjustment for any termination shall provide for payment to the ENGINEER for services rendered and expenses incurred prior to the termination, in addition to termination settlement costs reasonably incurred by the ENGINEER relating to commitments which had become firm prior to the termination. 9.1.3 Upon receipt of a termination action under paragraph 9.1.2, the ENGINEER shall (1) promptly discontinue all affected work (unless the notice directs otherwise), and (2) deliver or otherwise make available to the OWNER within ten (10) days copies of all data, design drawings, specifications, reports, estimates, summaries and such other information and materials as may have been accumulated by the ENGINEER in performing this Agreement, whether completed or in process. 9.1.4 In the event this Contract is terminated prior to completion, the original copies of the ENGINEER'S data, recommendations, plans, specifications, analysis and other related documents prepared by the ENGINEER prior to said termination shall be delivered to and become the property of the OWNER. 9.1.5 Upon termination, the OWNER may take over the work and may award another party an Agreement to complete the work under this Agreement. 9.1.6 OWNER'S right to terminate is in addition to any other remedies OWNER may have under the law. 9.2 INSPECTION AND AUDIT All books, papers, records, payrolls, vouchers and invoices relating to costs and expenditures incurred as to the performance of the services by the ENGINEER hereunder shall be made available to the OWNER, or their authorized representatives for audit and review, at the ENGINEER'S respective offices at all reasonable times during the contract period and for three years from the date of final payment. 9.3 EMPLOYMENT The ENGINEER warrants that he has not employed or retained any company or persons, other than a bona fide employee, working solely for the ENGINEER, to solicit to secure this contract, and that he has not paid or agreed to pay any company or person, other than bona fide employees working solely for the ENGINEER, any fee, commission, percentage, brokerage fee, gifts or any other considerations contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, the OWNER shall have the right to annul the Contract without liability or in its discretion to deduct from the price or consideration or otherwise recover the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. All employees of the ENGINEER or other persons while engaged in the performance of work or services required by the ENGINEER shall be considered employees of the ENGINEER only and not of the OWNER. 9.4 NONDISCRIMINATION The ENGINEER will have a policy to provide equal employment opportunity in accordance with all applicable state and federal anti-discrimination laws, regulations, and contracts. 12 The ENGINEER will not refuse employment to a person, bar a person from employment, or discriminate against a person in compensation or in a term, condition, or privilege of employment because of race, color, religion, creed, political ideas, sex, age, marital status, national origin, actual or perceived sexual orientation, gender identity, physical or mental disability, except when the reasonable demands of the position require an age, physical or mental disability, marital status or sex distinction. The ENGINEER shall be subject to and comply with Title VI of the Civil Rights Act of 1964; Section 140, Title 2, United States Code, and all regulations promulgated thereunder. The ENGINEER shall require these nondiscrimination terms of its sub-consultants providing services under this agreement. 9.5 SUBLETTING OR ASSIGNING OF WORK The ENGINEER shall not sublet or assign any of the work covered herein without prior written approval of the OWNER. 9.6 STANDARD OF CARE In providing services under this agreement, the ENGINEER will perform in a manner consistent with the degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances. If any service should be found to be not in conformance with this standard, the ENGINEER shall, at the OWNER’s request, re- perform the service at its own expense. Engineer shall also, at its own expense, make such changes, modifications or additions to the project which are made necessary as a result of the initial non-performance or the re-performance of services. The OWNER’s rights herein are in addition to any other remedies the OWNER may have under the law. 9.7 LEGAL RELATIONS: 9.7.1 The ENGINEER shall, consistent with the standard care, comply with those Federal, State, and Local laws and ordinances applicable to the work to be done. 9.7.2 The ENGINEER agrees to defend, indemnify and hold harmless the OWNER, its officers, directors, agents and employees from and against any suit, cause of action, claim, cost, expenses, obligation and liability of any character, including attorney’s fees, which is brought or asserted for any bodily injury, death, or physical damage to property received or sustained by any person, persons, property, business or any other entity, arising out of or resulting from, or in connection with the ENGINEER’S negligent performance of the work specified in this agreement. 9.7.3. The ENGINEER agrees to defend, indemnify and hold harmless the OWNER, its officers, directors, agents and employees, should OWNER, its officers, directors, agents or employees be named as a defendant in any action where the OWNER’S alleged liability arises from the negligent performance of the ENGINEER’S work herein described. The obligations of the ENGINEER to defend, indemnify and hold harmless the OWNER will apply to any suit, cause of action, claim, cost or obligation including, without limitation, those alleged under the common law or pursuant to a federal or state statute or regulation including those arising in tort, trespass, nuisance, and strict liability. 9.7.4 In the event the OWNER is found proportionately responsible for any damages ultimately awarded to a plaintiff or plaintiffs in any lawsuit, the ENGINEER will be responsible for only those damages, costs, or liabilities as are attributable to the ENGINEER’S percent of fault as compared with 100% of the fault giving rise to the damages. Should the OWNER be found responsible for negligence by its own officers, directors, agents or employees, then in that event the OWNER agrees to reimburse the ENGINEER for the reasonable attorney’s fees and costs incurred in any defense of the OWNER in an amount proportional to the fault attributed to the 13 OWNER. The indemnity required herein shall not be limited by reason of the specification of any particular insurance coverage in this Agreement. 9.7.5 Should either OWNER or ENGINEER be held responsible, for any damages, costs or liabilities resulting from intentional misconduct by any officer, director, agent or employee in connection with the work specified in this Agreement, then in that event, that party shall defend, indemnify and hold harmless the other as to any damages, costs or liabilities that result from or arise out of that intentional misconduct, including reasonable attorney’s fees and costs which shall include costs and salary of the city attorney or other in-house counsel. Further, notwithstanding the obligations set forth in paragraphs 9.7.2 and 9.7.3 above, the ENGINEER agrees to defend OWNER where the OWNER’S alleged liability arises from intentional misconduct by the ENGINEER. Should the OWNER be found responsible for intentional misconduct by its own officer, director, agent or employee, then OWNER agrees to reimburse ENGINEER for the reasonable attorney’s fees and costs incurred in any defense of the OWNER. 9.7.6 The ENGINEER shall perform this agreement as an independent contractor, and as such, is responsible to the OWNER only as to the results to be obtained in the work herein specified, and to the extent that the work shall be done in accordance with the terms, plans and specifications. The ENGINEER shall have and maintain complete control over all of its employees, subcontractors, agents and operations, being responsible for any required payroll deductions and providing required benefits, such as, but not limited to worker’s compensation with statutory limits, and unemployment insurance. 9.8 INSURANCE The ENGINEER shall secure and furnish to the OWNER certificate of insurance, therein, naming the OWNER as an additional insured, to include thirty (30) days notice of cancellation or non-renewal. Without limiting any of ENGINEER's obligations hereunder, ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, insurance coverage naming the OWNER as additional insured with minimum insurance coverage as follows: 14 Type of Coverage Limits Employers' Liability: $ 100,000. per accident General Liability: Bodily Injury & Property Damage Single and combined $ 1,000,000. per accident General Aggregate: $ 2,000,000. Excess Liability Coverage (umbrella) $1,000,000. each occurrence Automobile: Bodily Injury covering all $ 1,000,000 each person automobiles, trucks, tractors, trailers, or $ 1,000,000 each occurrence other automotive equip- ment whether owned or rented by Engineer or owned by employees of Engineer. Property Damage covering $ 100,000 each occurrence all automobiles, trucks, tractors, trailers or other automotive equipment whether owned or rented by Engineer or owned by employees of Engineer OR Bodily Injury & Property $1,000,000 each occurrence Damage Single and combined In addition to the above insurance coverage, the ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, and without naming OWNER as an additional insured, professional errors and omissions coverage as follows: Professional Errors & Omissions: $ 1,000,000 per claim and aggregate each occurrence 9.9 ENDORSEMENT The ENGINEER shall place his endorsement on all drawings and other data furnished by him. 15 9.10 OWNERSHIP OF DOCUMENTS The parties admit and agree the documents produced under this agreement are not intended or represented to be suitable for reuse by OWNER or any other individual on any other project. Any reuse without written verification or adaptation by ENGINEER will be at OWNER’s sole risk and without liability or legal exposure to ENGINEER, or to ENGINEER’s independent professional associates or consultants. Files in electronic media format of text, data, graphics, or of other types that are furnished by ENGINEER to OWNER are only for convenience of owner. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. 9.11 PUBLIC INFORMATION The ENGINEER shall not issue any statements, releases or information for public dissemination without prior approval of the OWNER. 9.12 PROPRIETARY RIGHTS If patentable discoveries or inventions should result from work required herein, all rights accruing from such discoveries or inventions shall be joint property of the ENGINEER and the OWNER. Provided that the OWNER, state agencies or political subdivisions and the United States Government shall have the irrevocable, nonexclusive, nontransferable and royalty-free license to use each invention in the manufacture, use and disposition, according to law, of any article or material, and in the use of any method that may be developed as part of the work described and contemplated herein. 9.13 RECORDS The ENGINEER shall maintain accounting records and other evidence pertaining to the cost incurred and to make the records available at all reasonable times during the Contract term and for one (1) year from the date of final payment. Such accounting records and other evidence pertaining to the cost incurred will be made available for inspections by OWNER. 9.14 SUCCESSORS IN INTEREST The covenants, agreements and all statements in this Contract apply to and shall be binding on the heirs, personal representatives, successors and assigns of the respective parties. 16 9.15 ATTORNEY'S FEES AND COSTS That in the event it becomes necessary for either Party of this Contract to retain an attorney to enforce any of the terms or conditions of this Contract or to give any notice required herein, then the prevailing Party or the Party giving notice shall be entitled to reasonable attorney's fees and costs, including fees, salary, and costs of in-house counsel to include City Attorney. 