HomeMy WebLinkAbout18- Construction Agreement - FieldTurf USA, Inc. - Bozeman Sports Park ATTACHMENT B
CONSTRUCTION AGREEMENT
This Construction Agreement is made this Lday of ,I(-LWz , 20t5,
by and between the CITY OF BOZEMAN, MONTANA, a municipal corporation organized
and existing under the laws of the State of Montana, P.O. Box 1231, Bozeman, Montana 59771-
1231 ("City"), and FIELDTURF USA, Inc., whose mailing address is 7445 Cote-de-Liesse
Road, Suite 200, Montreal, Quebec, Canada 1-14T 1G2("Contractor").
Recitals
A. The City has approved the use of Cooperative Purchasing Agreement awarded by
the Association of Educational Purchasing Agencies Invitation for Bid#016 - G ("AEPA IFA
#016-G"—Exhibit H) for the construction of artificial turf fields and associated sitework
including but not limited to the installation of asphalt, concrete, drainage, and gravel paths for
the Bozeman Sports Park ("Construction Project")pursuant to the requirements of all
applicable statutes, rules, regulations, and ordinances.
B. The City has analyzed and accepted the price quotation submitted by the
Contractor under the terms of AEPA#016-G (Exhibit H) pursuant to its standard practices and
the requirements of all applicable statutes, rules, regulations, and ordinances.
C. The City therefore awards the bid to the Contractor,pursuant to the terms and
conditions of this Agreement.
NOW THEREFORE, in consideration of the covenants, agreements, representations,
and warranties contained herein, the parties agree as follows:
Agreement
1. Work to be Performed:
a. A description of the Construction Project and Contractor's duties is set forth
in the CONTRACTOR'S BID FORM (Exhibit B) as awarded and accepted by City
including the DETAILED GRADING PLAN prepared by DOWL dated 4/23/2018 for the
BOZEMAN SPORTS PARK ARTIFICIAL TURF FIELDS NOS. 5 -6, located at 4600
Baxter Lane, 59718 (Exhibit G) , which are attached hereto and incorporated herein by j
this reference, and the drawings, plans, and specifications provided by the City and its
architects and engineers. Where a provision of any other portion of the Construction
Documents conflicts with this Agreement,the terms and conditions of this Agreement
shall control.
b. Prior to the commencement of any work on the Construction Project,
Contractor's representatives and City's representatives shall hold a meeting to establish a
working understanding among the parties as to the scope of the Construction Project and
duties of the Contractor. At this meeting, Contractor and City shall resolve any
outstanding issues related to the plans, designs, drawings, and specifications. If the parties
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 1 of 35
are unable to resolve these issues and the City fails, refuses, or is unable to approve the
same, no work shall commence on the Construction Project until such issues are resolved
and the City approves the related plans, designs, drawings, and specifications.
C. Except as provided elsewhere in this Agreement, Contractor shall furnish
all the labor, materials, equipment, tools, and services necessary to perform and complete
the Construction Project. The Contractor's Bid Form is attached here and incorporated
into this Agreement as Exhibit B.
d During work on the Construction Project, and as part of the final
completion of the Construction Project, Contractor shall clean up the Project site,
including the removal and satisfactory disposal of all waste, garbage, excess materials,
equipment, temporary buildings, the removal or grading of all embankments made for
construction purposes, the filling in of all excavations, and the performance of any other
work necessary to restore the site to at least as good order and condition as at the
commencement of the Construction Project.
2. City-Supplied Materials: The City may supply materials from time to time in
furtherance of the Construction Project. Such materials will be noted as an addendum to this
Agreement.
3. Time of Performance:
a Contractor shall begin the Construction Project after receiving a Notice to
Proceed from City and shall complete the Construction Project within seventy (70) days
(10 weeks) of the starting date stated in the Notice to Proceed. After receiving the 'Notice
to Proceed" from the City Contractor shall develop a Construction Schedule for approval
by the City which shall become part of this Agreement. Time is of the essence of
completion of all work and each phase of the Construction Project.
b. The Construction Schedule is subject to the City's approval. Contractor's
construction plan, methods of operation, materials used, and individuals and
subcontractors employed (collectively"Contractor's Resources") are subject to the City's
approval at all times during the term of this Agreement, and must be such as to ensure the
completion of the work in compliance with the deadlines set in the Construction Schedule
during the term of this Agreement. In the event the City determines the Contractor's
Resources are inadequate to meet the approved Construction Schedule, the City may order
the Contractor to accelerate its performance to give reasonable assurances of timely
completion and quality results. Acceleration under this section shall not be deemed a
Change Order as defined in Section 5.b. ("Compensation") below and the Contractor shall
receive no equitable adjustment for such acceleration. Nothing in this section shall be
interpreted to relieve the Contractor of its duties and responsibilities to plan for and
complete the work in a timely manner according to the Construction Schedule.
4. Liquidated Damages: If the Construction Project is not completed within the
time provided by this Agreement, the City may deduct for each day the Construction Project
remains uncompleted the sum of(n/a) from the compensation hereinafter specified and retain
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 2 of 35
that sum as payment for liquidated damages sustained by reason of the Contractor's failure to
complete the Construction Project on time.
5. Compensation:
a. City shall pay to Contractor, and Contractor shall accept as full payment for
the performance of this Agreement and the Construction Project, the amount not to
exceed seven hundred ninety-six thousand three hundred ninety-six and 58/100
dollars ($796,396.58) subject to Change Orders approved by both parties, in accordance
with Exhibit C.
b. If work not included within the original Construction Documents is
requested by City, such additional work and the related compensation shall be agreed to
in writing by both parties prior to commencement of the additional work ("Change
Order") pursuant to the Exhibit D - Change of Work Specifications set forth attached
hereto.
C. Monthly progress payments and final payment will be made only in
accordance with the terms of a completed Compensation Schedule to be approved by the
City's Representative. All invoices must be submitted to the City's Representative.
d City shall retain five percent (5%) of the total amount of compensation to
be paid to the Contractor to ensure compliance with the terms and conditions of this
Agreement and the timely completion of the Construction Project and any and all "punch
list" items ("Retainage Amount"). The Retainage Amount shall be paid to Contractor
thirty (30) days after the City's final acceptance of the portion of work for which a
separate price is stated in the specifications for the Construction Project.
e. Upon acceptance of final payment and for other good and valuable
consideration, Contractor shall and hereby does release and forever discharge City, its
officers, agents, and employees of and from any and all claims, demands, actions, causes
of action, obligations, and liabilities of every kind and character whatsoever, in law and
in equity, whether now known or in the future discovered, arising from or related to this
Agreement or the Construction Project that Contractor may have or assert against City, its
officers, agents, and employees.
6. Inspection and Testing:
a. City has the right to inspect and test any and all work performed by
Contractor on the Construction Project. Contractor shall allow City and its agents access
to the Construction Project at all times and shall provide every reasonable facility for the
purpose of such inspection and testing, including temporarily discontinuing portions of the
work or uncovering or taking down portions of the finished work. Any inspection and
testing performed by the City and its agents is for the sole benefit of the City and shall
not relieve the Contractor of its duty, responsibility, and obligation to ensure that the
work strictly complies with the Agreement terms and conditions and all applicable laws
and building and safety codes. City's inspection and testing shall not be deemed or
CONSTRUCTION AGREEMENT with FIELDTURF AO for SPORTS PARK
Page 3 of 35
considered acceptance by the City of any portion of the Construction Project. City's
inspection and testing shall not serve to nullify, amend, or waive any warranties provided
by the Contractor under this Agreement.
h. Contractor shall, without charge, replace any material or correct any work
found by the City or its agents to be defective or otherwise not in compliance with the
terms and conditions of this Agreement. In the event Contractor fails to replace or correct
any defective work or materials after reasonable written notice by the City to do so, the
City may take such corrective action, either with its own materials and employees or by
retaining any third party to do so, and deduct the cost and expense of such corrective
action from the Contractor's compensation.
7. Partial Utilization of Construction Project: City shall have the right to use or
occupy any portion of the Construction Project that City and Contractor mutually agree is
substantially completed and constitutes a separately functioning and usable part of the
Construction Project for its intended purpose without significant interference with Contractor's
performance of the remaining portions of the Construction Project. In the event City takes
possession of any portion of the Construction Project, such possession shall not be deemed an
acceptance of the Construction Project, in whole or in part. Contractor shall still be required to
conduct any final testing of the portions in the possession of the City. City's use of any portion of
the Construction Project shall not be grounds for extensions of any construction deadlines or a
change in the Contractor's compensation. Contractor's warranties shall run from the completion
of the total Construction Project and not from the date the City may take possession of selected
portions of the Construction Project.
8. Related Work at the Site: Nothing in this Agreement shall prevent or preclude
City, through its own employees or by contract with any third party, from performing other work
related to the Construction Project at the construction site; provided such related work is not
otherwise addressed in this Agreement and provided such related work does not otherwise
interfere with Contractor's performance of this Agreement or the completion of the Construction
Project. Contractor shall afford any City employee, agent or representative, or any third party
under contract with the City to perform the related work, proper and safe access to the
construction site, a reasonable opportunity for the introduction and storage of materials and
equipment, the opportunity to perform the related work, and shall properly coordinate the
Contractor's work on the Construction Project with the related work.
9. Contractor's Warranties: Contractor represents and warrants as follows:
a. Unless otherwise specified by the terms of this Agreement, all materials
and equipment used by Contractor on the Construction Project shall be new and where not
otherwise specified, of the most suitable grade for their intended uses.
h. All workmanship and materials shall be of a kind and nature acceptable to
the City.
C. All equipment, materials, and labor provided to, on, or for the
Construction Project must be free of defects and nonconformities in design, materials, and
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 4 of 35
workmanship for a minimum period beginning with the commencement of the work on
the Construction Project and ending one (1) calendar year from the final completion and
acceptance by the City of the Construction Project, regardless of whether such
equipment, materials, or labor were supplied directly by Contractor or indirectly by
Contractor's subcontractors or suppliers. Other express warranties on materials that
provide for a warranty period longer than one year apply for the period of that express
warranty and are not reduced by this provision. Upon receipt of City's written notice of a
defective or nonconforming condition during the warranty period, Contractor shall take
all actions, including redesign and replacement, to correct the defective or nonconforming
condition within a time frame acceptable to the City and at no additional cost to the City.
Contractor shall also, at its sole cost, perform any tests required by City to verify that such
defective or nonconforming condition has been corrected. Contractor warrants the
corrective action taken against defective and nonconforming conditions for a period of an
additional one (1) year from the date of City's acceptance of the corrective action.
d Contractor and its sureties are liable for the satisfaction and full
performance of all warranties.
e. Contractor shall give its personal attention to the faithful prosecution of the
completion of the Construction Project and Contractor, or its duly authorized
representative assigned to serve as the Construction Project Manager, shall be personally
present at the site of the Construction Project during working hours for the term of this
Agreement until the completion of the Construction Project.