9.16 MODIFICATIONS AND AMENDMENTS That any amendment or modification of this Contract or any provisions herein shall be made in writing or executed in the same manner as this original document and shall after execution become a part of this Contract. In witness Whereof, the Parties hereto do make and execute this Agreement. CITY OF BOZEMAN, MONTANA ENGINEER BY: BY: (City Manager) (President) DATE: DATE: ATTEST: BY: (City Clerk) 1 EXHIBIT A TO AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES ENGINEER'S STATUS DURING CONSTRUCTION This Exhibit is attached to, made a part of and incorporated by reference with the Agreement made on , between CITY OF BOZEMAN (OWNER) and (ENGINEER) providing for professional engineering services. ARTICLE 10 - ENGINEER'S STATUS DURING CONSTRUCTION 10.1. OWNER’S REPRESENTATIVE ENGINEER will be OWNER's representative during the construction period. The duties and responsibilities and the limitations of authority of ENGINEER as OWNER's representative during construction are set forth in the Contract Documents and shall not be extended without written consent of OWNER and ENGINEER. 10.2. VISITS TO THE SITE ENGINEER will make visits to the site at intervals appropriate to the various stages of construction to observe the progress and quality of the executed Work and to determine, in general, if the Work is proceeding in accordance with the Contract Documents. ENGINEER will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. ENGINEER's efforts will be directed toward providing for OWNER's greater degree of confidence that the completed Work will conform to the Contract Documents. On the basis of such visits and on-site observations as an experienced and qualified design professional, ENGINEER will keep OWNER informed of the progress of the Work and will endeavor to guard OWNER against defects and deficiencies in the Work. 10.3. PROJECT REPRESENTATION If OWNER and ENGINEER agree, ENGINEER will furnish a Resident Project Representative to assist ENGINEER in observing the performance of the Work. The duties, responsibilities and limitations of authority of any such Resident Project Representative and assistants will be as provided in EXHIBIT B, A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE. 10.4. CLARIFICATIONS AND INTERPRETATIONS ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the requirements of the Contract Documents (in the form of Drawings or otherwise) as ENGINEER may determine necessary, which shall be consistent with or reasonably inferable from the overall intent of the Contract Documents. If CONTRACTOR believes that a written clarification or interpretation justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree to the amount or extent thereof, CONTRACTOR may make a claim therefor as provided in the General Provisions of the construction Contract Document. 10.5. AUTHORIZED VARIATIONS IN WORK ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Time and are consistent with the overall intent of the Contract Documents. These may be accomplished by a Field Order and will be binding on OWNER, and also on CONTRACTOR who shall perform the Work involved promptly. If CONTRACTOR believes that a Field Order justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree as 2 to the amount or extent thereof, CONTRACTOR may make a claim therefor as provided in the General Conditions of the Construction Contract. 10.6. REJECTING DEFECTIVE WORK ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, and will also have authority to require special inspection or testing of the Work as provided in the General Provisions of the construction Contract Document whether or not the work is fabricated, installed, or completed. 10.7. SHOP DRAWINGS, CHANGE ORDERS AND PAYMENT 10.7.1. The ENGINEER's responsibility for Shop Drawings and samples shall comply with the shop drawing provisions of the General Provisions of the construction Contract Document 10.7.2. The ENGINEER's responsibilities for Change Orders shall comply with the change order provisions of the General Provisions of the construction Contract Document. 10.7.3. The ENGINEER's responsibilities for contractor's Application for Payment shall comply with the payment provisions of the General Provisions of the construction Contract Document. 10.8. DETERMINATIONS FOR UNIT PRICES ENGINEER will determine the actual quantities and classifications of Unit Price Work performed by CONTRACTOR. ENGINEER will review with CONTRACTOR the ENGINEER's preliminary determinations on such matters before rendering a written recommendation thereon (by recommendation of an Application for Payment or otherwise) to OWNER. 10.9. DECISION ON DISPUTES 10.9.1. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. Claims, disputes and other matters relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the performance and furnishing of the Work and claims under The General Conditions of the Construction Contract in respect of changes in the Contract Price or Contract Time will be referred initially to ENGINEER in writing with a request for a formal decision in accordance with this paragraph, which ENGINEER will render in writing within a reasonable time. Written notice of each such claim, dispute and other matter shall be promptly reported and copied to the OWNER. 10.9.2. When functioning as interpreter under paragraphs 10.8 and 10.9.1, ENGINEER will not show partiality to OWNER or CONTRACTOR and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to paragraphs 10.8 and 10.9.1 with respect to any such claim, dispute or other matter will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any such claim, dispute or other matter. 3 10.10. LIMITATIONS ON ENGINEER'S RESPONSIBILITIES 10.10.1. Neither ENGINEER's authority to act under this Article or elsewhere in the Contract Documents nor any decision made by ENGINEER in good faith either to exercise or not exercise such authority shall give rise to any duty or responsibility of ENGINEER to CONTRACTOR, any Sub-contractor, any Supplier, or any other person or organization performing any of the Work, or to any surety for any of them. 10.10.2. Whenever in the Contract Documents the terms "as ordered", "as directed", "as required", "as allowed", "as approved" or terms of like effect or import are used, or the adjectives "reasonable", "suitable", "acceptable", "proper" or "satisfactory" or adjectives of like effect or import are used to describe a requirement, direction, review or judgment of ENGINEER as to the Work, it is intended that such requirement, direction, review or judgment will be solely to evaluate the Work for compliance with the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective shall not be effective to assign to ENGINEER any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of paragraph 4.5.3. 1 EXHIBIT B TO AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE. This Exhibit is attached to, made a part of and incorporated by reference with the Agreement made on , between CITY OF BOZEMAN (OWNER) and (ENGINEER) providing for professional engineering services. ARTICLE 11 - DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE ENGINEER shall furnish a Resident Project Representative (RPR), assistants and other field staff to assist ENGINEER in observing performance of the work of Contractor. Through more extensive on-site observations of the work in progress and field checks of materials and equipment by the RPR and assistants, ENGINEER shall endeavor to provide further protection for OWNER against defects and deficiencies in the work of CONTRACTOR; but, the furnishing of such services will not make ENGINEER responsible for or give ENGINEER control over construction means, methods, techniques, sequences or procedures or for safety precautions or programs, or responsibility for CONTRACTOR's failure to perform the Work in accordance with the Contract Documents and in particular the specific limitations set forth in section 4.5 of the Agreement are applicable. The duties and responsibilities of the RPR are limited to those of ENGINEER in this agreement and in the construction Contract Documents, and are further limited and described as follows: 11.1. GENERAL RPR is ENGINEER's agent at the site, will act as directed by and under the supervision of ENGINEER, and will confer with ENGINEER regarding RPR's actions. RPR's dealings in matters pertaining to the on-site work shall in general be with ENGINEER and CONTRACTOR keeping OWNER advised as necessary. RPR's dealings with subcontractors shall only be through or with the full knowledge and approval of CONTRACTOR. RPR shall generally communicate with OWNER with the knowledge of and under the direction of ENGINEER. 11.2. DUTIES AND RESPONSIBILITIES OF RPR 11.2.1. Schedules: Review the progress schedule, schedule of Shop Drawing submittals and schedule of values prepared by CONTRACTOR and consult with ENGINEER concerning acceptability. 11.2.2. Conferences and Meetings: Attend meetings with CONTRACTOR, such as preconstruction conferences, progress meetings, job conferences and the project-related meetings, and prepare and circulate copies of minutes thereof. 11.2.3. Liaison: 11.2.3.1. Serve as ENGINEER's liaison with CONTRACTOR, working principally through CONTRACTOR's superintendent and assist in understanding the intent of the Contract Documents; and assist ENGINEER in serving as OWNER's liaison with CONTRACTOR. 2 11.2.3.2. Assist in obtaining from OWNER additional details or information, when required for proper execution of the Work. 11.2.4. Shop Drawings and Samples: 11.2.4.1. Record date of receipt of Shop Drawings and samples. 11.2.4.2. Receive samples which are furnished at the site by CONTRACTOR, and notify ENGINEER of availability of samples for examination. 11.2.4.3. Advise ENGINEER and CONTRACTOR of the commencement of any Work requiring Shop Drawing or sample if the submittal has not been approved by ENGINEER. 11.2.5. Review of Work, Rejection of Defective Work, Inspections and Tests: 11.2.5.1. Conduct on-site observations of the Work in progress to assist ENGINEER in determining if the Work is in general proceeding in accordance with the Contract Documents. 11.2.5.2. Report to ENGINEER whenever RPR believes that any Work is unsatisfactory, faulty or defective or does not conform to the Contract Documents, or has been damaged, or does not meet the requirements of any inspection, test or approval required to be made; and advise ENGINEER of Work that RPR believes should be corrected or rejected or should be uncovered for observation, or requires special testing, inspection or approval. 11.2.5.3. Verify that tests, equipment and systems startup and operating and maintenance training are conducted in the presence of appropriate personnel, and the CONTRACTOR maintains adequate records thereof; and observe, record and report to ENGINEER appropriate details relative to the test procedures and startup. 11.2.5.4. Accompany visiting inspectors representing public or other agencies having jurisdiction over the Project, record the results of these inspections and report to ENGINEER. 11.2.6. Interpretation of Contract Documents: Report to ENGINEER when clarifications and interpretations of the Contract Documents are needed and transmit to CONTRACTOR clarifications and interpretations as issued by ENGINEER. 11.2.7. Modifications: Consider and evaluate CONTRACTOR's suggestions for modifications in Drawings or Specifications and report with RPR's recommendations to ENGINEER. Transmit to CONTRACTOR decisions as issued by ENGINEER. 11.2.8. Records: 11.2.8.1. Maintain at the job site orderly files for correspondence, reports of job conferences, Shop Drawings and samples, reproductions of original Contract Documents including all Work Directive Changes, Addenda, Change Orders, Field Orders, additional Drawings issued subsequent to the execution of the Contract, ENGINEER's clarifications and interpretations of the Contract Documents, progress reports, and other Project related documents. 11.2.8.2. Keep a detailed and accurate diary or log book, recording CONTRACTOR hours on the job site, weather conditions, prime and subcontractor daily work force, daily log of equipment onsite or on standby, data relative to questions of Work Directive Changes, Change Orders or changed conditions, list of job site visitors, daily activities, decisions, observations in general, and 3 specific observations in more detail as in the case of observing test procedures; and send copies to ENGINEER. 11.2.8.3. Record names, addresses and telephone numbers of all CONTRACTORS, subcontractors and major suppliers of materials and equipment. 11.2.9. Reports: 11.2.9.1. Furnish ENGINEER periodic reports as required of progress of the Work and of CONTRACTOR's compliance with the progress schedule and schedule of Shop Drawing and sample submittals. 11.2.9.2. Consult with ENGINEER in advance of scheduled major tests, inspections or start of important phases of the Work. 11.2.9.3. Draft proposed Change Orders and Work Directive Changes, obtaining backup material from CONTRACTOR and recommend to ENGINEER Change Orders, Work Directive Changes, and Field Orders. 11.2.9.4. Report immediately to ENGINEER and OWNER upon the occurrence of any accident. 