£ Contractor shall have a complete, accurate, and up-to-date set of
construction plans, drawings, and specifications on site at all times.
g, Contractor has examined all available records and made field
examinations of the site of the Construction Project. Contractor has knowledge of the
field conditions to be encountered during the Construction Project. Contractor has
knowledge of the types and character of equipment necessary for the work, the types of
materials needed and the sources of such materials, and the condition of the local labor
market.
h Contractor is responsible for the safety of the work and shall maintain all
lights, guards, signs, temporary passages, or other protections necessary for that purpose
at all times.
i All work must be performed at Contractor's risk, and Contractor shall
promptly repair or replace all damage and loss at its sole cost and expense regardless of
the reason or cause of the damage or loss; provided, however, should the damage or loss
be caused by an intentional or negligent act of the City, the risk of such loss shall be
placed on the City.
j. Contractor is responsible for any loss or damage to materials, tools, or
other articles used or held for use in the completion of performance of the Construction
Project.
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 5 of 35
k Contractor's performance must be without damage or disruption to any
other work or property of the City or of others and without interference with the operation
of existing machinery or equipment.
1 Title to all work, materials, and equipment covered by any payment of
Contractor's compensation by City, whether directly incorporated into the Construction
Project or not, passes to City at the time of payment, free and clear of all liens and
encumbrances.
10. Delays and Extensions of Time: If Contractor's performance of this Agreement
is prevented or delayed by any unforeseen cause beyond the control of the Contractor, including
acts or omissions of the City, Contractor shall, within ten (10) days of the commencement of any
such delay, give the City written notice thereof. Further, Contractor shall, within ten (10) days of
the termination of such delay, give the City written notice of the total actual duration of the delay.
If the City is provided with these required notices and if the City determines that the cause of the
delay was not foreseeable, was beyond the control of the Contractor, and was not a result of the
fault or negligence of the Contractor, then the City will determine the total duration of the delay
and extend the time for performance of the Agreement accordingly. Unless the delay is caused
by the intentional interference of the City with the Contractor's performance, Contractor shall
make no claim for damages or any other claim other than for an extension of time as herein
provided by reason of any delays.
11. Suspension:
a The City may, by written notice to the Contractor and at its convenience
for any reason, suspend the performance of all or any portion of the work to be performed
on the Construction Project("Notice of Suspension"). The Notice of Suspension shall set
forth the time of suspension, if then known to the City. During the period of suspension,
Contractor shall use its best efforts to minimize costs associated with the suspension.
b. Upon Contractor's receipt of any Notice of Suspension, unless the notice
requires otherwise, Contractor shall: (1) immediately discontinue work on the date and to
the extent specified in the Notice of Suspension; (2) place no further orders or
subcontracts for materials, services, or equipment; (3)promptly make every reasonable
effort to obtain suspension upon terms satisfactory to City of all orders, subcontracts, and
rental agreements to the extent that they relate to the performance of the work suspended;
and (4) continue to protect and maintain the Project, including those portions on which
work has been suspended.
C. As compensation for the suspended work, Contractor will be reimbursed
for the following costs, reasonably incurred, without duplication of any item, and to the
extent that such costs directly resulted from the suspension: (1) a standby charge paid
during the period of suspension which will be sufficient to compensate Contractor for
keeping, to the extent required in the Notice of Suspension, Contractor's organization and
equipment committed to the Project in standby status; (2) all reasonably incurred costs
for the demobilization of Contractor's and subcontractor's crews and equipment; (3) an
equitable amount to reimburse Contractor for the cost to protect and maintain the Project
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 6 of 35
during the period of suspension; and (4) an equitable adjustment in the cost of performing
the remaining portion of the work post-suspension if, as a direct result of the suspension,
the cost to Contractor of subsequently performing the remaining work on the
Construction Project has increased or decreased.
d Upon receipt of written notice by the City to resume the suspended work
("Notice to Resume Work"), Contractor shall immediately resume performance of the
suspended work as to the extent required in the Notice to Resume Work. Any claim by
Contractor for time or compensation described in Section I I(c) shall be made within
fifteen (15) days after receipt of the Notice to Resume Work and Contractor shall submit a
revised Construction Schedule for the City's review and approval. Contractor's failure to
timely make such a claim shall result in a waiver of the claim.
e. No compensation described in Section 1 I(c) shall be paid and no extension
of time to complete the Construction Project shall be granted if the suspension results
from Contractor's non-compliance with or breach of the terms or requirements of this
Agreement.
12. Termination for Contractor's Fault:
a. If Contractor refuses or fails to timely do the work, or any part thereof, or
fails to perform any of its obligations under this Agreement, or otherwise breaches any
terms or conditions of this Agreement, the City may, by written notice, terminate this
Agreement and the Contractor's right to proceed with all or any part of the Construction
Project("Termination Notice Due to Contractor's Fault"). The City may then take over
the Construction Project and complete it, either with its own resources or by re-letting the
contract to any other third party, and may immediately take possession of and use such
materials, appliances, tools, and equipment as may be on the site and which may be
necessary for the completion of the Construction Project.
b. In the event of a termination pursuant to this Section 12, Contractor shall
be entitled to payment only for those services Contractor actually rendered. In the case of
a lump sum or unit price contract, Contractor shall not be entitled to any further payment
until the Construction Project has been completed. Upon completion of the Construction
Project, if the unpaid balance of the Contractor's compensation exceeds the cost to the
City of completing the work, including all costs paid to any subcontractors or third
parties retained by the City to complete the Construction Project and all administrative
costs resulting from the termination ("City's Cost for Completion"), such excess shall be
paid to the Contractor. If the City's Cost for Completion exceeds the unpaid balance of the
Contractor's compensation, then Contractor and its sureties shall be liable for and shall
pay the difference, plus interest at the rate applicable to court judgments, to the City.
C. Any termination provided for by this Section 12 shall be in addition to any
other remedies to which the City may be entitled under the law or at equity.
d In the event of termination under this Section 12, Contractor shall, under
no circumstances, be entitled to claim or recover consequential, special, punitive, lost
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 7 of 35
business opportunity, lost productivity, field office overhead, general conditions costs, or
lost profits damages of any nature arising, or claimed to have arisen, as a result of the
termination.
13. Termination for City's Convenience:
a. Should conditions arise which, in the sole opinion and discretion of the
City, make it advisable to the City to cease work on the Construction Project, City may
terminate this Agreement by written notice to Contractor("Notice of Termination for
City's Convenience"). The termination shall be effective in the manner specified in the
Notice of Termination for City's Convenience and shall be without prejudice to any
claims that the City may otherwise have against Contractor.
b. Upon receipt of the Notice of Termination for City's Convenience, unless
otherwise directed in the Notice, the Contractor shall immediately cease work on the
Construction Project, discontinue placing orders for materials, supplies, and equipment for
the Construction Project, and make every reasonable effort to cancel all existing orders or
contracts upon terms satisfactory to the City. Contractor shall do only such work as may
be necessary to preserve, protect, and maintain work already completed, in progress, or in
transit to the construction site.
C. In the event of a termination pursuant to this Section 13, Contractor is
entitled to payment only for those services Contractor actually rendered and materials
actually purchased or which Contractor has made obligations to purchase on or before the
receipt of the Notice of Termination for City's Convenience, and reasonably incurred
costs for demobilization of Contractor's and any subcontractor's crews. It is agreed that
any materials that City is obligated to purchase from Contractor will remain the City's
sole property.
d The compensation described in Section 13(c) is the sole compensation due
to Contractor for its performance of this Agreement. Contractor shall, under no
circumstances, be entitled to claim or recover consequential, special, punitive, lost
business opportunity, lost productivity, field office overhead, general conditions costs, or
lost profits damages of any nature arising, or claimed to have arisen, as a result of the
termination.
14. Limitation on Contractor's Damages; Time for Asserting Claim:
a. In the event of a claim for damages by any of the parties under this
Agreement, the parties damages shall be limited to contract damages and the parties
hereby expressly waive any right to claim or recover consequential, special, punitive, lost
business opportunity, lost productivity, field office overhead, general conditions costs, or
lost profits damages of any nature or kind.
h In the event Contractor wants to assert a claim for damages of any kind or
nature, Contractor shall provide City with written notice of its claim, the facts and
circumstances surrounding and giving rise to the claim, and the total amount of damages
sought by the claim, within ten (10) days of the facts and circumstances giving rise to the
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 8 of 35
claim. In the event Contractor fails to provide such notice, Contractor shall waive all
rights to assert such claim.
15. Representatives:
a. City's Representative: The City's Representative for the purpose of this
Agreement shall be Carolyn Poissant, Trails, Open Space and Parks Program Manager, or
such other individual as City shall designate in writing. Whenever approval or
authorization from or communication or submission to City is required by this Agreement,
such communication or submission shall be directed to the City's Representative and
approvals or authorizations shall be issued only by such Representative; provided,
however, that in exigent circumstances when City's Representative is not available,
Contractor may direct its communication or submission to other designated City
personnel or agents and may receive approvals or authorization from such persons.
b Contractor's Representative: The Contractor's Representative for the
purpose of this Agreement shall be Jed Easterbrook, Rocky Mountain Regional Manager,
or such other individual as Contractor shall designate in writing. Whenever direction to or
communication with Contractor is required by this Agreement, such direction or
communication shall be directed to Contractor's Representative; provided, however, that
in exigent circumstances when Contractor's Representative is not available, City may
direct its direction or communication to other designated Contractor personnel or agents.
16. Locating Underl4round Facilities: Contractor shall be responsible for obtaining
and determining the location of any underground facilities, including but not limited to, the
location of any pipelines or utility supply, delivery, or service lines in accordance with the
provisions of§69-4-501, et seq., MCA. Contractor shall make every effort to avoid damage to
underground facilities and shall be solely responsible for any damage that may occur. If City
personnel assume responsibility for locating any underground facilities, this fact shall be noted in
writing prior to commencement of such location work.
17. Permits: Contractor shall provide all notices, comply with all applicable laws,
ordinances, rules, and regulations, obtain all necessary permits, licenses, including a City of
Bozeman business license, and inspections from applicable governmental authorities, pay all fees
and charges in connection therewith, and perform all surveys and locations necessary for the
timely completion of the Construction Project.
18. Ownership of Documents; Indemnification: All plans, designs, drawings,
specifications, documents, sample results and data, in whatever medium or format, originated or
prepared by or for Contractor in contemplation of, or in the course of, or as a result of this
Agreement or work on the Construction Project, shall be promptly fiirnished to the City ("City
Documents and Information"). All City Documents and Information shall be the exclusive
property of the City and shall be deemed to be works-for-hire. Neither party grants to the other
any express or implied licenses under any patents, copyrights, trademarks, or other intellectual
property rights, except to the extent necessary to complete its obligations to the other under this
Agreement.
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 9 of 35
19. Laws and Regulations: Contractor shall comply fillly with all applicable state
and federal laws, regulations, and municipal ordinances including, but not limited to, all
workers' compensation laws, all environmental laws including, but not limited to, the generation
and disposal of hazardous waste, the Occupational Safety and Health Act (OSHA), the safety
rules, codes, and provisions of the Montana Safety Act in Title 50, Chapter 71, MCA, all
applicable City, County, and State building and electrical codes, the Americans with Disabilities
Act, and all non-discrimination, affirmative action, and utilization of minority and small business
statutes and regulations.
20. Non-discrimination: Contractor agrees that all hiring by Contractor of persons
performing under this Agreement will be on the basis of merit and qualifications. The Contractor
shall have a policy to provide equal employment opportunity in accordance with all applicable
state and federal anti-discrimination laws, regulations, and contracts. The Contractor shall not
refuse employment to a person, bar a person from employment, or discriminate against a person
in compensation or in a term, condition, or privilege of employment because of race, color,
religion, creed, political ideas, sex, age, marital status, national origin, actual or perceived sexual
orientation, gender identity, physical or mental disability, except when the reasonable demands
of the position require an age, physical or mental disability, marital status or sex distinction. The
Contractor shall be subject to and comply with Title VI of the Civil Rights Act of 1964; Section
140, Title 2, United States Code, and all regulations promulgated thereunder. The Contractor
shall require these nondiscrimination terms of its sub-contractors providing services under this
agreement.
21. Intoxicants; DOT Drug and Alcohol Regulations: Contractor shall not permit
or suffer the introduction or use of any intoxicants, including alcohol or illegal drugs, upon the
site of the Construction Project. Contractor acknowledges it is aware of and shall comply with
its responsibilities and obligations under the U.S. Department of Transportation (DOT)
regulations governing anti-drug and alcohol misuse prevention plans and related testing. City
shall have the right to request proof of such compliance and Contractor shall be obligated to
furnish such proof.
22. Labor Relations:
a Contractor shall post a legible statement of all wages and fringe benefits to
be paid to the Contractor's employees and the frequency of such payments (i.e., hourly
wage employees shall be paid weekly). Such posting shall be made in a prominent and
accessible location at the site of the Construction Project and shall be made no later than
the first day of work. Such posting shall be removed only upon the final completion of
the Construction Project and the termination of this Agreement.
b. In performing the terms and conditions of this Agreement and the work on
the Construction Project, Contractor shall give preference to the employment of bona fide
residents of Montana, as required by §18-2-403, MCA, and as such, term is defined by
§18-2-401(1), MCA. When making assignments of work, Contractor shall use workers
both skilled in their trade and specialized in their field of work for all work to which they
are assigned.
c Pursuant to §§18-2-403 and 18-2-422, MCA, Contractor shall pay wages,
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 10 of 35
benefits, and expenses in conformance with the current version of the Prevailing Wage
Rates for Building Construction Services as published by the Montana Department of
Labor and Industry and which are applicable to Gallatin County. Contractor shall pay all
hourly wage employees on a weekly basis. Violation of the requirements to pay
applicable prevailing wage rates may subject the Contractor to the penalties set forth in
§18-2-407, MCA. Contractor shall maintain payroll records and provide certified copies
to the City. Contractor shall maintain such payroll records during the term of this
Agreement, the course of the work on the Construction Project, and for a period of three
(3) calendar years following the date of final completion of the Construction Project and
termination of this Agreement.
d In the event that, during the term of this Agreement and throughout the
course of Contractor's performance of the Construction Project, any labor problems or
disputes of any type arise or materialize which in turn cause any work on the Construction
Project to cease for any period of time, Contractor specifically agrees to take immediate
steps, at its own expense and without expectation of reimbursement from City, to alleviate
or resolve all such labor problems or disputes. The specific steps Contractor shall take to
resume work on the Construction Project shall be left to the discretion of Contractor;
provided, however, that Contractor shall bear all costs of any related legal action.
Contractor shall provide immediate relief to the City so as to permit the work on the
Construction Project to resume and be completed within the time frames set forth in the
Construction Schedule at no additional cost to City.
e Contractor shall indemnify, defend, and hold the City harmless from any
and all claims, demands, costs, expenses, damages, and liabilities arising out of, resulting
from, or occurring in connection with any labor problems or disputes or any delays or
stoppages of work associated with such problems or disputes.
23. Subcontractors:
a. Contractor may employ subcontractors for any work on the Construction
Project. Contractor shall provide City with a list of all subcontractors employed.
b. Contractor remains fully responsible for the acts and omissions of any
subcontractor,just as Contractor is for its own acts and omissions, and Contractor shall
remain fully responsible and liable for the timely completion of the Construction Project.
C Contractor is solely liable for any and all payments to subcontractors.
Contractor shall hold all payments received from the City in trust for the benefit of
subcontractors, and all such payments shall be used to satisfy obligations of the
Construction Project before being used for any other purpose. Contractor shall make any
payments due to any subcontractor within seven(7) days of Contractor's receipt of
payment, including a proportional part of the retainage Contractor has received from the
City. In the event of a dispute regarding any subcontractor's invoice, Contractor shall
promptly pay the undisputed amount to the subcontractor and notify the subcontractor in
writing of the amount in dispute and the reasons for the dispute. Any withholding of
payment must comply with the requirements of§28-2-2103, MCA. In the event the
Contractor is unwilling or unable to make timely and proper payment to any
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 11 of 35
subcontractor, City may elect to withhold any payment otherwise due to Contractor and
upon seven (7) days' written notice to Contractor, may pay subcontractor by direct or
joint payment.
24. Indebtedness and Liens: Before City may make any final payment to Contractor,
Contractor shall furnish City with satisfactory proof that there are no outstanding debts or liens in
connection with the Construction Project. If the Contractor allows any indebtedness to accrue to
subcontractors or others during the progress of the work, and fails to pay or discharge the same
within five (5) days after demand, then City may either withhold any money due to Contractor
until such indebtedness is paid or apply the same towards the discharge of the indebtedness. If
any lien or claim is filed or made by any subcontractor, material supplier, or any other person, the
Contractor shall immediately notify the City and shall cause the same to be discharged of record
within thirty (30) days after its filing.
25. Hazard Communication: Contractor shall comply with all hazard
communication requirements dictated by the Environmental Protection Agency, the Montana
Department of Agriculture, OSHA, Hazard Communications Standard, 29 CFR 1910.1200, and
applicable City ordinances. Contractor shall supply a chemical list, the associated material safety
data sheets (MSDS), and other pertinent health exposure data for chemicals that the Contractor's,
subcontractor's or the City's employees may be exposed to while working on City property
during the course of the Construction Project. One copy of this documentation must be delivered
to City to the attention of the City's Representative. This documentation must be delivered before
work involving these chemicals may commence.
26. Accounts and Records: During the term of this Agreement and for two (2) years
following the City's final acceptance of the Construction Project, Contractor shall maintain
accounts and records related to the Construction Project. Upon reasonable notice, City shall
have the right to inspect all such accounts and records, including but not limited to, Contractor's
records, books, correspondence, instructions, drawings, specifications, field and site notes,
receipts, invoices, bills, contracts, or other documents relating to the Construction Project.
27. Indemnification; Insurance;Bonds:
a. Contractor agrees to release, defend, indemnify, and hold harmless the
City, its agents, representatives, employees, and officers (collectively referred to for
purposes of this Section as the City) from and against any and all claims, demands,
actions, fees and costs (including attorney's fees and the costs and fees of and expert
witness and consultants), losses, expenses, liabilities (including liability where activity is
inherently or intrinsically dangerous) or damages of whatever kind or nature connected
therewith and without limit and without regard to the cause or causes thereof or the
negligence of any party or parties that may be asserted against, recovered from or
suffered by the City occasioned by, growing or arising out of or resulting from or in any
way related to: (i) the negligent, reckless, or intentional misconduct of the Contractor; (ii)
any negligent, reckless, or intentional misconduct of any of the Contractor's agents.
b. Such obligations shall not be construed to negate, abridge, or reduce other
rights or obligations of indemnity that would otherwise exist. The indemnification
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 12 of 35
obligations of this Section must not be construed to negate, abridge, or reduce any
common-law or statutory rights of the indemnitee(s) which would otherwise exist as to
such indemnitee(s).
C. Contractor's indemnity under this Section shall be without regard to and
without any right to contribution from any insurance maintained by City.
d Should any indemnitee described herein be required to bring an action
against the Contractor to assert its right to defense or indemnification under this
Agreement or under the Contractor's applicable insurance policies required below the
indemnitee shall be entitled to recover reasonable costs and attorney fees incurred in
asserting its right to indemnification or defense but only if a court of competent
jurisdiction determines the Contractor was obligated to defend the claim(s) or was
obligated to indemnify the indemnitee for a claim(s) or any portion(s)thereof.
e In the event of an action filed against City resulting from the City's
performance under this Agreement, the City may elect to represent itself and incur all
costs and expenses of suit.
£ Contractor also waives any and all claims and recourse against the City or
its officers, agents or employees, including the right of contribution for loss or damage to
person or property arising from, growing out of, or in any way connected with or incident
to the performance of this Agreement except "responsibility for his own fraud, for willful
injury to the person or property of another, or for violation of law, whether willful or
negligent" as per 28-2-702, MCA.
9 These obligations shall survive termination of this Agreement and the
services performed hereunder.
h In addition to and independent from the above, Contractor shall at
Contractor's expense secure insurance coverage through an insurance company or
companies duly licensed and authorized to conduct insurance business in Montana which
insures the liabilities and obligations specifically assumed by the Contractor in this
Section. The insurance coverage shall not contain any exclusion for liabilities specifically
assumed by the Contractor in subsection (a) of this Section. The insurance shall cover and
apply to all claims, demands, suits, damages, losses, and expenses that may be asserted or
claimed against, recovered from, or suffered by the City without limit and without regard
to the cause therefore and which is acceptable to the City and Contractor shall fiirnish to
the City an accompanying certificate of insurance and accompanying endorsements in
amounts not less than as shown on Exhibit E.
The amounts of insurance provided shall be exclusive of defense costs. The City of
Bozeman, its officers, agents, and employees, shall be endorsed as an additional or named
insured on a primary non-contributory basis on both the Commercial General and
Automobile Liability policies. The insurance and required endorsements must be in a form
suitable to City and shall include no less than a thirty (30) day notice of cancellation or
non-renewal. The City must approve all insurance coverage and endorsements prior to the
Contractor commencing work. Contractor shall notify City within two (2) business days of
Contractor's receipt of notice that any required insurance coverage will be terminated or
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 13 of 35
Contractor's decision to terminate any required insurance coverage for any reason.