11.2.10. Payment Requests: Review applications for payment with CONTRACTOR for compliance with the established procedure for their submission and forward with recommendations to ENGINEER, noting particularly the relationship of the payment requested to the schedule of values, Work completed and materials and equipment delivered at the site but not incorporated in the Work. 11.2.11. Certificates, Maintenance and Operation Manuals: During the course of the Work, verify that certificates, maintenance and operation manuals and other data required to be assembled and furnished by CONTRACTOR are applicable to the items actually installed and in accordance with the Contract Documents, and have this material delivered to ENGINEER for review and forwarding to OWNER prior to final payment for the Work. 11.2.12. Completion: 11.2.12.1. Submit to CONTRACTOR, and ENGINEER a list of observed items requiring completion or correction before ENGINEER may issue a Certificate of Substantial Completion. 11.2.12.2 Assess completion or correction of items noted under 11.2.12.1, advise ENGINEER on their status, and make recommendation to Engineer regarding issuance of a Certificate of Substantial completion. 11.2.12.3. Conduct final inspection in the company of ENGINEER, OWNER, and CONTRACTOR and prepare a final list of items to be completed or corrected. 11.2.12.4. Observe that all items on final list have been completed or corrected and make recommendations to ENGINEER concerning final acceptance. 11.3. LIMITATIONS OF AUTHORITY Resident Project Representative: 11.3.1. Shall not authorize any deviation from the Contract Documents or substitution of materials or equipments, unless authorized by ENGINEER. 4 11.3.2. Shall not exceed limitations of ENGINEER's authority as set forth in the Agreement or the Contract Documents. 11.3.3. Shall not undertake any of the responsibilities of CONTRACTOR, subcontractors or CONTRACTOR's superintendent. 11.3.4. Shall not advise on, issue directions relative to or assume control over any aspect of the means, methods, techniques, sequences or procedures of construction unless such advice or directions are specifically required by the Contract Documents. 11.3.5. Shall not advise on, issue directions regarding or assume control over safety precautions and programs in connection with the Work. 11.3.6. Shall not accept Shop Drawing or sample submittals from anyone other than CONTRACTOR. 11.3.7. Shall not authorize OWNER to occupy the Project in whole or in part. 11.3.8. Shall not participate in specialized field or laboratory tests or inspections conducted by others except as specifically authorized by ENGINEER. A/C AIR CONDITIONING CLKG CAULKING F TO F FACE TO FACE ID INSIDE DIAMETER, INTERIOR DIMENSION N NORTH, NEUTRAL R&R REMOVE AND REPLACE TOB TOP OF BOLT, TOP OF BANK, TOP OF BEAM, TOP OF BERM A/E ARCHITECT/ENGINEER CLR CLEAR F&B FACE AND BYPASS IE INVERT ELEVATION, FOR EXAMPLE NA NOT APPLICABLE R&S REMOVE AND SALVAGE TOC TOP OF CURB, TOP OF CONCRETEA AMPERE CMH COMMUNICATION MANHOLE FAB FABRICATE IF INSIDE FACE NAT NATURAL, NATIONAL R RADIUS, REGISTER, RISER TOD TOP OF DUCTAB ANCHOR BOLT CMP CORRUGATED METAL PIPE FB FLOOR BEAM IH INTAKE HOOD NC NORMALLY CLOSED RA RETURN AIR TOF TOP OF FOOTINGABAN ABANDON CMU CONCRETE MASONRY UNIT FBD FIBERBOARD IMP IMPACT NEG NEGATIVE RB RESILIENT BASE, ROCK BERM TOG TOP OF GRATINGABC AGGREGATE BASE COURSE CO CLEANOUT, CONCRETE OPENING FBG FIBERGLASS IN INCH NF NEAR FACE, NON-FUSED RCPT RECEPTACLE TOL TOLERANCE, TOP OF LEDGERABT ABOUT COL COLUMN FBM BOARD FOOT MEASURE INC INCLUDE, INCANDESCENT NIC NOT IN CONTRACT RD ROOF DRAIN TOM TOP OF MASONRYAC ALTERNATING CURRENT COMB COMBINATION FBO FURNISHED BY OWNER INF INLFUENT NO NORMALLY OPEN, NUMBER REC RECESS TOP TOP OF PLATE ACK ACKNOWLEDGE COMM COMMUNICATION FC FLUSHING CONNECTION INSTR INSTRUMENTATION NOM NOMINAL RECD RECEIVED TOPO TOPOGRAPHY ACP ACOUSTIC CEILING PANEL, ASPHALTIC CONCRETE PAVEMENT COMP COMPOSITION, COMPRESSIBLE, COMPOSITE FCA FLANGED COUPLING ADAPTER INSUL INSULATION NPS NOMINAL PIPE SIZE RECT RECTANGULAR TOS TOP OF SLAB, TOP OF STEEL, TOE OF SLOPE ACST ACOUSTIC CON CONCENTRIC FD FLOOR DRAIN INT INTERIOR, INTERSECTION NPT NATIONAL PIPE THREAD RED REDUCER TOW TOP OF WALLAD ADDENDUM, AREA DRAIN CONC CONCRETE FDC FLEXIBLE DUCT CONNECTION INTR INTERMEDIATE, INTERIOR NS NEAR SIDE REF REFERENCE TP TOILET PARTITION, TELEPHONE POLE,TOE PLATE, TRAP PRIMERADDL ADDITIONAL CONN CONNECTION FDR FEEDER INV INVERT NTS NOT TO SCALE REINF REINFORCING TPD TOILET PAPER DISPENSERADH ADHESIVE CONST CONSTRUCTION FDTN FOUNDATION IPS IRON PIPE SIZE NWL NORMAL WATER LEVEL REM REMOVE TPG TOPPING, THROUGH PLATE GIRDERADJ ADJUSTABLE, ADJACENT CONT CONTINUOUS FE FLANGED END IPT INTERNAL PIPE THREAD REQD REQUIRED TR TRANSOM AF AMP FRAME, AMP FUSE COOR COORDINATE FEC FIRE EXTINGUISHER CABINET IR INSIDE RADIUS, IRON ROD O TO O OUT TO OUT RESIL RESILIENT TRANS TRANSITION AFF ABOVE FINISH FLOOR CORR CORROSIVE, CORRUGATED FES FLARED END SECTION IRR IRRIGATION OA OUTSIDE AIR, OVERALL RET RETAINING, RETURN TRD TRENCH DRAIN AFG ABOVE FINISH GRADE CP CHECKER PLATE, CONTROL POINT FEXT FIRE EXTINGUISHER ISO ISOMETRIC OC ON CENTER REV REVISION, REVERSE TYP TYPICAL AGGR AGGREGATE CPLG COUPLING FF FAR FACE, FACTORY FINISH, FLAT FACE OCPD OVER CURRENT PROTECTION DEVICE RF RESILIENT FLOORINGAI AREA INLET, ANALOG INPUT CRL CORROSION-RESISTANT LINING FG FINISHED GRADE JB JUNCTION BOX OD OUTSIDE DIAMETER RFG ROOFING U URINALAIC AMPS INTERRUPTING CAPACITY CSC COMPRESSION SLEEVE COUPLING FH FIRE HYDRANT JCT JUNCTION OED OPEN END DUCT RFL REFLECTED, REFLECTOR UG UNDERGROUNDALIG ALIGNMENT CSK COUNTERSINK FIG FIGURE JF JOINT FILLER OF OUTSIDE FACE, OFFICE FURNISHING RGH ROUGH ULT ULTIMATEALT ALTERNATE, ALTITUDE CSS CLINIC SERVICE SINK FIN FINISH JST JOIST OFCI OWNER FURNISHED CONTRACTOR INSTALLED RGS RIGID GALVANIZED STEEL UNFN UNFINISHED ALUM ALUMINUM CT CERAMIC TILE FJT FLUSH JOINT JT JOINT OFOI OWNER FURNISHED OWNER INSTALLED RGS-PVC PVC COATED RGS UNO UNLESS NOTED OTHERWISE AM ACOUSTICAL MATERIAL CTJ CONTRACTION JOINT FL FLOW, FLOW LINE OG ORIGINAL GROUND RH RELIEF HOOD, RIGHT HAND, RELATIVE HUMIDITY UTIL UTILITY AMB AMBIENT CTR CENTER FLEX FLEXIBLE K KIP OH OVERHEAD RL REQUIRED LAP ANC ANCHOR CTRL CONTROL FLG FLANGE KB KNEE BRACE OPNG OPENING RLFA RELIEF AIR V VENT, VELOCITY, VOLTAO ANALOG OUTPUT CVT CULVERT FLOR FLOURESCENT KCMIL THOUSAND CIRCULAR MILS OPP OPPOSITE RND ROUND VA VOLT AMPEREAP ACCESS PANEL CU COPPER, CUBIC FLR FLOOR KD KNOCK DOWN OPT OPTIONAL RNG RUNNING VAC VACUUMAPRX APPROXIMATE CW CLOCKWISE FLS FLASHING, FLUSH KO KNOCK OUT OR OUTSIDE RADIUS RO ROUGH OPENING VAR VARNISH, VARIABLE,VOLT AMPERES REACTIVEAPVD APPROVED CY CUBIC YARD FN FENCE KSI KIPS PER SQUARE INCH ORD OVERFLOW ROOF DRAIN ROW RIGHT-OF-WAY VB VAPOR BARRIER, VINYL BASE, VALVE BOX ARCH ARCHITECTURAL FO FINISHED OPENING KW KILOWATT ORIG ORIGINAL RPM REVOLUTIONS PER MINUTE VC VERTICAL CURVE ASSY ASSEMBLY d PENNY (NAIL MEASURE) FOB FLAT ON BOTTOM OVFL OVERFLOW RR RAILROAD VCP VITRIFIED CLAY PIPE AT ACOUSTICAL TILE, AMP TRIP D DEEP, DIFFUSER, DRAIN FOC FACE OF CONCRETE, FACE OF CURB L ANGLE, LENGTH, LAVATORY, LINTEL OVHG OVERHANG RSP ROCK SLOPE PROTECTION VCT VINYL COMPOSITION TILE, VERTICAL CENTERLINEATC ACOUSTICAL TILE CEILING DB DUCT BANK, DECIBEL, DRY BULB FOF FACE OF FINISH LAD LADDER OZ OUNCE RT RIGHT VEL VELOCITYATM ATMOSPHERE DBA DEFORMED BAR ANCHOR FOM FACE OF MASONRY LAM LAMINATE RVT RESILIENT VINYL TILE VENT VENTILATIONAUTO AUTOMATIC DBL DOUBLE FOS FACE OF STUDS LATL LATERAL P PAINT RY READY VERT VERTICALAUX AUXILIARY DC DIRECT CURRENT FOT FLAT ON TOP LB LAG BOLT, POUND PA PUBLIC ADDRESS VERTS VERTICAL REINFORCINGAVE AVENUE DEG DEGREE FPT FEMALE PIPE THREAD LCTB LIQUID CHALK AND TACK BOARD PAR PARALLEL, PARAPET S SOUTH, SINK VG VERTICAL GRAIN AVG AVERAGE DEG C DEGREE CENTIGRADE FR FRAME LDG LANDING PB PANIC BAR, PULL BOX SA SUPPLY AIR VIF VERIFY IN FIELD AWG AMERICAN WIRE GAGE DEG F DEGREE FAHRENHEIT FRP FIBERGLASS REINFORCED PLASTIC LDR LEADER PBD PARTICLE BOARD SAMU SOUND-ABSORBING MASONRY UNIT VIN VINYL AWT ACOUSTICAL WALL TILE DEMO DEMOLITION FRTM FIRE RETARDANT TREATED MATERIAL LE LIFTING EYE PC POINT OF CURVE, PIECE, PRECAST SAN SANITARYVOLVOLUME DEP DEPRESSED FS FLOOR SINK, FAR SIDE LF LINEAR FOOT PCC POINT OF COMPOUND CURVATURE SB SPLASH BLOCK VPC VERTICAL POINT OF CURVATURE DEPT DEPARTMENT FT FEET, FOOT LG LONG PCF POUNDS PER CUBIC FOOT SC SOLID CORE VPI VERTICAL POINT OF INTERSECTIONB TO B BACK TO BACK DET DETAIL FTG FOOTING, FITTING LH LEFT HAND PCT PERCENT SCH SCHEDULE VPT VERTICAL POINT OF TANGENCYBAL BALANCE DI DROP INLET, DUCTILE IRON, DIGITAL INPUTFUR FURRED, FURRING LIN LINEAR PE PLAIN END SCHEM SCHEMATIC VS VERSUS, VAPOR SEALBBD BULLETIN BOARD DIA DIAMETER FURN FURNITURE, FURNISH LIQ LIQUID PED PEDESTAL SCN SCREEN VTR VENT THROUGH ROOFBC BASE CABINET, BOTTOM CHORD.BOLT CENTER, BOLT CIRCLE DIAG DIAGONAL, DIAGRAM FUT FUTURE LLH LONG LEG HORIZONTAL PEN PENETRATION SE STEEL/ALUMINUM EDGE VWC VINYL WALL COVERING BD BOARD DIFF DIFFERENTIAL, DIFFERENCE FV FACE VELOCITY LLV LONG LEG VERTICAL PERF PERFORATED SEC SECONDARY, SECONDS BE BOTH ENDS, BELL END DIM DIMENSION FW FIELD WELD, FIRE WALL LMLU LIQUID MARKER LECTURE UNIT PERM PERMANENT SECT SECTION W/ WITH BF BOTH FACES, BOTTOM FACE, BLIND FLANGE, BOARD FEET DISCH DISCHARGE FWD FORWARD LNG LONGITUDINAL PERP PERPENDICULAR SEP SEPARATE W/O WITHOUT BITUM BITUMINOUS DIST DISTANCE, DISTRIBUTION FEW FURNISHED WITH EQUIPMENT LOC LOCATION PF POWER FACTOR SF SQUARE FOOT, SILT FENCE W WATT, WEST, WIDE, WINDOW, WIREWIDE FLANGE BEAMBKG BACKING DIV DIVISION FXTR FIXTURE LP LOW POINT PFMU PREFACED MASONRY UNIT SG SHEET GLASS, SEALANT GROOVE WB WOOD BASEBL BASE LINE DL DEAD LOAD LPS LOW-PRESSURE SODIUM PH PHASE SH SHOWER WC WATER CLOSET, WATER COLUMNBLDG BUILDING DMJ DOUBLE MECHANICAL JOINT G GRILLE, GROUND LR LONG RADIUS PI POINT OF INTERSECTION SHT SHEET WD WOOD, WIDTHBLK BLOCK DMPF DAMP PROOFING GA GAGE (METAL THICKNESS) LT LEFT PKG PACKAGE SHTG SHEATHING WF WIDE FLANGE, WASH FOUNTAIN BLKG BLOCKING DN DOWN GAL GALLON LTD LIMITED PL PLATE, PROPERTY LINE, PRECAST LINTEL SIL SILENCE WG WIRE GLASS, WATER GAGE BM BENCHMARK, BEAM DO DISSOLVED OXYGEN, DIGITAL OUTPUT DITTO GALV GALVANIZED LTG LIGHTING PLAS PLASTER SIM SIMILAR WH WALL HYDRANT, WEEP HOLE BOC BACK OF CURB DP DEPTH GB GRAB BAR, GRADE BREAK LTL LINTEL PLAT PLATFORM SJ SLAB JOINT WI WROUGHT IRONBOD BOTTOM OF DUCT DPDT DOUBLE POLE, DOUBLE THROW GC GROOVED COUPLING LTNG LIGHTING PLBG PLUMBING SL SLOPE, STEEL LINTEL WL WATER LEVELBOG BOTTOM OF GRILLE DPST DOUBLE POLE, SINGLE THROW GD GUARD LV LOW VOLTAGE PLF POUNDS PER LINEAR FOOT SLTD SLOTTED WLD WELDEDBOL BOTTOM OF LOUVER, BOLLARD DS DOWN SPOUT GEN GENERAL LVL LAMINATED VENEER LUMBER PNEU PNEUMATIC SLV SLEEVE WM WIRE MESHBOP BOTTOM OF PIPE DT DOUBLE TEE, DRIP TRAP ASSEMBLY GFCI GROUND FAULT CIRCUIT INTERRUPTER LVR LOUVER POL POLISH SMLS SEAMLESS WP WEATHERPROOFBOR BOTTOM OF REGISTER DUP DUPLICATE GFMU GROUND FACE MASONRY UNIT LW LIGHTWEIGHT POS POSITIVE, POSITION SOG SLAB ON GRADE WS WATERSTOP, WATER SURFACEBOT BOTTOM DWG DRAWING GG GUTTER GRADE LWC LIGHTWEIGHT CONCRETE PP POLYPROPYLENE, POWER POLE SP SOUNDPROOF, STANDPIPE WSCT WAINSCOT BOU BOTTOM OF UNIT DWL DOWEL GJ GROOVED JOINT LWL LOW WATER LEVEL PRC POINT OF REVERSE CURVATURE SPA SPACING WT WEIGHT, WATER TIGHT BP BASE PLATE DWR DRAWER GL GLASS PREF PREFINISHED SPEC SPECIFICATION WTHP WATERPROOF, WORKING POINT BRG BEARING GLB GLASS BLOCK, GLULAM BEAM MA MIXED AIR PREFAB PREFABRICATED SPLY SUPPLY WWF WELDED WIRE FABRIC BRGP BEARING PLATE E EAST GND GROUND MACH MACHINED PRELIM PRELIMINARY SPST SINGLE POLE SINGLE THROWBRKT BRACKET EA EACH, EXHAUST AIR GP GUY POLE MAINT MAINTENANCE PREP PREPARE SPT SET POINT XP EXPLOSION-PROOFBS BOTH SIDES EC ELECTRICAL CONTRACTOR GR GRADE MAN MANUAL PRES PRESSURE SQ SQUARE XS EXTRA STRONGBTU BRITISH THERMAL UNIT ECC ECCENTRIC GRTG GRATING MATL MATERIAL PRI PRIMARY SR SHORT RADIUS XSECT CROSS SECTIONBTW BETWEEN ED EQUIPMENT DRAIN GSB GYPSUM SHEATHING BOARD MAX MAXIMUM PROP PROPERTY, PROPOSED SS SERVICE SINK XXS DOUBLE EXTRA STRONGBTWLD BUTT WELD EDB ELECTRICAL DUCT BANK GT GREASE TRAP MB MACHINE BOLT PROT PROTECTION SST STAINLESS STEELBU BELL UP, BUILT-UP EE EACH END GVL GRAVEL MBR MEMBER PS PIPE SUPPORT ST STREET YH YARD HYDRANT BUR BUILT-UP ROOFING EF EACH FACE GW GUY WIRE MC MECHANICAL CONTRACTOR, MECHANICAL COUPLING, MOMENT CONNECTION PSF POUNDS PER SQUARE FOOT STA STATION YS YIELD STRENGTH BW BOTH WAYS EFF EFFLUENT, EFFICIENCY GWB GYPSUM WALLBOARD MCB METAL CORNER BEAD PSI POUNDS PER SQUARE INCH STD STANDARDBYP BYPASS EHH ELECTRICAL HANDHOLE GYP GYPSUM HARDBOARD MCJ MASONRY CONTROL JOINT PSIA POUNDS PER SQUARE INCH ABSOLUTE STIF STIFFENEREIFS EXTERIOR INSULATION & FINISH SYSTEM MDMJ MODIFIED DOUBLE MECHANICAL