The City must approve all insurance coverage and endorsements prior to the
Contractor commencing work.
28. Taxes: Contractor is obligated to pay all taxes of any kind or nature and make all
appropriate employee withholdings. Contractor understands that all contractors or subcontractors
working on a publicly funded project are required to pay or have withheld from earnings a license
fee of one percent(1%) of the gross contract price if the gross contract price is Five Thousand
Dollars ($5,000) or more. This license fee is paid to the Montana Department of Revenue.
29. Dispute Resolution:
a. Any claim, controversy, or dispute between the parties, their agents,
employees, or representatives shall be resolved first by negotiation between senior-level
personnel from each party duly authorized to execute settlement agreements. Upon
mutual agreement of the parties, the parties may invite an independent, disinterested
mediator to assist in the negotiated settlement discussions.
b. If the parties are unable to resolve the dispute within thirty (30) days from
the date the dispute was first raised, then such dispute shall be resolved in a court of
competent jurisdiction in compliance with the Applicable Law provisions of this
Agreement.
30. Survival: Contractor's indemnification and warranty obligations shall survive the
termination or expiration of this Agreement for the maximum period allowed under applicable
law.
31. Headings: The headings used in this Agreement are for convenience only and are
not be construed as a part of the Agreement or as a limitation on the scope of the particular
paragraphs to which they refer.
32. Waiver: A waiver by City of any default or breach by Contractor of any
covenants, terms, or conditions of this Agreement does not limit City's right to enforce such
covenants, terms, or conditions or to pursue City's rights in the event of any subsequent default
or breach.
33. Severability: If any portion of this Agreement is held to be void or unenforceable,
the balance thereof shall continue in effect.
34. Applicable Law: The parties agree that this Agreement is governed in all respects
by the laws of the State of Montana.
35. Binding Effect: This Agreement is binding upon and inures to the benefit of the
heirs, legal representatives, successors, and assigns of the parties.
36. Amendments: This Agreement may not be modified, amended, or changed in any
respect except by a written document signed by all parties.
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 14 of 35
37. No Third-Party Beneficiary: This Agreement is for the exclusive benefit of the
parties, does not constitute a third-party beneficiary agreement, and may not be relied upon or
enforced by a third party.
38. Counterparts: This Agreement may be executed in counterparts, which together
constitute one instrument.
39. Assignment: Contractor may not assign this Agreement in whole or in part
without the prior written consent of the City. No assignment will relieve Contractor of its
responsibility for the performance of the Agreement and the completion of the Construction
Project. Contractor may not assign to any third party other than Contractor's subcontractors on
the Construction Project, the right to receive monies due from City without the prior written
consent of City.
40. Authority: Each party represents that it has full power and authority to enter into
and perform this Agreement and the person signing this Agreement on behalf of each party has
been properly authorized and empowered to sign this Agreement.
41. Independent Contractor: The parties agree and acknowledge that in the
performance of this Agreement and the completion of the Construction Project, Contractor shall
render services as an independent contractor and not as the agent, representative, subcontractor,
or employee of the City. The parties further agree that all individuals and companies retained by
Contractor at all times will be considered the agents, employees, or independent contractors of
Contractor and at no time will they be the employees, agents, or representatives of the City.
42. Agreement Documents: All work on the Construction Project shall be
performed by Contractor in accordance with all of the terms and conditions of this Agreement
and are incorporated herein by this reference:
Exhibit A: N/A
Exhibit B: Contractor's submitted Bid Form
Exhibit C: Compensation Schedule
Exhibit D: Change of Work Specifications
Exhibit E: Required Insurance Coverage
Exhibit F: Required Bonds
Exhibit G: Plans and Specifications
43. Integration: This Agreement and all Exhibits attached hereto constitute the entire
agreement of the parties. Covenants or representations not contained therein or made a part
thereof by reference, are not binding upon the parties. There are no understandings between the
parties other than as set forth in this Agreement. All communications, either verbal or written,
made prior to the date of this Agreement are hereby abrogated and withdrawn unless specifically
made a part of this Agreement by reference.
***END OF AGREEMENT EXCEPT FOR SIGNATURES"*
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Page 15 of 35
IN WITNESS WHEREOF, Contractor and City have caused this Agreement to be
executed, effective on the date written above, and intend to be legally bound thereby.
CITY OF BOZEMAN, MONTANA CONTRACTOR
—lid ' -� Dafi ' ij Date: l v,(`
�y
By: Andrea Surratt, City Manager By: (Signature)
(Printed Name)
(Title)
APP V FORM (§18-2-406, MCA):
Greg Sullivan, City Attorney
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page Xcf 35
it
EXHIBIT A -NOT APPLICABLE
Notice of Award
(for advertised competitively bid contracts only)
Dated:
TO:
ADDRESS:
PROJECT:
CONTRACT FOR:
You are notified that your Bid opened on ,for the above Contract has been considered. You are the
apparent Successful Bidder and have been awarded a Contract for the: Project.
The Contract Price of your Contract is: ($,000.00).
Five(5)copies of Contract Documents(except Drawings)accompany this Notice of Award.
You must comply with the following conditions precedent within fifteen (15)days of the date of this Notice of Award,
that is, by
1. You must deliver to the OWNER Five(5)fully executed counterparts of the Agreement including all the
Contract Documents and Drawings. Executed copies will be distributed as follows: City Clerk; Facilities;
Parks;Architect; Contractor.
2. You must deliver with the executed Construction Agreement the Contract Security(Bonds)as specified in
the Instruction to Bidders.
3. You must deliver with the executed Construction Agreement the Certificates of Insurance as specified in
the Agreement.
Failure to comply with these conditions within the time specified will entitle OWNER to consider your Bid
abandoned, to annul this Notice of Award, and to declare your Bid Security forfeited.
Within ten (10)days after you comply with these conditions, OWNER will return to you two fully signed counterpart
of the Agreement with the Contract Documents attached.
CITY OF BOZEMAN, MONTANA ATTEST:
BY: BY:
(CITY MANAGER)
(CITY CLERK)
DATE:
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 17 of 35
EXHIBIT B - Contractor's Bid Form
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 18 of 35
May 11,2018
ReldTurif
A Tarkett Sports Company
BOZEMAN
SPORTS PARKS
FOUNOA710N
PRICING PROPOSAL
FieldTurf is pleased to offer to supply and install the following high performance infilled grass surface.
Field Name: Bozeman Sports Parks
Turf System: FieldTurf Vertex Prime FTVTP-50
Square Footage: 198,000 sq
Field Markings: Soccer and Lacrosse
Price: $3.85/sf
Field Groomer $5,100.00
Bonds $11,923.66
Total Price $779,323.66
Alternate#1: Construct dynamic base under FieldTurf system(see below scope of work)
Square Footage: 198,000 sgft
Price: $3.60/sf
Bonds $11,084.21
Total Price $724,457.93
Relffurf 744S Cote-de-Liesse Road Suite 200,Montreal,QC,Canada H4T 1G2•Toll Free:1-800-724-2969
A TxAait%ptlt tc CamP�"1
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 19 of 35
Alternate#2: Complete"Mass Grading"for FieldTurf Limits(see below scope of work)
Square Footage: 198,000 sgft
Price: $0.36/sf
Bonds $1,100.67
Total Price $71,938.65
PRODUCT DETAILS
FieldTurf,the worldwide leader in artificial turf,is pleased to offer the FieldTurf Vertex Prime 2",with
the following product characteristics:
Pile Height: 2"
Infill Weight: 6.25lbs
Pile Weight: 39 oz
Total System Weight: 60 oz
The FieldTurf Quality Guarantee
To achieve unmatched quality and level of performance,we have invested heavily in modernizing our
plants with the latest fiber manufacturing,coating and tufting technologies along with top
manufacturing talent,and specialized installation equipment.Our dedicated CAD-based design
department supports customization for each client,and our experts ensure timely delivery and
installation on every project.
The world leader in artificial turf innovation is ISO 9001,ISO 14001 and OHSAS 18001 certified for its
leadership in quality,environment and safety management systems.FieldTurf's Calhoun facility
represents the only artificial turf manufacturing operation in North America to have received these
ISO certifications.
FieldTurf has taken the necessary steps to ensure that your project will run smoothly and that the
quality promised will be the quality delivered.
FieldTurf Price Includes:
a) Infill recipe for 2"is 3.65 Ibs silica sand/2.6 Ibs coated cryogenic rubber
b) Installation of the artificial in-filled grass surface upon a suitable base;
c) An 8 year 3rd party pre-paid insured warranty on the FieldTurf artificial grass surface
d) Inlaid markings and logos as indicated above
e) 1 field Groomer
7445 Cote-de-Liesse Road Suite 200,Montreal,QC,Canada H4T 1G2•Toll Free:1-800-724-2969
A TmWt SpoOt C&mp4ny
CONSTRUCTION AGREEMENT with FIELDTURFO for SPORTS PARK
Version 12 14 15 Page 20 of 35
i
l
0 a 0 ►
Alternate#1 Price Includes:
a) Mobilization
b) Management of our work
c) Proof-roll subgrade with loaded end dump trailer;soft,rutting or pumping areas to be
rejected
d) Accept non-yielding,stabilized and compacted subgrade at+/-.1'from required elevation
e) Consultation with Project Engineer to assist with design
f) Furnish and install 10"-12"perforated HDPE pipe along perimeter of field
g) Connect to existing storm structure within 50 LF of field
h) Furnish and install 1"x12"flat tile at 30'O.C.
a. Gravity feed into 12"collector
i) Furnish and install 4 oz.geotextile fabric on subgrade
j) Grade for new concrete curb installation
k) Furnish&install 6"x12"concrete curb around perimeter of field
1) Backfill curb
m) Furnish&install 2"x4"treated wood nailer board onto concrete curb
n) Furnish&install 4"crushed permeable base rock
o) Furnish&install 2"crushed permeable finish rock
p) Fine grade field to Fieldturf tolerances
q) Demobilization
Alternate#2 Price Includes:
a) Mobilization
b) Survey and Layout of our work
c) Furnish soil erosion measures/rock entrance
d) Cut 12"of existing topsoil and stockpile onsite
a. No haul off of material included
e) Lasergrade and compact subgrade
Price does not Include:
a) Montana sales tax
b) Design services and construction documentation,including,but not limited to:conceptual
drawings/preliminary design;construction drawings;storm water management;submittal.
reviews and processing;architectural/engineering inspections;soil borings;professional
survey;and as-built drawings.
c) Permits/fees
d) Testing
e) Removal or relocation of existing utilities
f) Soil corrections or soil stabilization
Flelffurf 7445 Cote-de-Liesse Road Suite 200,Montreal,QC,Canada H4T 1G2•Toll Free:1-500-724-2969
A fait.tt Speats C mps-y
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 1415 Page 21 of 35
g) Import of granular fill other than permeable rock section for FieldTurf system
h) Hauling offsite of material/topsoil
i) Irrigation,Seeding/sod,Site restoration or any improvements or restoration not listed.
j) Athletic equipment or events
k) Surveying
1) Asphalt paving
m) Any costs associated with necessary changes relating to delineation of the field.
n) The supply of manholes or clean-outs or grates,or supply of the manhole covers.
o) Any alteration or deviation from specifications involving extra costs,which alteration or
deviation will be provided only upon executed change orders,and will become an extra charge
over and above the offered price.
p) Site security.
q) Small vehicle to tow FieldTurf maintenance equipment.
r) All applicable taxes
The price is valid for a period of 90 days.The price is subject to increase if affected by an increase in
raw materials,freight or other manufacturing costs,a tax increase,new taxes,levies or any new
legally binding imposition affecting the transaction.
Please feel free to reach out to any member of our project team with questions about our offer:
Sacha De Rubeis Jed Easterbrook
Project Manager Director of Sales—Rocky Mountain Region
514-375-3579 303-775-6773
Sacha.DeRubeisGReldturf.com Jed.Easterbrook@fieldturf.com
Thank you again for your interest In FieldTurf,we look forward to working with you.
Per
Marie-Christine Raymond,Director of Operations
FieldTurf USA,Inc.
Relffurf 7445 Cote-de-Liesse Road Suite 200,Montreal,QC,Canada 114T 162•Toll Free:1-500-724-2969
A tartish Sport€Comp4q
CONSTRUCTION AGREEMENT with FIELDTURFO for SPORTS PARK
Version 12 14 15 Page 22 of 35
Conditions
Notwithstanding any other document or agreement entered into by FieldTurf in connection with the
supply and installation only of its product pursuant to the present bid proposal,the following shall
apply:
a) This bid proposal and its acceptance is subject to strikes,accidents,delays beyond our control
and force majeure;
b) Final payment shall be upon the substantial completion of FieldTurf's obligations;
c) Accounts overdue beyond 30 days of invoice date will be charged at an interest rate of 10%
per annum.
d) FieldTurf requires a minimum of 21 days after receiving final approvals on shop drawings to
manufacture,coordinate delivery and schedule arrival of installation crew.Under typical field
size and scenario,FieldTurf further requires 28 days per field to install the Product subject to
weather and force majeure.
e) FieldTurf requires a suitable staging area. Staging area must be square footage of field x 0.12,
have a minimum access of 15 feet wide by 15 feet high,and,no more than 100ft from the site.
A 25 foot wide by 25 foot long hard or paved clean surface area located within 50 feet of the
playing surface shall be provided for purposes of proper mixing of infill material.Access to any
field will include suitable bridging over curbs from the staging area to permit suitable access to
the field by low clearance vehicles.
f) This proposal is based on a single mobilization. If the site is not ready and additional
mobilizations are necessary,additional charges will apply.
g) FieldTurf shall be accountable for its negligence but shall not be bound by any penalty clauses.
h) FieldTurf shall be entitled to recover all costs and expenses,including attorney fees,
associated with collection procedures in the event that FieldTurf pursues collection of
payment of any past due invoice.
7445 Cote-de-Liesse Road Suite 200,Montreal,QC,Canada H4T 1G2•Toll Free:1-800-724-2969
A T44*lt 5p,ts Camp of
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 23 of 35
i
EXHIBIT B - Contractor's Bid Form (contd)
NON-DISCRIMINATION AFFIRMATION FORM
FieldTurf USA Inc [name of entity submitting]hereby affirms it will not discriminate
on the basis of race, color,religion,creed,sex, age,marital status,national origin,or because
of actual or perceived sexual orientation, gender identity or disability in the performance of
work performed for the city of Bozeman,if contract is awarded to it,and also recognizes the
eventual contract,if awarded,will contain a provision prohibiting discrimination as described
above and that this prohibition shall apply to the hiring and treatment of the
FieldTurf USA Inc - [iaine of entity submitting]employees and to all subcontracts it
enters into in performance of the agreement with the city of Bozeman.
Signature of Bidder:
Person authorized to sign on lalf. e bidder
CONSTRUCTION AGREEMENT with FIELDTURF@ for SPORTS PARK
Version 12 14 15 Page 24 of 35
EXHIBIT C
Compensation Schedule
Contractor shall not demand or be entitled to receive payment for any work on the
Construction Project, in whole or in part, except in the manner set forth herein.
Monthly Progress Payments
A. After the commencement of work on the Construction Project, the Contractor may
request monthly progress payments by submitting an Application for Payment to the City's
Representative during each successive calendar month, with a copy to the project architect or
engineer. The Application for Payment must be based upon the actual or estimated percentage of
work completed and materials supplied on the Construction Project prior to the date of the
Application and shall be filled out and signed by the Contractor on a form provided by the City.
Contractor shall attach all supporting documentation to the Application, including certified
payroll records and receipts,to verify that the work claimed in the Application has been
completed. Only one Application for Payment may be submitted within a calendar month.
R Beginning with the second Application for Payment, each Application shall also
include an affidavit signed by the Contractor stating that all previous monthly progress payments
received have been applied on account to discharge Contractor's obligations associated with the
prior Applications for Payment.
C City and its architect or engineer shall promptly review all Applications for
Payment and, within twenty-one (21) days after receipt of each Application, determine whether a
progress payment should be disapproved in whole or in part. An Application for Payment is
considered to have been received when it is submitted to City's Representative and is considered
approved unless prior to the expiration of the 21-day period the City or its architect or engineer
provides the Contractor with a written statement containing specific items that are being
disapproved. A progress payment or any portion may be disapproved upon a claim of. (1)
unsatisfactory job progress; (2) failure to remedy defective construction work or materials; (3)
disputed work or materials; (4) failure to comply with material provisions of this Agreement,
drawings,plans, specifications for the Construction Project, or other required documents,
including but not limited to, payroll certifications, insurance coverage,bonding, lien releases,
warranties, material certifications, and test data; (5) failure of Contractor to make timely
payment for claims including, but not limited to claims for labor, equipment, materials,
subcontracts,taxes, fees, professional services, rent, and royalties; (6) damages to the City; (7)
the existence of reasonable evidence that the Agreement cannot be completed for the unpaid
balance of the Agreement's Compensation; and (8) Contractor's non-compliance with applicable
federal, state, and local laws, mules, and ordinances.
A The City will furnish Contractor a written statement specifying a reason for
disapproval that is listed in Section C above for which approval of the Application for Payment or
a portion thereof is being withheld. If the City disapproves only a portion of an Application for
Payment, the remainder of the Application for Payment is considered approved.
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 25 of 35
C
E. If the City approves a monthly progress payment, the City shall withhold the five
percent (5%) Retainage Amount from the total payment requested in the Application for
Payment and may withhold an amount that is sufficient to pay the direct expenses that the City
may reasonably expect will be necessary to correct any claim based on the eight(8) items set out
in Section C above. City shall tender the balance of the approved monthly progress payment to
Contractor within seven (7) days following the approval.
R Contractor understands that the Montana Public Contractors' Gross Receipts Tax
requires all contractors or subcontractors working on a publicly funded project to pay or have
withheld from earnings one percent (1%) of the gross contract price if the public contract price,
including subcontracts attached thereto, is Five Thousand Dollars ($5,000) or more. If required,
the City will withhold this tax from any payment made to Contractor and will remit the amount
withheld to the Montana Department of Revenue. Contractor must withhold the tax from
payments made to subcontractors by Contractor.
G. City's approval of any progress payment shall not operate as City's acceptance of
any portion of the Construction Project as complete or free of defects or nonconformities, nor
shall it operate as a waiver of Contractor's obligations under the Agreement including, but not
limited to, Contractor's testing and warranty obligations.
Final Payment
A Upon completion of the Construction Project, Contractor shall submit a final
Application for Payment to the City's Representative seeking payment of the remaining balance
of Contractor's compensation, including all retainage amounts. Contractor shall attach all
supporting documentation and receipts to the final Application for Payment to verify that the
Construction Project has been fully and finally completed in compliance with all terms and
conditions of the Agreement, including complete and legally effective releases or waivers of all
liens or encumbrances that have been filed against the Construction Project, and a consent from
all of Contractor's sureties to final payment. In addition, Contractor shall include an affidavit
signed by the Contractor stating that all previous monthly progress payments received have been
applied on account to discharge Contractor's obligations associated with the Construction Project
and that the prior Applications for Payment and all claims asserted by any person arising from or
related to the Construction Project have been settled or satisfied. In the event any claims have not
been settled or satisfied, the Affidavit shall contain a complete listing of such claims, the name
and address of each person making a claim, the facts and circumstances surrounding each claim,
the amount of each claim, and the efforts made to date by Contractor to resolve, settle or satisfy
each claim.
R City and its architect or engineer shall promptly review the final Application for
Payment and, within twenty-one (21) days after receipt of the request, determine whether it
should be disapproved in whole or in part. The final Application for Payment is considered to
have been received when it is submitted to City's Representative and is considered approved
unless the City's Representative provides the Contractor with a written statement containing
specific items that are being disapproved prior to the expiration of the 21-day period. A final
payment or any portion may be disapproved upon a claim of. (1) unsatisfactory job progress; (2)
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 1415 Page 26 of 35
i
after City's final inspection of the Construction Project, Contractor has not completed all punch
list items and failed to remedy defective construction work or materials; (3) disputed work or
materials; (4) failure to comply with material provisions of this Agreement, drawings,plans,
specifications for the Construction Project, or other required documents including, but not
limited to, payroll certifications, insurance coverage, bonding, lien releases, warranties, material
certifications, and test data; (5) failure of Contractor to make timely payment for claims
including, but not limited to, claims for labor, equipment, materials, subcontracts, taxes, fees,
professional services, rent, and royalties; (6) claims have been brought or liens have been filed
against Contractor or the City related to the Construction Project, or any such claims have not
been properly documented in Contractor's Affidavit; (7) damage to the City; (8) Contractor has
not delivered all maintenance and operating instructions,marked-up record documents, and any
other documents relating to the Construction Project as required by City; and (9)the Contractor
is not in compliance with applicable federal, state, and local laws, rules, and ordinances and has
not remedied the noncompliance.
C_ The City's Representative will furnish Contractor a written statement specifying a
reason for disapproval that is listed in Section B above for which approval of the final
Application for Payment or a portion thereof is being withheld. If the City disapproves only a
portion of an Application for Payment,the remainder of the Application for Payment is
considered approved.