JOINT PSIG POUNDS PER SQUARE INCH GAGE STIR STIRRUPC TO C CENTER TO CENTER EJ EXPANSION JOINT H HIGH MECH MECHANICAL PST PRESTRESSED STL STEELC&G CURB AND GUTTER EL ELBOW, ELEVATION HB HOSE BIBB MED MEDIUM PT POINT, POINT OF TANGENCY STOR STORAGEC CHANNEL SHAPE, CENTIGRADE, CONDUIT ELEC ELECTRICAL HBD HARDBOARD MFR MANUFACTURER PTN PARTITION STR STRUCTURAL, STRAIGHT CAB CABINET EMBD EMBEDDED HC HANDICAPPED, HOLLOW CORE, HORIZONTAL CURVE, HORIZONTAL CENTERLINE MH MANHOLE, METAL HALIDE PVC POLYVINYL CHLORIDE, POINT OF VERTICAL CURVE SUB SUBSTITUTE CAP CAPACITY EMER EMERGENCY HD HEAD, HOT DIP MIN MINIMUM PVMT PAVEMENT SUC SUCTIONCAT CATALOG, CATEGORY EMH ELECTRICAL MANHOLE HDR HEADER MIR MIRROR PWD PLYWOOD SUSP SUSPENDEDCAV CAVITY ENCL ENCLOSURE HDW HARDWARE MISC MISCELLANEOUS PWJ PLYWOOD WEB JOIST SY SQUARE YARDCB CATCH BASIN ENGR ENGINEER HEX HEXAGONAL MJ MECHANICAL JOINT PZ PIEZOMETER SYM SYMBOLCCB CONCRETE BLOCK ENTR ENTRANCE HGR HANGER ML MASONRY LINTEL SYMM SYMMETRICALCCW COUNTER CLOCKWISE EOP EDGE OF PAVEMENT HH HANDHOLE MLO MAIN LUGS ONLY Q RATE OF FLOW SYN SYNTHETIC CDF CONTROLLED-DENSITY FILL EQ EQUAL HID HIGH-INTENSITY DISCHARGE MMB MEMBRANE QT QUARRY TILE SYS SYSTEM CE CONCRETE EDGE EQUIP EQUIPMENT HM HOLLOW METAL MO MASONRY OPENING QTR QUARTER CER CERAMIC EQUIV EQUIVALENT HORIZ HORIZONTAL MOD MODULAR, MODIFY QTY QUANTITY T&B TOP AND BOTTOM CF CUBIC FEET (FOOT) ES EACH SIDE, EQUAL SPACE, EMERGENCY SHOWER HP HIGH POINT, HORSEPOWER MON MONUMENT QUAL QUALITY T&G TONGUE AND GROOVE CFL COUNTER FLASHING ESEW EMERGENCY SHOWER AND EYE WASH HPC HORIZONTAL POINT OF CURVATURE MPT MALE PIPE THREAD T TILE, TREADCHBD CHALKBOARD EST ESTIMATE HPS HIGH-PRESSURE SODIUM MRGWB MOISTURE-RESISTANTGYPSUM WALLBOARD TA TOILET ACCESSORY, TEMPERED AIR CHD CHORD EW EACH WAY, EMERGENCY EYE/FACE WASH HPT HORIZONTAL POINT OF TANGENCY MS MOP SINK TAN TANGENTCHFR CHAMFER EWC ELECTRIC WATER COOLER HR HOSE REEL, HOUR MSL MEAN SEA LEVEL TBM TEMPORARY BENCHMARK CHH COMMUNICATION HANDHOLE EWEF EACH WAY, EACH FACE HS HEADED STUD, HIGH STRENGTH MT MOUNT TCE TEMPORARY CONSTRUCTION EASEMENT CI CURB INLET EWTB EACH WAY,TOP AND BOTTOM HSS HOLLOW STRUCTURAL SHAPE MU MASONRY UNIT TEF TROWELED EPOXY FLOORING CIP CAST-IN-PLACE EXC EXCAVATION HT HEIGHT MULL MULLION TEMP TEMPORARY, TEMPERATURE CIPD CONCRETE INTERLOCKING PAVER BALLASEXH EXHAUST HTG HEATING MV MEDIUM VOLTAGE THD THREADCIRC CIRCULATION, CIRCULAR EXP EXPANSION, EXPOSED HV HIGH VOLTAGE MW MONITORING WELL THK THICKCJ CONSTRUCTION JOINT EXST EXISTING HVAC HEATING, VENTILATING AND AIR CONDITIONING THRESH THRESHOLD CKT CIRCUIT EXT EXTERIOR, EXTERNAL, EXTENSION HWD HARDWOOD TKBD TACK BOARDCL CENTERLINE, CLASS, CLOSE HWL HIGH WATER LEVELCLG CEILING HYD HYDRAULIC HZ HERTZ, CYCLES PER SECOND GENERAL NOTES: 1. THESE ABBREVIATIONS APPLY TO THE ENTIRE SET OF CONTRACT DRAWINGS. 2. LIST OF ABBREVIATIONS DOES NOT IMPLY THAT ALL ABBREVIATIONS ARE USED IN THE CONTRACT. 3. ABBREVIATIONS SHOWN ON THIS SHEET INCLUDE VARIATIONS OF A WORD. FOR EXAMPLE, "MOD" MAY MEAN MODIFY OR MODIFICATION; "INC" MAY MEAN INCLUDED OR INCLUDING AND "REINF" MAY MEAN EITHER REINFORCE OR REINFORCING. 4. SEE INSTRUMENTATION LEGEND SHEET FOR PROJECT-SPECIFIC EQUIPMENT SYMBOLS, EQUIPMENT ABBREVIATIONS, AND PIPING SYSTEM ABBREVIATIONS. 1 PROFESSIONAL SERVICES AGREEMENT THIS IS AN AGREEMENT made as of , between THE CITY OF BOZEMAN, a Municipal Corporation, Bozeman, Montana, 59715 (OWNER) and , Montana, (ENGINEER). Whereas the accomplishment of the work and services described in this Agreement is essential to the OWNER'S public works improvement program. Whereas the OWNER intends to and has selected the ENGINEER to provide necessary and professional engineering services for the project. Whereas the ENGINEER represents that it is willing and qualified to perform the professional engineering services for this project described in this Agreement. Therefore, in consideration of the foregoing recitals and the mutual covenants and conditions contained herein, the parties agree as follows: The conditions and provisions set forth in the attached EXHIBIT A (insert title), EXHIBIT B (insert title) , and EXHIBIT C (insert title) , are hereby incorporated in and made part of this Agreement. ARTICLE 1 - ENGINEERING SERVICES 1.1. The detailed description of the specific project components is described as follows: (Insert detailed project description) 1.2. The scope of services under this contract is set forth in this agreement and the attached EXHIBITS. ARTICLE 2 - ENGINEER'S RESPONSIBILITIES 2.1. ENGINEER shall perform for OWNER professional engineering services in all phases of the Project to which this Agreement applies as hereinafter provided. These services will include, but not be limited to, serving as OWNER's professional engineering representative for the Project, providing professional engineering consultation and advice and furnishing customary civil and structural engineering services incidental thereto. 2.2. The ENGINEER shall furnish all labor, materials, equipment, supplies, and incidentals necessary to conduct and complete the ENGINEER'S portions of the Project and to prepare and deliver to the OWNER all data, reports, plans, specifications, and recommendations as designated herein. 2.3. The ENGINEER shall ascertain such information as may have a bearing on the work from local units of government, public, and private organizations and shall be authorized to procure information from other authorities as to the extent of these contacts and the results thereof. 2.4. The ENGINEER'S work shall be in accordance with the standards of sound engineering practices. 2.5. The ENGINEER shall name a Principal-In-Charge for the duration of the project. The Principal-In-Charge shall be . 2.6. The ENGINEER shall name a Project Manager who shall be the liaison between the ENGINEER and the OWNER. The Project Manager shall be . The OWNER may name a Task Director 2 who would be the liaison between the ENGINEER and the OWNER during the design segment of the Project. 2.7. The ENGINEER shall submit an estimated progress schedule at the beginning of the work, and monthly progress reports thereafter until the project is completed. ARTICLE 3 - OWNER'S RESPONSIBILITIES 3.1 The OWNER shall name a Task Director who shall be the liaison between the ENGINEER and the OWNER during DESIGN segment of the Project. The Task Director designated shall be . 3.2 The OWNER shall have the right of review and examination of the ENGINEER'S work at all times. 3.3 The OWNER shall make available all records (record drawings, construction records, etc.) indicating the existing configuration of the city utilities. 3.4 The OWNER will be responsible for Advertising Bid Openings. 3.5 The OWNER shall attend the pre-bid conferences, bid openings, pre-construction conferences, construction progress and other job related meetings, substantial completion inspections and final payment inspections. ARTICLE 4 - BASIC ENGINEERING SERVICES The ENGINEER shall render professional Engineering Services as follows: 4.1 PRE-DESIGN INVESTIGATION PHASE After written authorization to proceed, ENGINEER shall: 4.1.1 Consult with OWNER to clarify and define OWNER's requirements for the Project and review available data. 4.1.2 Advise OWNER as to the necessity of OWNER's providing or obtaining from others, data or services and assist OWNER in obtaining such data or services. 4.1.3 Identify and analyze requirements of governmental authorities having jurisdiction to approve the design of the Project and participate in consultations with such authorities. 4.1.4. Provide analyses of OWNER's needs, planning surveys, site evaluations and comparative studies of prospective sites and solutions. 4.1.5. Provide a general economic analysis of OWNER's requirements applicable to various alternatives. 4.1.6 Assist in formation of Special Improvement Districts (SID) by preparing district boundary descriptions and maps, preparing a property owner's and assessments role lists including project assessment costs based on the preliminary project cost estimates, and providing technical information at SID public hearings, if applicable. 4.1.7. Prepare a Report containing schematic layouts, sketches and conceptual design criteria with appropriate exhibits to indicate clearly the considerations involved (including applicable requirements of governmental authorities having jurisdiction as aforesaid) and the alternative solutions available to OWNER and setting forth ENGINEER's findings and recommendations. This Report will be accompanied by ENGINEER's opinion of probable costs for the Project, including the following which will be separately itemized: Construction Cost, allowance for engineering costs and contingencies, and (on the basis of information furnished by OWNER) allowances for such other items as charges of all other professionals and consultants, for the cost of land and rights-of-way, for compensation for or damages to properties, for interest and financing charges and for other services to be provided by others for Owner. The total of all 3 such costs, allowance, etc. are hereinafter called "Total Project Costs". 4.1.8. Furnish copies and an electronic copy of the Study and Report documents and review them in person with OWNER. The Pre-design Investigation Phase will be completed and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.2 PRELIMINARY DESIGN PHASE After acceptance of the pre-design report and receipt of written authorization to proceed with the Preliminary Design Phase, ENGINEER shall: 4.2.1. In consultation with OWNER determine general scope, extent and character of the Project. 4.2.2. ENGINEER shall then prepare a Preliminary Design Report, preliminary plans and specifications and a written description for the Project. 4.2.3. Preliminary Design Report: Specific items to be addressed in the design report will include, but not be limited to: 4.2.3.1. Summary of construction requirements with appropriate drawings for each task included in the project. 4.2.3.2. Plans for providing water and sewer services for affected properties during construction. 4.2.3.3. Summary geotechnical report for specific tasks, if needed. 4.2.3.4. Special design considerations for Project tasks with conditions not covered in standard construction methods or specifications. 4.2.3.5. A traffic control plan for each project task, if necessary. 4.2.4. Design and Construction Survey: The ENGINEER shall conduct a design field survey of the project areas, as necessary, for locating existing utilities (such as gas, power, telephone, TV cables, water and sewer lines, irrigation facilities, fences, and approach driveways), existing right-of-way and easements, and making measured drawings of or investigating conditions of existing facilities. The ENGINEER shall provide suitable horizontal and vertical reference control points for the construction phase. 4.2.5. Permits and Rights-of-Way: The ENGINEER shall obtain approved permits, licenses, and/or easement agreements from private landowners and any other agencies or entities requiring similar approvals prior to bidding. These approvals will be coordinated with the OWNER and will be made on easement and permit documents approved by the OWNER. Information and easement descriptions provided in the Basic Engineering Services will be based on data available from design surveys and courthouse records. 4.2.6. Geotechnical Explorations and Analysis: The ENGINEER shall conduct such geotechnical explorations and analysis as necessary for project design and bidding. A geotechnical report will be prepared with recommendations relating to conditions pertinent to the design and construction of the Project. Subsurface information will be obtained by reviewing any existing geotechnical data available and using additional backhoe test pits and soil borings as necessary. The ENGINEER shall furnish copies of a geotechnical report as requested to OWNER for use by OWNER and Contractors, and review the results of the report with Contractors in a pre-bid meeting. The report is to be prepared for design purposes; ENGINEER will not be responsible if it is used by others for other purposes. 4 4.2.7. Preliminary Plans and Specifications. Prepare preliminary construction plans and specifications with information which addresses the special features of each project task. 4.2.8. Based on the information contained in the preliminary design documents, ENGINEER will submit a revised opinion of probable Total Project Costs to the OWNER. 