D. Final payment is due and payable within fourteen (14) days of the City's
Representative's approval, but City may withhold an amount that is sufficient to pay the direct
expenses that the City may reasonably expect will be necessary to correct any claim based on the
nine (9) items set out in Section B above and any tax withholding required by law.
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 27 of 35
EXHIBIT D
Change of Work Specifications
A. City may, at any time or from time to time, order changes, additions, deletions, or
revisions to the work on the Construction Project by submitting a written Change Order to
Contractor on a form as provided for by the City. Upon receipt of any Change Order, Contractor
shall comply with the terms of the changed work as reflected in the Change Order.
B. City and Contractor shall negotiate in good faith for an agreement as to any
increase or decrease in the Contractor's compensation that results from any Change Order. The
increased or decreased Contractor's compensation shall be set forth in the Change Order and
both the City and the Contractor shall sign the Change Order as an indication of their respective
acceptance of the changes and modifications to the Agreement. In the event the City and
Contractor are unable to agree upon the increase or decrease in Contractor's compensation
resulting from any Change Order, such increase or decrease shall be determined as follows:
1. increases to Contractor's compensation shall be calculated as follows and shall be
evidenced by Contractor's submission to the City of its actual supporting documentation
including time slips/cards, invoices, and receipts:
a. by unit prices otherwise set forth in the Agreement or subsequently agreed
upon;
b. by an agreed upon lump sum; or
C. by the cost of the work and an agreed upon mark-up for Contractor's
overhead and profit, with the costs of the work determined as follows:
0 Contractor's actual, direct payroll expenses for the cost of labor.
Payroll expenses shall only include actual gross wages paid, without any
deductions, withholding, or overhead. The agreed upon mark-up fee shall
cover Contractor's liability insurance, workers' compensation, and Social
Security taxes applicable to said wages, Contractor's reasonable profit, the
costs for the use of small tools and equipment not otherwise classified
under heavy equipment use, and Contractor's general overhead expenses.
lot Contractor's actual cost of materials, including actual
transportation costs, for all materials supplied by Contractor.
fin) Costs for the use of heavy equipment and the transportation of the
same. Such costs shall be the actual rental fees incurred for the use of the
heavy equipment and the actual costs of transporting such heavy equipment
to and from the site of the Construction Project.
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 28 of 35
2. Decreases to Contractor's compensation shall be determined by the City's good
faith estimate. If Contractor disagrees with such good faith estimate, Contractor can avail
itself of the Dispute Resolution provisions set forth in the Agreement.
C. Except for minor modifications in the work not involving an increase of costs or
Contractor's compensation and not inconsistent with the purposes of the work required by the
Agreement, and except in an emergency situation which endangers life or property, no change to
the work requirements shall be made unless pursuant to a written Change Order duly executed.
D. Contractor shall not be entitled to any increase in the Contractor's compensation
or the extension of any deadlines set forth in Construction Schedule with respect to any work
performed by Contractor that is not required by the terms and conditions of the Agreement and is
not contained in a duly executed Change Order.
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 29 of 35
I
EXHIBIT E
Required Insurance Coverage
Contractor shall purchase and maintain insurance coverage as set forth below. The
insurance policy must protect, defend, and indemnify the City, its employees, officers,
and agents and must endorse the City, its employees, officers and agents as an additional
insureds and be written on a"primary—noncontributory basis."Each coverage shall be
obtained fiom an insurance company that is duly licensed and authorized to transact
insurance business and write insurance within the state of Montana, with a minimum of
"A.M. Best Rating" of A-, VI, as will protect the Contractor,the various acts of
subcontractors,the City and its officers, employees, agents, and representatives from claims
for bodily injury and/or property damage which may arise from operations and completed
operations under this Agreement. All insurance coverage shall remain in effect throughout
the life of this Agreement and for a minimum of one (1) year following the date of expiration
of Contractor's warranties. All insurance policies must contain a provision or endorsement
that the coverage afforded will not be canceled, materially changed, or renewal refused until
at least forty-five (45) days prior written notice has been given to Contractor, City, and all
other additional insured to whom a certificate of insurance has been issued.
Required Insurance Coverage:
1. Commercial General Liability $1,500,000 per occurrence
(bodily injury and property damage) $3,000,000 aggregate
2. Products and Completed Operations $3,000,000
3. Automobile Liability $1,500,000 per accident
(all owned,hired,non-owned)
4. Workers'Compensation Not less than statutory limits
5. Employers'Liability $1,000,000
6. Professional Liability(E&O) $1,500,000
(only if applicable)
7. Installation Floater/Property Insurance: Equal to greater of
Contractor's compensation or full replacement(covering all work. buildings, materials and
equipment,whether on site or in transit,loss due to fire, lightening,theft,vandalism, malicious
mischief,earthquake,collapse,debris removal,demolition occasioned by enforcement of laws,water
damage,flood if site within a flood plain,repair or replacement costs,testing and start-up costs)
8. Contractual Liability Insurance $1,000,000 per occurrence
(covering indemnity obligations) $3,000,000 aggregate
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 1415 Page 30 of 35
I
EXHIBIT F
Required Bonds
Contractor shall make, execute,purchase, maintain and deliver to City performance and
payment bonds in an amount at least equal to the Contractor's compensation under this
Agreement, conditioned that the Contractor shall faithfully perform of all of Contractor's
obligations under this Agreement and pay all laborers, mechanics, subcontractors, material
suppliers and all persons who supply the Contractor or Contractor's subcontractors with
provisions,provender, material, or supplies for performing work on the Construction Project.
All bonds must be obtained with a surety company that is duly licensed and authorized to transact
business within the state of Montana and to issue bonds for the limits so required. The surety
company must have a Best's Financial Strength Rating of A, as rated by the A. M. Best Co., or an
equivalent rating from a similar rating service. All bonds must remain in effect throughout the life
of this Agreement and for a minimum of one (1) year following the date of expiration of
Contractor's warranties. A certified copy of the agent's authority to act must accompany all
bonds signed by an agent. If the surety on any bond furnished by Contractor is declared bankrupt
or becomes insolvent or its right to do business within the state of Montana is terminated,
Contractor shall promptly notify City and shall within twenty(20) days after the event giving rise
to such notification, provide another bond with another surety company, both of which shall
comply with all requirements set forth herein.
Bond Types and Amounts:
1. Performance Bond Equal to Contractor's compensation amount
2. Labor and Materials Bond Equal to Contractor's compensation amount
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK-
Version 12 14 15 Page 31 of 35
i
EXHIBIT G
Drawings,Plans and Specifications
The Drawings, Plans and Specifications provided by the City or its architect or
engineer as illustrated below and as described in the Pricing Proposal (Exhibit B):
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 1214 15 Page 32 of 35
uV i
I Ir I m I
I�I 1
I, s
(, m
ScM
b m
m
m
'N
ix 1
1
I �
�11 �
1
_ ....... -- —
--------------------------------
I _
RANDERS MILL ROAD
i
t r
k T f }
1 �
BOZEMAN SPORTS PARK: Kv'�
PHASE 1 SITE IMPROVEMEtlTS h118
SOZEMAN,MONTANA ID O W L
01 DETAILED GRADING PLAN
M6aa01871
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 33 of 35
EXHIBIT H
Association of Educational Purchasing Agencies Invitation for Bid#0 16 — G (AEPA IFA#O 1 6-G)
AEPA FORM B: ACCEPTANCE OF BID AND CONTRACT AWARD
AEPA IFB 4016-G
Athletic Surfaces--Synthetic Turf
NAME OFRIDDER F1P4dTurf USA,Inc.
JNSTRL1CTl0l4S:PART I of this form is to be completed by the Bidder and signed by its Aodwrizcd Rcprcscnts6vc
PART It will be completed by the AEPA -Mc)nbet Agency only upon the oceasiwl of the bid award. Tho completed
clocwmni must Ire scanned to a PDII lonnat and.roved to Folder A,and it completed and signed paper verAnn must be
included to the package, 11'approved by APPA,the bidder is Tequirod to produce a copy of the document for rich or the
AEPA Mcnibcr Agcocy with which it contracts.
PART 1:BIDDER
In compliance with the Invitation For Bid (IFB), the undersigned warrants that 11wc have examined the
Instructions to Bidders,associated documents, and being familiar with all of the conditions surrounding the
proposed projecls,hereby offer and agree to furnish all labor,materials, supplies and equipment incurred in
compliance with all terms,conditions,specifications and amendments associated with this IFB and any written
exceptions to the hid. Signature also certifies understanding and compliant: with the certification
requirements of the Al PA Member Agency's Terms and Conditions and/or Special Terms and Conditions,
The undersigned understands that their competence,ability,capacity and obligations to offer and provide the
proposed tangible ptimmai property,professional services,construction services and other services on be-balf
of the Vendor Partner as well as other factors of interest to the AEPA Member Agency as stated in the
evaluation section,will be a consideration in making the award.
Company Name nowurt USA,Inc, Date
Company Address 7445 Cote-de-l-losse,suite 200 City Montreal state QC zip 'H4T 1 G2
Contact Person Eric Dallero Title CEO
Authorized Signature(ink only) L
Title CEO
Email Address Eiic.DailomOtatkottsoorts.corn Phonc,
PART H: AWARDING MEMBER AGENCY
Your bid response for the above identified bid is hereby accepted- As a Vendor Partner you are now bound to
offer and provide the products and services identified within this IF13,your response and approved by AEPA,
including all tenets,conditions,spccificaUons,cxccpticn15 and aiticiAncrits,As Vendor Palmer,you are hereby
not to commence any billable work or provide any products or services under this contract until an executed
purchase order is received from the AEPA Member Agency or Participating Erifities. The intent of this
contract is to constitute the final and mmplctc agreement between the AEPA Member Agency and Vendor
Partner,and no other agreements, oral or otherwise,regarding the subject tatter of this contract,shall bind
any of the parties hereto. No change or modification of this contract shall be valid unless in writing and signed
by both parties to this contract. If any provision of this contract is deemcd invalid or illegal by any appropriate
court of law,the remainder of this contract shall not be affected therthy. The initial term of this contract shall
he for up to fifteen(15)months and will commence on the date indicated below and continue until February
28, 200 unless terminated,cauncelcid or extended. By mutual written agreement as warranted, the contract
may be extended mouth by month up to six(6)months or for three(3)additional 12-month periods,
Awarding Agency
Agency Executive C—'
Awarded this day of Contract Number
fill 1:
Contract to commence(Member Agency to select):0 of 0 N1
AKPA IFU 00164; Sycillittic Turt Page 4 U38 Due Dote:0CT09F[?7,
Part C:Did Farms
CONSTRUCTION AGREEMENT with FIELDTURF@ for SPORTS PARK
Version 12 14 15 Page 34 of 35
DATE EXTENSION FOR EXHIBIT H
EXTENSION OF AGREEMENT
AEPA BID 4016
Contract EXTENS(ON AGREEMENT made by and between
FieldTurf USA,Inc.(Vendor)
Synthetic Turf
and
Montana Cooperative Services,MT(Member)
The existing Agreement was initially awarded through February 28, 2017 for a 12-month term. The Term of Contract and
Extension in the AEPA Bid provides the Agreement may be extended for three(3)additional 12-month periods by mutual written
agreement through February 28,2020. AEPA has approved this extension and now the Member and the Vendor desire to
extend the Agreement for an additional term to commence February 28,2018. Upon the silmatures of an authorized officer
of the Member and the Vendor,the Agreement is hereby extended.
This extension shall be subject to the same Terms and Conditions as contained in the original AEPA Bid,and subject to the Bylaws,
Policies and Procedures of AEPA in addition to the Member Terms and Conditions.
Member
Authorized Signature J Title Director
Typed Name DavidL.Puyear Date 12-15-17
Vendor
Authorized Signature Title �c_% ri d,tA/r--(`' _
Typed Name l r�.t, r:)n J i r r _ Date k'
The Vendor agrees to provide complete information of any deleted and new products or prices as allowed under headings
(Discontinued Products)and(New Technology and Price Reduction)of the AEPA Bid.
If you as the Vendor do not want to extend contract,please sign below.
Discontinue: We desire to discontinue the contract,effective February 28.
Authorized Signature Title
Typed Name Date
MAILING ADDRESS:
Montana Cooperative Services
P.O.Box 1611* *Preferred Mailing Address,Please use this address if possible
Helena MT 59624
2047 Last Chance Gulch 4312 *Secondary/Physical Address
Helena MT 59601
NOTE:•Phis agreement must be received by the Member on or before January 30,2018
CONSTRUCTION AGREEMENT with FIELDTURF®for SPORTS PARK
Version 12 14 15 Page 35 of 35
IZ H U E3 B Surety 0 +908.903.3485
202B Halls Mill Road,PO Box 1650 F +908.903.3656
Whitehouse Station,NJ 08889-1650
Federal Insurance Company
AIA Document A312T11- 2010 Performance Bond Bond No. 8246-74-03
Any singular reference to Contractor,Surety,Owner or other party shall be considered plural where applicable.
CONTRACTOR SURETY(Name and Principal Place of Business):
(Name,legal status and address): Federal Insurance Company
Fieldturf USA, Inc. 202B Hall's Mill Road
7445 Cote-de-Liesse Road, Suite 200 Whitehouse Station, NJ 08889
Montreal, Quebec, Canada, H4T 1G2 "The liability of the surety under this bond shall not
OWNER extend beyond one year from the final completion and
(Name,legal status and address): acceptance of the work by the owner/obligee and in no way shall
City of Bozeman the surety be liable under any extended warranty provided
P.O. Box 1230 by Fieldturf USA, Inc. or the named Principal on this bond"
Bozeman, MT 59771
CONSTRUCTION CONTRACT
Date: ��� I I t'.�b 19
Amount:$796,396.58 Seven Hundred Ninety Six Thousand Three Hundred Ninety Six Dollars and 58/100
Description(Name and Location): Athletic Surfaces - Synthetic Turf Field Placement, Bozeman, MT, Bozeman
Sports Park, Base Construction
BOND
Date(Not earlier than Construction Contract Date): c- L 1/ I ( I--A0I9
Amount: $796,396.58 Seven Hundred Ninety Six Thousand Three Hundred Ninety Six Dollars and 58/100
Modifications to this Bond: lt7 None ❑ See Page 4
CONTRACTORS AS PRINCIPAL SURETY
Company: (CorporateSeal)
Company: (Corporateseal)
Fieldturf USA, I Federal Ins ance Company
Signature: - Signature:
��,
Name and Title: Attorney-in-Fact Name: Mark W. Edwards, 11
PeaP.(r✓', C?�:O- ` Tvr-asU
Signed and Sealed this day of
(Any additional signatures appear on the last page of this Performance Bond.)
(FOR INFORMATION ONLY—Name,Address and Telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE(Architect,Engineer orotherparty):
McGriff, Seibels &Williams, Inc.
2211 7th Avenue, South
Birmingham,AL 35233
205-252-9871
Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in
AIA DocumentA312""-2010.
Form 15-02-057-FED(Rev.11/16)
1
1. The Contractor and the Surety,jointly and severally,bind themselves,their heirs,executors,administrators,
successors and assigns to the Owner for the performance of the Construction Contract,which is incorporated
herein by reference.
2. If the Contractor performs the Construction Contract,the Surety and the Contractor shall have no obligation
under this Bond,except when applicable to participate in a conference as provided in Section 3.
3. If there is no Owner Default under the Construction Contract,the Surety's obligation under this Bond shall
arise after:
1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring
a Contractor Default.Such notice shall indicate whether the Owner is requesting a conference among the
Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a
conference,the Surety may,within five(5)business days after receipt of the Owner's notice,request such
a conference.If the Surety timely requests a conference,the Owner shall attend.Unless the Owner agrees
otherwise,any conference requested under this Section 3.1 shall be held within ten(10)business days of the
Surety's receipt of the Owner's notice.If the Owner,the Contractor and the Surety agree,the Contractor
shall be allowed a reasonable time to perform the Construction Contract,but such an agreement shall not
waive the Owner's right,if any,subsequently to declare a Contractor Default;
.2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety;
and
.3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the
Construction Contract to the Surety or to a contractor selected to perform the Construction Contract.
4. Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute
a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its
obligations,except to the extent the Surety demonstrates actual prejudice.
5. When the Owner has satisfied the conditions of Section 3,the Surety shall promptly and at the Surety's expense
take one of the following actions:
51 Arrange for the Contractor,with consent of the Owner,to perform and complete the Construction Contract;
5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent
contractors;
5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for
performance and completion of the Construction Contract,arrange for a contract to be prepared for execution
by the Owner and a contractor selected with the Owner's concurrence,to be secured with performance and
payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract,
and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract
Price incurred by the Owner as a result of Contractor Default;or
5.4 Waive its right to perform and complete,arrange for completion,or obtain a new contractor and with reasonable
promptness under the circumstances:
.1 After investigation,determine the amount for which it maybe liable to the Owner and,as soon as practicable
after the amount is determined,make payment to the Owner;or
.2 Deny liability in whole or in part and notify the Owner,citing the reasons for denial.
6. If the Surety does not proceed as provided in Section 5 with reasonable promptness,the Surety shall be deemed
to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the
Surety demanding that the Surety perform its obligations under this Bond,and the Owner shall be entitled to
enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4,and the Owner
refuses the payment or the Surety has denied liability,in whole or in part,without further notice the Owner
shall be entitled to enforce any remedy available to the Owner.
Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in
AIA Document A312 T"'-2010.
Form 15.02.0573•FED(Rev.11/16) 2
7. If the Surety elects to act under Section 5.1,5.2 or 5.3,then the responsibilities of the Surety to the Owner shall not
be greater than those of the Contractor under the Construction Contract,and the responsibilities of the Owner to
the Surety shall not be greater than those of the Owner under the Construction Contract. Subject to commitment
by the Owner to pay the Balance of the Contract Price,the Surety is obligated,without duplication,for
1 the responsibilities ofthe Contractor for correction ofdefectivework and completionofthe Construction Contract;
2 additional legal,design professional and delay costs resulting from the Contractor's Default,and resulting
from the actions or failure to act of the Surety under Section 5;and
3 liquidated damages,or if no liquidated damages are specified in the Construction Contract,actual damages
caused by delayed performance or non-performance of the Contractor.
8. If the Surety elects to act under Section 5.1,5.3 or 5.4,the Surety's liability is limited to the amount of this Bond.
9. The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to
the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account
of any such unrelated obligations.No right of action shall accrue on this Bond to any person or entity other
than the Owner or its heirs,executors,administrators successors and assigns.
10. The surety hereby waives notice of any change,including changes of time,to the Construction Contract or to
related subcontracts,purchase orders and other obligations.
11. Any proceeding,legal or equitable,under this Bond may be instituted in any court of competent jurisdiction
in the location in which the work or part of the work is located and shall be instituted within two years after
a declaration of Contractor Default or within two years after the Contractor ceased working or within two
years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If
the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to
sureties as a defense in the jurisdiction of the suit shall be applicable.
12. Notice to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown on the
page on which their signature appears.
13. When this Bond has been furnished to comply with a statutory or other legal requirement in the location
where the construction was to be performed,any provision in this Bond conflicting with said statutory or legal
requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal
requirements shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall be
construed as a statutory bond and not as a common law bond.
14. DEFINITIONS
14.1 Balance of the Contract Price:The total amount payable by the Owner to the Contractor under the Construction
Contract after all proper adjustments have been made,including allowance to the Contractor of any amounts received or
to be received by the owner in settlement ofinsurance or other claims for damages to which the Contractor is entitled,
reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract.
14.2Construction Contract: The agreement between the Owner and the Contractor identified on the cover
page,including all Contract Documents and changes made to the agreement and the Contract Documents.
14.3Contractor Default: Failure of the Contractor, which has not been remedied nor waived, to perform or
otherwise to comply with the term of the Construction Contract.
14.40wner Default: Failure of the Owner, which has not been remedied or waived, to pay the Contractor as
required under the Construction Contract or to perform and complete or comply with the other material
terms of the Construction Contract.
14.5.Contract Documents:All the documents that comprise the agreement between the Owner and Contractor.
15. If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this
Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor.
Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in
ALA Document A312 T"'-2010.
Form 15-02.0573-FED(Rev.11/16) 3
16 MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties,other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporateseal)
Federal Insurance Company
Signature• Signature:
Name and Title: Name and Title:
Address: Address:
Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in
AIA Document A312 T"-2010.
Corm 15-02-0573-FED(Rev.11/16) 4
CHUBB'
Power of Attorney
Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company
Know All by These Presents,That FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY,a New York corporation,and PACIFIC
INDEMNITY COMPANY,a Wisconsin corporation,do each hereby constitute and appoint Anna Childress, Mark W. Edwards, II,Alisa B. Ferris, Robert R. Freel,
Ronald B.Giadrosich,Richard H.Mitchell,William M.Smith and Jeffrey M.Wilson of Birmingham,Alabama;Robert Read Davis of Atlanta,Georgia;
Richard E.Daniels of Pensacola,Florida;Robert M.Verdin of Metairie,Louisiana---------------------------------------------------------------------------------------
each as their true and lawful Attorney-in-Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety
thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed in the course of business,and any
instruments amending or altering the same,and consents to the modification or alteration of any instrument referred to in said bonds or obligations.