4.2.9. ENGINEER shall prepare and furnish complete paper and electronic copies of preliminary bidding documents and design report as requested to OWNER and at the same time furnish copies as directed by OWNER to agencies and/or parties having regulatory responsibilities or direct financial participation in any part of the Project; provide any technical criteria, written descriptions and design data necessary for securing permits or approval from authorities having jurisdiction to review and approve the design, and assist owner in securing such approvals; and review documents in person with OWNER and review authorities, and, if necessary, conduct a plan-in-hand site review. All changes agreed to between ENGINEER and OWNER will be noted in a memorandum from the ENGINEER to the OWNER and incorporated into the final plans and specifications. The Preliminary Design Phase will be completed and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.3 FINAL DESIGN PHASE After written authorization to proceed with the Final Design Phase, ENGINEER shall: 4.3.1. On the basis of the accepted Preliminary Design documents and the revised opinion of probable Total Project Costs, prepare for incorporation in the Contract Documents final drawings and Technical Specifications of sufficient detail to show the general scope, extent and detailed character of the work to be furnished and performed by the Contractor(s) suitable for use in the project bidding and construction. 4.3.2. Advise OWNER of any adjustments to the latest opinion of probable Total Project Costs caused by changes in general scope, extent or character or design requirements of the Project or Construction Costs. Furnish to OWNER a revised opinion of probable Total Project Costs based on the Drawings and Specifications. 4.3.3. Prepare for review and approval by OWNER, its legal counsel and other advisors, contract agreement forms, general conditions and supplementary conditions, and (where appropriate) bid forms, invitations to bid and instructions to bidders, special provisions, technical specifications, and standard drawings, and other related contract documents in conformance with the latest edition of the Montana Public Works Standard Specifications (MPWSS) and City of Bozeman Modifications to MPWSS adopted by the City of Bozeman. 4.3.4. Furnish OWNER six copies and an electronic copy of the Contract Documents (including design drawings, specifications and contracts). The Final Phase will be complete and submitted within calendar days following written authorization from OWNER to ENGINEER to proceed with that phase of services. 4.4 BIDDING OR NEGOTIATING PHASE After written authorization to proceed with the Bidding or Negotiating Phase, ENGINEER shall: 4.4.1. Assist OWNER in advertising for and obtaining bids or negotiating proposals for construction contract(s) and record prospective bidders to whom Bidding Documents have been issued, receive and process deposits for Bidding Documents and conduct pre-bid conferences. 4.4.2. Provide interpretation or clarification to prospective bidders regarding the Bidding Documents, and issue addenda as appropriate. 5 4.4.3. Consult with and advise OWNER as to the acceptability of the prime contractor, subcontractors, suppliers and other persons and organizations proposed by the prime contractor(s) (herein call "Contractor(s)") for those portions of the work as to which such acceptability is required by the Bidding Documents. 4.4.4. Consult with OWNER concerning and determine the acceptability of substitute materials and equipment proposed by Contractor(s) when substitution prior to the award of contracts is allowed by the Bidding Documents. 4.4.5. Attend the Bid opening, prepare bid tabulation, evaluate bids, assess bidders' responsiveness and responsibility and make award recommendation to OWNER. 4.4.6 Facilitate contract award, and the execution and distribution of the contract documents for construction, materials, equipment and services. Furnish Owner two original signature sets of executed contract documents (including design drawings, specifications and contracts). Furnish contractor with one set of original signature executed contract documents and up to three sets of construction documents. 4.5 CONSTRUCTION PHASE The responsibilities of the ENGINEER during the Construction Phase are summarized as follows: 4.5.1. General Administration of Construction Contract. ENGINEER shall consult with and advise OWNER and act as OWNER'S representative as provided in EXHIBIT A - ENGINEER'S STATUS DURING CONSTRUCTION, attached to and made part of this Agreement and may be further provided under the General Conditions of the contract documents. The extent and limitations of the authority, duties, and responsibilities of the ENGINEER on the construction job site as assigned here-in shall not be modified except as the ENGINEER may otherwise agree in writing. All of OWNER's instruction to Contractor(s) will be issued through ENGINEER who will have authority to act on behalf of OWNER to the extent provided in the General Conditions except as otherwise provided in writing. In addition to the services provided under Article 10 (Exhibit A) the ENGINEER shall provide the following services during construction: 4.5.1.1 Schedule and conduct a pre-construction conference. 4.5.1.2 Provide personnel, equipment and supplies for construction layout and control, including establishment of line, grade, and blue top control staking. 4.5.1.3 Review Contractors' construction schedules and operations, and the Contractors' traffic control plans and its implementation prior to the start of construction. 4.5.1.4 Ascertain that the Contractor has secured required permits needed to accomplish his work. 4.5.1.5 Prepare and provide weekly activity and progress reports to the City's Task Director. 4.5.1.6 ENGINEER shall provide OWNER copies of all correspondence between the ENGINEER and Contractor. 4.5.1.7 Issue stop and resume work orders, in whole or in part, when work is not or cannot be performed in accordance with the Contract Documents. 4.5.1.8 Review and approve, for conformance with the project technical specifications all shop drawings, and other Contractor submittals required by the Contract Documents. 4.5.1.9 During construction review Contractors' construction schedules and evaluate conformance and progress under the Contract time provisions. 6 4.5.1.10 Prepare for OWNER'S approval any plan and specification changes which due to any initial design or engineering deficiencies are required to complete the project original design concept. 4.5.1.11 Inspect the project and when appropriate, and after conferring with OWNER, issue a Certificate of Substantial Completion to the Contractor. 4.5.1.12 Prior to recommending final payment, schedule and conduct with the OWNER a final project inspection and submit a report to the OWNER documenting any outstanding items or deficiencies requiring correction prior to final payment. Upon satisfactory project completion ENGINEER shall certify in writing to the OWNER, and any required regulatory agencies, that the construction was completed in accordance with the approved plans and specifications and is performing in accordance with the design concept. 4.5.1.13 Twenty-three months after project substantial completion schedule and conduct with the Owner a Two Year Warranty Inspection of the project and advise the owner in writing whether project deficiencies exist and if the project is performing in accordance with the design concept. 4.5.2. Resident Project Representative. ENGINEER shall provide a qualified Resident Project Representative at the job site to provide observation of the work as provided in EXHIBIT B - A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE, attached to and made part of this Agreement. The ENGINEER shall submit to the OWNER, for review and acceptance, the resume of each Resident Project Representative who may be assigned to the job site during the course of the Project not less than 10 calendar days prior to the pre-construction meeting. Any subsequent change in the resident representative shall also be subject to the OWNER'S approval. 4.5.3 Limitations of Responsibilities. ENGINEER will not be responsible for CONTRACTOR's means, methods, techniques, sequences or procedures of construction, or the safety precautions and programs incident thereto, and ENGINEER will not be responsible for CONTRACTOR's failure to perform or furnish the Work in accordance with the Contract Documents; however, nothing contained in this agreement shall be construed to release ENGINEER from liability for failure to properly perform duties and responsibilities assumed by ENGINEER in the Contract Documents. 4.6. PROJECT DOCUMENTATION ENGINEER shall furnish OWNER with (a) one mylar copy, two paper copies, and an electronic copy of the Project Record Drawings ("As-Builts"), (b) written monthly progress reports, and (c) a project notebook containing such correspondence and documentation as requested by OWNER. 4.7. CONSTRUCTION TESTING The inspection services shall include material testing and verification of contract compliance with job site requirements, plans and specifications. The ENGINEER shall provide and maintain detailed documentation of the following material testing: 1) Concrete strength, air content and slump 2) Embankment, trench backfill, and gravel and pavement densities 3) Aggregate gradations 4) Plant mix strength, flow and asphalt content 7 ARTICLE 5 - ADDITIONAL SERVICES 5.1. If OWNER wishes ENGINEER to perform any of the following Additional Services, OWNER shall so instruct ENGINEER in writing, and ENGINEER shall perform or obtain from others such services and will be paid therefor as provided in the Agreement: 5.1.1. Legal land surveys performed to obtain data for preparing easements and rights-of-way descriptions. 5.1.2. Preparation of applications and supporting documents for governmental agencies in addition to those required under Basic Services; preparation or review of environmental studies and related services; and assistance in obtaining environmental approvals. 5.1.3. Services resulting from significant changes in the general scope, extent or character of the Project or major changes in documentation previously accepted by OWNER where changes are due to causes beyond ENGINEER's control. 5.1.4. Providing renderings or models. 5.1.5. Preparing documents for alternate bids requested by OWNER for work not executed or for out-of- sequence work. 5.1.6. Providing other services not otherwise provided for in the Agreement, including services normally furnished by the OWNER as elsewhere herein described. 5.1.7. Furnishing the services of independent professional associates or consultants for other than Basic Services. 5.2. When required by the Contract Documents in circumstances beyond ENGINEER's control, ENGINEER shall perform or obtain from others any of the following Additional Services as circumstances require during construction and without waiting for specific instructions from OWNER, and ENGINEER will be paid therefor as provided in this Agreement: 5.2.1. Services in connection with work directive changes and change orders to reflect the changes requested by OWNER if the resulting change in compensation for Basic Services is not commensurate with the additional services rendered. 5.2.2. Services in making revisions to Drawings and Specifications occasioned by the OWNER'S acceptance of substitutions proposed by Contractor(s); services after the award of each contract in evaluating and determining the acceptability of an unreasonable or excessive number of substitutions proposed by Contractor; and evaluating an unreasonable or extensive number of claims submitted by Contractor(s) or others in connection with the work. 5.2.3. Services resulting from significant delays, changes or price increases occurring as a direct result of materials, equipment or energy shortages. 5.2.4. Additional or extended services during construction made necessary by (1) work damage by fire or other causes during construction, (2) a significant amount of defective or neglected work of any Contractor, (3) acceleration of the progress schedule involving services beyond normal working hours, (4) default by any Contractor. ARTICLE 6 - COMPENSATION FOR ENGINEERING SERVICE 8 6.1 LUMP SUM AGREEMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER 6.1.1 Payment. The OWNER shall for design phase services performed as Basic Engineering Services under sections 4.1 through 4.3 of this agreement pay a total sum in the amount of $ for such services. 6.1.2 Payment Schedule. Total cumulative payments for the design phase engineering services (sections 4.1 through 4.4) shall not exceed the following ceilings: $ (10 % of design fee) until the Pre-design Investigation and Preliminary Design Report have been submitted to the OWNER. $ (50% of design fee) until the Preliminary Plans and Specifications have been submitted to the OWNER and review authorities. $ (90% of design fee) until the Final Plans and Specifications have been submitted to the OWNER and review authorities. 6.1.3 General. Engineer shall submit monthly statements for services rendered. The statements shall be based upon Engineer's estimate of the proportion of the total services actually completed at the time of billing, subject to any limitations on Payments based on completion of tasks or specific retainage requirements pursuant to the payment provisions of the Agreement. 6.1.4 Reimbursable Expenses. Only those expenses specifically identified for payment under section 6.2 of this Agreement are reimbursable. All other design related expenses are included in the Lump Sum Payment for the Basic services (4.1 through 4.4) and are not separately reimbursable. Additional Services specifically identified under the scope of design services for payment under 6.1 are not separately reimbursable. 6.2 DIRECT LABOR COST PAYMENT FOR BASIC SERVICES AND EXPENSES OF ENGINEER. Construction and project documentation services performed as Basic Engineering Services under sections 4.4 through 4.7 including General Administration of Construction Contract, Resident Project Representation, Project Documentation, and Construction Testing, shall be compensated in accordance with the following: 6.2.1 The OWNER shall pay for Construction Phase and Project Documentation Services an amount not to exceed except as provided under 6.2.1.2 and 6.2.4. 6.2.1.1 Costs Compensation. Compensation for these services shall be based on the ENGINEER's Direct Labor Cost times a factor of for services rendered which shall cover Direct Labor, Direct Labor Overhead, General & Administrative Overhead and Profit. 6.2.1.2 Notification. At any time during the construction that it becomes apparent that the Construction Phase and Project Documentation Services rendered under this Agreement will exceed the negotiated compensation for these services, and prior to performing services in excess of the contract ceiling, the ENGINEER shall give OWNER written notice thereof. Promptly thereafter OWNER and ENGINEER shall review the scope and progress of the project work. ENGINEER shall obtain written authorization from OWNER, prior to any additional costs being incurred under paragraph 6.2.1.3. If it is determined that due to a change in project scope under paragraph 5.2.1, the ENGINEER is entitled to additional compensation, OWNER and ENGINEER may negotiate terms as provided under 6.2.1.1. The amount and terms of any additional compensation under 6.2.1.1 or 6.2.1.3 shall be negotiated and agreed in writing pursuant to 9.16. 6.2.1.3 Costs Exceeding Estimated Compensation. Except as allowed under 5.2.1, when the total cost of the original scope Construction Phase and Project Documentation Services exceeds the negotiated 9 compensation for these services, the OWNER shall pay only for the direct costs incurred in excess of the estimated compensation. These costs consist of an amount equal to the ENGINEER'S Direct Labor Cost times a factor of for services rendered which shall include Direct Labor, the federally audited payroll Direct Labor Overhead, and General & Administrative Overhead costs, but shall not include any allowance for profit. 6.2.2. Reimbursable Expenses, as defined in section 7.4 of this Agreement, for Basic Services and Approved Additional Services shall be paid to the ENGINEER by the OWNER in the actual amount of the costs incurred up to an amount not to exceed $ which includes $ for consultants employed by the Engineer and $ for all other reimbursable expenses. The estimated reimbursable expenses are identified in Exhibit " ". 6.2.3. Failed Test Expenses. The ENGINEER shall maintain and provide to the OWNER, a record of the costs associated with failing quality control tests performed for the OWNER during the course of the construction of the project and recommend an amount the OWNER deduct from the contractor(s) payments. 6.2.4 The OWNER shall pay an amount for Additional Services rendered by the ENGINEER and approved in writing by the OWNER on the basis of the ENGINEER'S Direct Labor Costs times a factor of , or an amount otherwise negotiated at the time such services are requested and approved by the OWNER. ARTICLE 7 - MEANING OF TERMS 7.1 AGREEMENT As used herein the term "this Agreement" refers to the contents of this document and its Exhibits attached hereto and referred to as if they were part of one and the same document. 7.2 CONSTRUCTION COSTS The construction cost of the entire Project (herein referred to as "Construction Cost") means the total cost to OWNER of those portions of the entire Project designed and specified by ENGINEER, but it will not include ENGINEER's compensation and expenses, the cost of land, rights-of-way, or compensation for or damages to, properties unless this Agreement so specifies, nor will it include OWNER's legal, accounting, insurance counseling or auditing services, or interest and financing charges incurred in connection with the Project or the cost of other services to be provided by others to OWNER. 7.3 DIRECT LABOR COSTS Direct Labor Costs used as a basis for payment mean the actual salaries and wages paid to all ENGINEER's personnel engaged directly on the Project, including, but not limited to, engineers, architects, surveyors, designers, drafters, specification writers, estimators, other technical and business personnel; but does not include indirect payroll related costs or fringe benefits. For the purposes of this Agreement the principals and employees of the ENGINEER maximum billable Direct Labor Costs are: Principals $ /hour Project Manager $ /hour Senior Engineer $ /hour Staff Engineer $ /hour Senior Technicians $ /hour CADD Drafter $ /hour 10 Technicians $ /hour Construction Inspector $ /hour Two Person Survey Crew $ /hour Clerical $ /hour 7.4 REIMBURSABLE EXPENSES Reimbursable Expenses mean the actual expenses incurred by ENGINEER or ENGINEER's independent professional associates or consultants directly in connection with the Project, such as expenses for: transportation and subsistence incidental thereto; obtaining bids or proposals from Contractor(s); subsistence and transportation of Resident Project Representatives and their assistants; toll telephone calls and telegrams; reproduction of reports, Drawings, Specifications, Bidding Documents and similar Project-related items; and if authorized in advance by OWNER, overtime work requiring higher than regular rates. In addition, when compensation for Basic Services is on the basis of Direct Labor Costs method of payment, Reimbursable Expenses will also include the amount billed to ENGINEER by special consultants employed by ENGINEER and authorized by OWNER (other than as an authorized Additional Services) and will also include expenses incurred for computer time and other specialized equipment, including an appropriate charge for previously established programs and expenses of photographic production techniques. ARTICLE 8 - PAYMENT PROVISIONS 8.1 TIMES OF PAYMENTS. ENGINEER may submit monthly statements for Basic Services and approved Additional Services rendered and for Reimbursable Expenses incurred; however, payments shall not exceed the ceilings provided in 6.1 and 6.2. Final payment shall be made only after acceptance of the project by the OWNER. If OWNER disputes the amount of the billing, OWNER will notify the ENGINEER in writing within ten (10) calendar days of the receipt of bill of the dispute. 8.2 REQUESTS FOR PAYMENT. Each request for payment shall include a documentation summary of the period incremental man hours incurred, direct labor rates and billed rates, detail of reimbursable costs, total period billing, and total cumulative billing. When requested by OWNER services for distinct project segments shall be accounted and billed separately. 8.3 PAYMENT UNDER TERMINATION. In the event of termination by the OWNER upon the completion of any phase of the Basic Services, progress payments due ENGINEER for services rendered through such phase shall constitute total payment for such services. In the event of such termination by OWNER during any phase of the Basic Services, ENGINEER also will be reimbursed for the charges of pre-approved independent professional associates and consultants employed by ENGINEER to render Basic Services, and paid for services rendered during that phase on the basis of the payment provisions of the Agreement. In the event of any such termination, ENGINEER will be paid for unpaid pre- approved Additional Services and unpaid Reimbursable Expenses which are authorized under this agreement. ARTICLE 9 - GENERAL CONSIDERATIONS 9.1 TERMINATION OF AGREEMENT 9.1.1 The sole right is hereby reserved to the OWNER to terminate this Engineering Agreement for any and all causes or for its convenience at any time upon fifteen (15) days written notice to the ENGINEER. 11 9.1.2 If termination for default is effected by the OWNER, an equitable adjustment in the price provided for in this Agreement shall be made, but (1) no amount shall be allowed for anticipated profit on unperformed services or other work, and (2) any payment due to the ENGINEER at the time of termination may be adjusted to cover any additional costs to the OWNER because of the ENGINEER's default. If termination for convenience is effected by the OWNER, the equitable adjustment shall include a reasonable profit, as determined by owner, for services or other work performed. The equitable adjustment for any termination shall provide for payment to the ENGINEER for services rendered and expenses incurred prior to the termination, in addition to termination settlement costs reasonably incurred by the ENGINEER relating to commitments which had become firm prior to the termination. 9.1.3 Upon receipt of a termination action under paragraph 9.1.2, the ENGINEER shall (1) promptly discontinue all affected work (unless the notice directs otherwise), and (2) deliver or otherwise make available to the OWNER within ten (10) days copies of all data, design drawings, specifications, reports, estimates, summaries and such other information and materials as may have been accumulated by the ENGINEER in performing this Agreement, whether completed or in process. 9.1.4 In the event this Contract is terminated prior to completion, the original copies of the ENGINEER'S data, recommendations, plans, specifications, analysis and other related documents prepared by the ENGINEER prior to said termination shall be delivered to and become the property of the OWNER. 9.1.5 Upon termination, the OWNER may take over the work and may award another party an Agreement to complete the work under this Agreement. 9.1.6 OWNER'S right to terminate is in addition to any other remedies OWNER may have under the law. 9.2 INSPECTION AND AUDIT All books, papers, records, payrolls, vouchers and invoices relating to costs and expenditures incurred as to the performance of the services by the ENGINEER hereunder shall be made available to the OWNER, or their authorized representatives for audit and review, at the ENGINEER'S respective offices at all reasonable times during the contract period and for three years from the date of final payment. 9.3 EMPLOYMENT The ENGINEER warrants that he has not employed or retained any company or persons, other than a bona fide employee, working solely for the ENGINEER, to solicit to secure this contract, and that he has not paid or agreed to pay any company or person, other than bona fide employees working solely for the ENGINEER, any fee, commission, percentage, brokerage fee, gifts or any other considerations contingent upon or resulting from the award or making of this Contract. For breach or violation of this warranty, the OWNER shall have the right to annul the Contract without liability or in its discretion to deduct from the price or consideration or otherwise recover the full amount of such fee, commission, percentage, brokerage fee, gift or contingent fee. All employees of the ENGINEER or other persons while engaged in the performance of work or services required by the ENGINEER shall be considered employees of the ENGINEER only and not of the OWNER. 9.4 NONDISCRIMINATION The ENGINEER will have a policy to provide equal employment opportunity in accordance with all applicable state and federal anti-discrimination laws, regulations, and contracts. 12 The ENGINEER will not refuse employment to a person, bar a person from employment, or discriminate against a person in compensation or in a term, condition, or privilege of employment because of race, color, religion, creed, political ideas, sex, age, marital status, national origin, actual or perceived sexual orientation, gender identity, physical or mental disability, except when the reasonable demands of the position require an age, physical or mental disability, marital status or sex distinction. The ENGINEER shall be subject to and comply with Title VI of the Civil Rights Act of 1964; Section 140, Title 2, United States Code, and all regulations promulgated thereunder. The ENGINEER shall require these nondiscrimination terms of its sub-consultants providing services under this agreement. 9.5 SUBLETTING OR ASSIGNING OF WORK The ENGINEER shall not sublet or assign any of the work covered herein without prior written approval of the OWNER. 9.6 STANDARD OF CARE In providing services under this agreement, the ENGINEER will perform in a manner consistent with the degree of care and skill ordinarily exercised by members of the same profession currently practicing under similar circumstances. If any service should be found to be not in conformance with this standard, the ENGINEER shall, at the OWNER’s request, re- perform the service at its own expense. Engineer shall also, at its own expense, make such changes, modifications or additions to the project which are made necessary as a result of the initial non-performance or the re-performance of services. The OWNER’s rights herein are in addition to any other remedies the OWNER may have under the law. 9.7 LEGAL RELATIONS: 9.7.1 The ENGINEER shall, consistent with the standard care, comply with those Federal, State, and Local laws and ordinances applicable to the work to be done. 9.7.2 The ENGINEER agrees to defend, indemnify and hold harmless the OWNER, its officers, directors, agents and employees from and against any suit, cause of action, claim, cost, expenses, obligation and liability of any character, including attorney’s fees, which is brought or asserted for any bodily injury, death, or physical damage to property received or sustained by any person, persons, property, business or any other entity, arising out of or resulting from, or in connection with the ENGINEER’S negligent performance of the work specified in this agreement. 9.7.3. The ENGINEER agrees to defend, indemnify and hold harmless the OWNER, its officers, directors, agents and employees, should OWNER, its officers, directors, agents or employees be named as a defendant in any action where the OWNER’S alleged liability arises from the negligent performance of the ENGINEER’S work herein described. The obligations of the ENGINEER to defend, indemnify and hold harmless the OWNER will apply to any suit, cause of action, claim, cost or obligation including, without limitation, those alleged under the common law or pursuant to a federal or state statute or regulation including those arising in tort, trespass, nuisance, and strict liability. 9.7.4 In the event the OWNER is found proportionately responsible for any damages ultimately awarded to a plaintiff or plaintiffs in any lawsuit, the ENGINEER will be responsible for only those damages, costs, or liabilities as are attributable to the ENGINEER’S percent of fault as compared with 100% of the fault giving rise to the damages. Should the OWNER be found responsible for negligence by its own officers, directors, agents or employees, then in that event the OWNER agrees to reimburse the ENGINEER for the reasonable attorney’s fees and costs incurred in any defense of the OWNER in an amount proportional to the fault attributed to the 13 OWNER. The indemnity required herein shall not be limited by reason of the specification of any particular insurance coverage in this Agreement. 9.7.5 Should either OWNER or ENGINEER be held responsible, for any damages, costs or liabilities resulting from intentional misconduct by any officer, director, agent or employee in connection with the work specified in this Agreement, then in that event, that party shall defend, indemnify and hold harmless the other as to any damages, costs or liabilities that result from or arise out of that intentional misconduct, including reasonable attorney’s fees and costs which shall include costs and salary of the city attorney or other in-house counsel. Further, notwithstanding the obligations set forth in paragraphs 9.7.2 and 9.7.3 above, the ENGINEER agrees to defend OWNER where the OWNER’S alleged liability arises from intentional misconduct by the ENGINEER. Should the OWNER be found responsible for intentional misconduct by its own officer, director, agent or employee, then OWNER agrees to reimburse ENGINEER for the reasonable attorney’s fees and costs incurred in any defense of the OWNER. 9.7.6 The ENGINEER shall perform this agreement as an independent contractor, and as such, is responsible to the OWNER only as to the results to be obtained in the work herein specified, and to the extent that the work shall be done in accordance with the terms, plans and specifications. The ENGINEER shall have and maintain complete control over all of its employees, subcontractors, agents and operations, being responsible for any required payroll deductions and providing required benefits, such as, but not limited to worker’s compensation with statutory limits, and unemployment insurance. 9.8 INSURANCE The ENGINEER shall secure and furnish to the OWNER certificate of insurance, therein, naming the OWNER as an additional insured, to include thirty (30) days notice of cancellation or non-renewal. Without limiting any of ENGINEER's obligations hereunder, ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, insurance coverage naming the OWNER as additional insured with minimum insurance coverage as follows: 14 Type of Coverage Limits Employers' Liability: $ 100,000. per accident General Liability: Bodily Injury & Property Damage Single and combined $ 1,000,000. per accident General Aggregate: $ 2,000,000. Excess Liability Coverage (umbrella) $1,000,000. each occurrence Automobile: Bodily Injury covering all $ 1,000,000 each person automobiles, trucks, tractors, trailers, or $ 1,000,000 each occurrence other automotive equip- ment whether owned or rented by Engineer or owned by employees of Engineer. Property Damage covering $ 100,000 each occurrence all automobiles, trucks, tractors, trailers or other automotive equipment whether owned or rented by Engineer or owned by employees of Engineer OR Bodily Injury & Property $1,000,000 each occurrence Damage Single and combined In addition to the above insurance coverage, the ENGINEER shall secure and maintain, until the work is completed and accepted by the OWNER, and without naming OWNER as an additional insured, professional errors and omissions coverage as follows: Professional Errors & Omissions: $ 1,000,000 per claim and aggregate each occurrence 9.9 ENDORSEMENT The ENGINEER shall place his endorsement on all drawings and other data furnished by him. 15 9.10 OWNERSHIP OF DOCUMENTS The parties admit and agree the documents produced under this agreement are not intended or represented to be suitable for reuse by OWNER or any other individual on any other project. Any reuse without written verification or adaptation by ENGINEER will be at OWNER’s sole risk and without liability or legal exposure to ENGINEER, or to ENGINEER’s independent professional associates or consultants. Files in electronic media format of text, data, graphics, or of other types that are furnished by ENGINEER to OWNER are only for convenience of owner. Any conclusion or information obtained or derived from such electronic files will be at the user's sole risk. 9.11 PUBLIC INFORMATION The ENGINEER shall not issue any statements, releases or information for public dissemination without prior approval of the OWNER. 9.12 PROPRIETARY RIGHTS If patentable discoveries or inventions should result from work required herein, all rights accruing from such discoveries or inventions shall be joint property of the ENGINEER and the OWNER. Provided that the OWNER, state agencies or political subdivisions and the United States Government shall have the irrevocable, nonexclusive, nontransferable and royalty-free license to use each invention in the manufacture, use and disposition, according to law, of any article or material, and in the use of any method that may be developed as part of the work described and contemplated herein. 9.13 RECORDS The ENGINEER shall maintain accounting records and other evidence pertaining to the cost incurred and to make the records available at all reasonable times during the Contract term and for one (1) year from the date of final payment. Such accounting records and other evidence pertaining to the cost incurred will be made available for inspections by OWNER. 9.14 SUCCESSORS IN INTEREST The covenants, agreements and all statements in this Contract apply to and shall be binding on the heirs, personal representatives, successors and assigns of the respective parties. 16 9.15 ATTORNEY'S FEES AND COSTS That in the event it becomes necessary for either Party of this Contract to retain an attorney to enforce any of the terms or conditions of this Contract or to give any notice required herein, then the prevailing Party or the Party giving notice shall be entitled to reasonable attorney's fees and costs, including fees, salary, and costs of in-house counsel to include City Attorney. 9.16 MODIFICATIONS AND AMENDMENTS That any amendment or modification of this Contract or any provisions herein shall be made in writing or executed in the same manner as this original document and shall after execution become a part of this Contract. In witness Whereof, the Parties hereto do make and execute this Agreement. CITY OF BOZEMAN, MONTANA ENGINEER BY: BY: (City Manager) (President) DATE: DATE: ATTEST: BY: (City Clerk) 1 EXHIBIT A TO AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES ENGINEER'S STATUS DURING CONSTRUCTION This Exhibit is attached to, made a part of and incorporated by reference with the Agreement made on , between CITY OF BOZEMAN (OWNER) and (ENGINEER) providing for professional engineering services. ARTICLE 10 - ENGINEER'S STATUS DURING CONSTRUCTION 10.1. OWNER’S REPRESENTATIVE ENGINEER will be OWNER's representative during the construction period. The duties and responsibilities and the limitations of authority of ENGINEER as OWNER's representative during construction are set forth in the Contract Documents and shall not be extended without written consent of OWNER and ENGINEER. 10.2. VISITS TO THE SITE ENGINEER will make visits to the site at intervals appropriate to the various stages of construction to observe the progress and quality of the executed Work and to determine, in general, if the Work is proceeding in accordance with the Contract Documents. ENGINEER will not be required to make exhaustive or continuous on-site inspections to check the quality or quantity of the Work. ENGINEER's efforts will be directed toward providing for OWNER's greater degree of confidence that the completed Work will conform to the Contract Documents. On the basis of such visits and on-site observations as an experienced and qualified design professional, ENGINEER will keep OWNER informed of the progress of the Work and will endeavor to guard OWNER against defects and deficiencies in the Work. 10.3. PROJECT REPRESENTATION If OWNER and ENGINEER agree, ENGINEER will furnish a Resident Project Representative to assist ENGINEER in observing the performance of the Work. The duties, responsibilities and limitations of authority of any such Resident Project Representative and assistants will be as provided in EXHIBIT B, A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE. 10.4. CLARIFICATIONS AND INTERPRETATIONS ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the requirements of the Contract Documents (in the form of Drawings or otherwise) as ENGINEER may determine necessary, which shall be consistent with or reasonably inferable from the overall intent of the Contract Documents. If CONTRACTOR believes that a written clarification or interpretation justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree to the amount or extent thereof, CONTRACTOR may make a claim therefor as provided in the General Provisions of the construction Contract Document. 10.5. AUTHORIZED VARIATIONS IN WORK ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Time and are consistent with the overall intent of the Contract Documents. These may be accomplished by a Field Order and will be binding on OWNER, and also on CONTRACTOR who shall perform the Work involved promptly. If CONTRACTOR believes that a Field Order justifies an increase in the Contract Price or an extension of the Contract Time and the parties are unable to agree as 2 to the amount or extent thereof, CONTRACTOR may make a claim therefor as provided in the General Conditions of the Construction Contract. 10.6. REJECTING DEFECTIVE WORK ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, and will also have authority to require special inspection or testing of the Work as provided in the General Provisions of the construction Contract Document whether or not the work is fabricated, installed, or completed. 10.7. SHOP DRAWINGS, CHANGE ORDERS AND PAYMENT 10.7.1. The ENGINEER's responsibility for Shop Drawings and samples shall comply with the shop drawing provisions of the General Provisions of the construction Contract Document 10.7.2. The ENGINEER's responsibilities for Change Orders shall comply with the change order provisions of the General Provisions of the construction Contract Document. 10.7.3. The ENGINEER's responsibilities for contractor's Application for Payment shall comply with the payment provisions of the General Provisions of the construction Contract Document. 10.8. DETERMINATIONS FOR UNIT PRICES ENGINEER will determine the actual quantities and classifications of Unit Price Work performed by CONTRACTOR. ENGINEER will review with CONTRACTOR the ENGINEER's preliminary determinations on such matters before rendering a written recommendation thereon (by recommendation of an Application for Payment or otherwise) to OWNER. 10.9. DECISION ON DISPUTES 10.9.1. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. Claims, disputes and other matters relating to the acceptability of the Work or the interpretation of the requirements of the Contract Documents pertaining to the performance and furnishing of the Work and claims under The General Conditions of the Construction Contract in respect of changes in the Contract Price or Contract Time will be referred initially to ENGINEER in writing with a request for a formal decision in accordance with this paragraph, which ENGINEER will render in writing within a reasonable time. Written notice of each such claim, dispute and other matter shall be promptly reported and copied to the OWNER. 10.9.2. When functioning as interpreter under paragraphs 10.8 and 10.9.1, ENGINEER will not show partiality to OWNER or CONTRACTOR and will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to paragraphs 10.8 and 10.9.1 with respect to any such claim, dispute or other matter will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Contract Documents or by Laws or Regulations in respect of any such claim, dispute or other matter. 3 10.10. LIMITATIONS ON ENGINEER'S RESPONSIBILITIES 10.10.1. Neither ENGINEER's authority to act under this Article or elsewhere in the Contract Documents nor any decision made by ENGINEER in good faith either to exercise or not exercise such authority shall give rise to any duty or responsibility of ENGINEER to CONTRACTOR, any Sub-contractor, any Supplier, or any other person or organization performing any of the Work, or to any surety for any of them. 10.10.2. Whenever in the Contract Documents the terms "as ordered", "as directed", "as required", "as allowed", "as approved" or terms of like effect or import are used, or the adjectives "reasonable", "suitable", "acceptable", "proper" or "satisfactory" or adjectives of like effect or import are used to describe a requirement, direction, review or judgment of ENGINEER as to the Work, it is intended that such requirement, direction, review or judgment will be solely to evaluate the Work for compliance with the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective shall not be effective to assign to ENGINEER any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of paragraph 4.5.3. 1 EXHIBIT B TO AGREEMENT BETWEEN OWNER AND ENGINEER FOR PROFESSIONAL SERVICES A LISTING OF THE DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE. This Exhibit is attached to, made a part of and incorporated by reference with the Agreement made on , between CITY OF BOZEMAN (OWNER) and (ENGINEER) providing for professional engineering services. ARTICLE 11 - DUTIES, RESPONSIBILITIES AND LIMITATIONS OF AUTHORITY OF THE RESIDENT PROJECT REPRESENTATIVE ENGINEER shall furnish a Resident Project Representative (RPR), assistants and other field staff to assist ENGINEER in observing performance of the work of Contractor. Through more extensive on-site observations of the work in progress and field checks of materials and equipment by the RPR and assistants, ENGINEER shall endeavor to provide further protection for OWNER against defects and deficiencies in the work of CONTRACTOR; but, the furnishing of such services will not make ENGINEER responsible for or give ENGINEER control over construction means, methods, techniques, sequences or procedures or for safety precautions or programs, or responsibility for CONTRACTOR's failure to perform the Work in accordance with the Contract Documents and in particular the specific limitations set forth in section 4.5 of the Agreement are applicable. The duties and responsibilities of the RPR are limited to those of ENGINEER in this agreement and in the construction Contract Documents, and are further limited and described as follows: 11.1. GENERAL RPR is ENGINEER's agent at the site, will act as directed by and under the supervision of ENGINEER, and will confer with ENGINEER regarding RPR's actions. RPR's dealings in matters pertaining to the on-site work shall in general be with ENGINEER and CONTRACTOR keeping OWNER advised as necessary. RPR's dealings with subcontractors shall only be through or with the full knowledge and approval of CONTRACTOR. RPR shall generally communicate with OWNER with the knowledge of and under the direction of ENGINEER. 11.2. DUTIES AND RESPONSIBILITIES OF RPR 11.2.1. Schedules: Review the progress schedule, schedule of Shop Drawing submittals and schedule of values prepared by CONTRACTOR and consult with ENGINEER concerning acceptability. 11.2.2. Conferences and Meetings: Attend meetings with CONTRACTOR, such as preconstruction conferences, progress meetings, job conferences and the project-related meetings, and prepare and circulate copies of minutes thereof. 11.2.3. Liaison: 11.2.3.1. Serve as ENGINEER's liaison with CONTRACTOR, working principally through CONTRACTOR's superintendent and assist in understanding the intent of the Contract Documents; and assist ENGINEER in serving as OWNER's liaison with CONTRACTOR. 2 11.2.3.2. Assist in obtaining from OWNER additional details or information, when required for proper execution of the Work. 11.2.4. Shop Drawings and Samples: 11.2.4.1. Record date of receipt of Shop Drawings and samples. 11.2.4.2. Receive samples which are furnished at the site by CONTRACTOR, and notify ENGINEER of availability of samples for examination. 11.2.4.3. Advise ENGINEER and CONTRACTOR of the commencement of any Work requiring Shop Drawing or sample if the submittal has not been approved by ENGINEER. 11.2.5. Review of Work, Rejection of Defective Work, Inspections and Tests: 11.2.5.1. Conduct on-site observations of the Work in progress to assist ENGINEER in determining if the Work is in general proceeding in accordance with the Contract Documents. 11.2.5.2. Report to ENGINEER whenever RPR believes that any Work is unsatisfactory, faulty or defective or does not conform to the Contract Documents, or has been damaged, or does not meet the requirements of any inspection, test or approval required to be made; and advise ENGINEER of Work that RPR believes should be corrected or rejected or should be uncovered for observation, or requires special testing, inspection or approval. 11.2.5.3. Verify that tests, equipment and systems startup and operating and maintenance training are conducted in the presence of appropriate personnel, and the CONTRACTOR maintains adequate records thereof; and observe, record and report to ENGINEER appropriate details relative to the test procedures and startup. 11.2.5.4. Accompany visiting inspectors representing public or other agencies having jurisdiction over the Project, record the results of these inspections and report to ENGINEER. 11.2.6. Interpretation of Contract Documents: Report to ENGINEER when clarifications and interpretations of the Contract Documents are needed and transmit to CONTRACTOR clarifications and interpretations as issued by ENGINEER. 11.2.7. Modifications: Consider and evaluate CONTRACTOR's suggestions for modifications in Drawings or Specifications and report with RPR's recommendations to ENGINEER. Transmit to CONTRACTOR decisions as issued by ENGINEER. 11.2.8. Records: 11.2.8.1. Maintain at the job site orderly files for correspondence, reports of job conferences, Shop Drawings and samples, reproductions of original Contract Documents including all Work Directive Changes, Addenda, Change Orders, Field Orders, additional Drawings issued subsequent to the execution of the Contract, ENGINEER's clarifications and interpretations of the Contract Documents, progress reports, and other Project related documents. 11.2.8.2. Keep a detailed and accurate diary or log book, recording CONTRACTOR hours on the job site, weather conditions, prime and subcontractor daily work force, daily log of equipment onsite or on standby, data relative to questions of Work Directive Changes, Change Orders or changed conditions, list of job site visitors, daily activities, decisions, observations in general, and 3 specific observations in more detail as in the case of observing test procedures; and send copies to ENGINEER. 11.2.8.3. Record names, addresses and telephone numbers of all CONTRACTORS, subcontractors and major suppliers of materials and equipment. 11.2.9. Reports: 11.2.9.1. Furnish ENGINEER periodic reports as required of progress of the Work and of CONTRACTOR's compliance with the progress schedule and schedule of Shop Drawing and sample submittals. 11.2.9.2. Consult with ENGINEER in advance of scheduled major tests, inspections or start of important phases of the Work. 11.2.9.3. Draft proposed Change Orders and Work Directive Changes, obtaining backup material from CONTRACTOR and recommend to ENGINEER Change Orders, Work Directive Changes, and Field Orders. 11.2.9.4. Report immediately to ENGINEER and OWNER upon the occurrence of any accident. 11.2.10. Payment Requests: Review applications for payment with CONTRACTOR for compliance with the established procedure for their submission and forward with recommendations to ENGINEER, noting particularly the relationship of the payment requested to the schedule of values, Work completed and materials and equipment delivered at the site but not incorporated in the Work. 11.2.11. Certificates, Maintenance and Operation Manuals: During the course of the Work, verify that certificates, maintenance and operation manuals and other data required to be assembled and furnished by CONTRACTOR are applicable to the items actually installed and in accordance with the Contract Documents, and have this material delivered to ENGINEER for review and forwarding to OWNER prior to final payment for the Work. 11.2.12. Completion: 11.2.12.1. Submit to CONTRACTOR, and ENGINEER a list of observed items requiring completion or correction before ENGINEER may issue a Certificate of Substantial Completion. 11.2.12.2 Assess completion or correction of items noted under 11.2.12.1, advise ENGINEER on their status, and make recommendation to Engineer regarding issuance of a Certificate of Substantial completion. 11.2.12.3. Conduct final inspection in the company of ENGINEER, OWNER, and CONTRACTOR and prepare a final list of items to be completed or corrected. 11.2.12.4. Observe that all items on final list have been completed or corrected and make recommendations to ENGINEER concerning final acceptance. 11.3. LIMITATIONS OF AUTHORITY Resident Project Representative: 11.3.1. Shall not authorize any deviation from the Contract Documents or substitution of materials or equipments, unless authorized by ENGINEER. 4 11.3.2. Shall not exceed limitations of ENGINEER's authority as set forth in the Agreement or the Contract Documents. 11.3.3. Shall not undertake any of the responsibilities of CONTRACTOR, subcontractors or CONTRACTOR's superintendent. 11.3.4. Shall not advise on, issue directions relative to or assume control over any aspect of the means, methods, techniques, sequences or procedures of construction unless such advice or directions are specifically required by the Contract Documents. 11.3.5. Shall not advise on, issue directions regarding or assume control over safety precautions and programs in connection with the Work. 11.3.6. Shall not accept Shop Drawing or sample submittals from anyone other than CONTRACTOR. 11.3.7. Shall not authorize OWNER to occupy the Project in whole or in part. 11.3.8. Shall not participate in specialized field or laboratory tests or inspections conducted by others except as specifically authorized by ENGINEER.