In Witness Whereof,said FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY have each executed and attested these
presents and affixed their corporate seals on this 141"day ofJuly,2017.
Qhimux� &:t�— ,A d-r_�
Dawn M.Chloros.Assistant Secretary Stephen M.Ilancy.Vice Pixsident
STATE OF NEW JERSEY
County of Hunterdon SS.
On this 14'"day of July,2017 before me,a Notary Public of New Jersey,personally came Dawn M.Chloros,to me known to be Assistant Secretary of FEDERAL INSURANCE
COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY,the companies which executed the foregoing Power of Attorney,and the said Dawn M.
Chloros,being by me duly sworn,did depose and say that she is Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC
INDEMNITY COMPANY and knows the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by
authority of said Companies;and that she signed said Power of Attorney as Assistant Secretary of said Companies by like authority;and that she is acquainted with Stephen M.
Haney,and knows him to be Vice President of said Companies;and that the signature of Stephen M.Haney,subscribed to said Power of Attorney is in the genuine handwriting of
Stephen M.Haney,and was thereto subscribed by authority of said Companies and in deponent's presence.
Notarial Seal +o
,� KATNERINE J.ADEtJ1M
NOTARY PUBLIC OF NEW JERSEY
m No.2310585
4PUBl1 COm01I661011 Exp4e6 July 16,2019 Notary PuMIc
JER°�
CERTIFICATION
Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016:
"RESOLVED,that the following authorizations relate to the execution,for and on behalfof the Company,of bonds,undertakings,recognizances,contracts and other written commitments of the company
entered into in the ordinary course of business(each a"Written Commitment"):
(1) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized to execute any Written Commitment for and on behalfof the Company,under the
seal of the Company or otherwise.
(2) Each duly appointed attorney-in-fact of the Company is hereby authorized to execute any Written Commitment for and on behalf of the Company,under the seal of the Company or
otherwise,to the extent that such action is authorized by the grant of powers provided for in such person's written appointment as such attorney-m-fact.
(3) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalfofthe Company,to appoint in writing any person the attorney-
in-fact of the Company with full power and authority to execute,for and on behalfof the Company,under the seal of the Company or otherwise,such Written Commitments of the
Company as may be specified in such written appointment,which specification may be by general type or class of Written Commitments or by specification of one or more particular
Written Commitments.
(4) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalfof the Company,to delegate in writing to any other officer of the
Company the authority to execute,for and on behalf of the Company,under the Company's seal or otherwise,such Written Commitments of the Company as are specified in such
written delegation,which specification may be by general type or class of Written Commitments or by specification ofone or more particular Written Commitments.
(5) The signature ofany officer or other person executing any Written Commitment or appointment or delegation pursuant to this Resolution,and the seal of the Company,may be affixed by
facsimile on such Written Commitment or written appointment or delegation.
FURTHER RESOLVED,that the foregoing Resolution shall not be deemed to be an exclusive statement of the powers and authority of officers,employees and other persons to act for and on behalfof
the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or authority otherwise validly granted or vested."
I,Dawn M.Chloros,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY(the"Companies')do hereby
certify that
(i) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and in frill force and effect,
(ff) the Companies are duly licensed and authorized to transact surety business in all 50 of the United States of America and the District of Columbia and are
authorized by the U.S.Treasury Department;further,Federal and Vigilant are licensed in the U.S.Virgin Islands,and Federal is licensed in Guam,Puerto Rico,
and each of the Provinces of Canada except Prince Edward Island;and
(iii) the foregoing Power of Attorney is true,correct and in full force and effect.
Given under my hand and seals of said Companies at Whitehouse Station,M,this
Dawn M.Chlora;,Assistant Secretae
IN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM,VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER,PLEASE CONTACT US AT-
Telephone(908)903-3493 Fax(908)903-3656 e-mail:surety@chubb.com
Form 15-10-02258-U GEN CONSENT(rev.12-16)
H U E3 E-3 Surety 0 +908.903.3485
202B Halls Mill Road,PO Box 1650 F +908.903.3656
Whitehouse Station,NJ 08889-1650
Federal Insurance Company
AIA Document A312111- 2010 Payment Bond
Bond No. 8246-74-03
Any singular reference to Contractor,Surety,Owner or other party shall be considered plural where applicable.
CONTRACTOR SURETY
(Name,legal status and address): (Name, legal status and principal place of business):
Fieldturf USA, Inc. Federal Insurance Company
7445 Cote-de-Liesse Road, Suite 200 202B Hall's Mill Road
Montreal, Quebec, Canada, H4T 1G2 Whitehouse Station, NJ 08889
OWNER "The liability of the surety under this bond shall not
(Name,legal status and address): extend beyond one year from the final completion and
City of Bozeman acceptance of the work by the owner/obligee and in no way shall
P.O. Box 1230 the surety be liable under any extended warranty provided
Bozeman, MT 59771 by Fieldturf USA, Inc. or the named Principal on this bond"
CONSTRUCTION CONTRACT
Date: Jll vu�- I 1 I �D l Ig
Amount:$796,396.58 Seven Hundred Ninety Six Thousand Three Hundred Ninety Six Dollars and 58/100
Description(Name and Location): Athletic Surfaces- Synthetic Turf Field Placement, Bozeman, MT,
Bozeman Sports Park, Base Construction
BOND
Date(Not earlier than Construction Contract
Date): Juvv. 1 I l ZD 1 q
Amount: $796,396.58 Seven Hundred Ninety Six Thousand Three Hundred Ninety Six Dollars and 58/100
Modifications to this Bond: ❑ None )L] See Page 4
CONTRACTORS AS PRINCIPAL SURETY
Company: (CorporateSea Company: (CorporateSeal)
Fieldturf USA, c. Federal Insurance Compa
Signature: Signature: gd", . Fjxl� IZ/
Name and Title: Attorney-in-Fact Name: Mark W. Edwards, III
Signed and Sealed this day of
(Any additional signatures appear on the last page of this Performance Bond.)
(FOR INFORMATION ONLY—Name,Address and Telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE(Architect,Engineerorotherparty)
McGriff, Seibels &Williams, Inc.
2211 7th Avenue, South
Birmingham,AL 35233
205-252-9871
Printed in cooperation with theAmerican Institute ofArchitects(AIA)by Chubb.The language in this document conforms to the language used in AIA
Document A3127dt-2010.
Form 15-02-0574•FED(Rev.11/16) 1
I The Contractor and the Surety,jointly and severally,bind themselves,their heirs,executors,administrators,
successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the
performance of the Construction Contract,which is incorporated herein by reference,subject to the following
terms.
2 If the Contractor promptly makes payment of all sums due to Claimants,and defends,indemnifies and holds
harmless the Owner from claims,demands,liens or suits by any person or entity seeking payment for labor,
materials or equipment furnished for use in the performance of the Construction Contract, then the Surety
and the Contractor shall have no obligation under this Bond.
3. If there is no Owner Default under the Construction Contract,the Surety's obligation to the Owner under this
Bond shall arise after the Owner has promptly notified the Contractor and the Surety(at the address described in
Section 13)of claims,demands,liens or suits against the Owner or the Owner's property by any person or entity
seeking payment for labor,materials or equipment furnished for use in the performance of the Construction
Contract and tendered defense of such claims,demands,liens or suits to the Contractor and the Surety.
4 When the Owner has satisfied the conditions in Section 3,the Surety shall promptly and at the Surety's expense
defend,indemnify and hold harmless the Owner against a duly tendered claim,demand,lien or suit.
5. The Surety's obligations to a Claimant under this Bond shall arise after the following:
51 Claimants,who do not have a direct contract with the Contractor,
.1 have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the
amount claimed and the name of the party to whom the materials were, or equipment was, furnished or
supplied or for whom the labor was done or performed,within ninety(90)days after having last performed
labor or last furnished materials or equipment included in the Claim;and
.2 have sent a Claim to the Surety(at the address described in Section 13).
5.2 Claimants,who are employed by or have a direct contract with the Contractor,have sent a Claim to the Surety
(at the address described in Section 13).
& If a notice of non-payment required by Section 5.1.1 is given by the Owner to the Contractor,that is sufficient
to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1.
7. When a Claimant has satisfied the conditions of Sections 5.1 or 5.2,whichever is applicable,the Surety shall
promptly and at the Surety's expense take the following actions:
7.1 Send an answer to the Claimant,with a copy to the Owner,within sixty(60)days after receipt of the Claim,
stating the amounts that are undisputed and the basis for challenging any amounts that are disputed;and
7.2 Pay or arrange for payment of any undisputed amounts.
7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute
a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed
amounts for which the Surety and Claimant have reached agreement.If,however,the Surety fails to discharge
its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable
attorney's fees the CIaimant incurs thereafter to recover any sums found to be due and owing the Claimant.
8 The Surety's total obligation shall not exceed the amount of this Bond,plus the amount of reasonable attorney's
fees provided under Section 7.3,and the amount of this Bond shall be credited for any payments made in good
faith by the Surety.
9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the
performance of the Construction Contract and to satisfy claims,if any,under any construction performance
bond.By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by
the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the
Contractor and the Surety under this Bond,subject to the Owner's priority to use the funds for the completion
of the work.
Printed in cooperation with theAmerican Institute of Architects(ALA)by Chubb. The language in this document conforms to the language used in
AIA Documen t A312 Tu-2010.
Form 15.02.0574•FED(Rev.11/16) 2
10. The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are
unrelated to the Construction Contract.The Owner shall not be liable for the payment of any costs or expenses
of any Claimant under this Bond,and shall have under this Bond no obligations to make payments to,or give
notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond.
It The Surety hereby waives notice of any change,including changes of time,to the Construction Contract or to
related subcontracts,purchase orders and other obligations.
i2 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent
jurisdiction in the state in which the project that is subject of the Construction Contract is located or after
the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to
Section 5.1.2 or 5.2,or(2)on which the last labor or service was performed by anyone or the last materials or
equipment were furnished by anyone under the Construction Contract,whichever of(1)or(2)first occurs.If
the provisions of this Paragraph are void or prohibited by law,the minimum period of limitation available to
sureties as a defense in the jurisdiction of the suit shall be applicable.
11 Notice and Claims to the Surety,the Owner or the Contractor shall be mailed or delivered to the address shown
on the page which their signature appears.Actual receipt of notice or Claims,however accomplished, shall
be sufficient compliance as of the date received.
14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location
where the construction was to be performed, any provision in this Bond conflicting with said statutory or
legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other
legal requirement shall be deemed incorporated herein.When so furnished,the intent is that this Bond shall
be construed as a statutory bond and not as a common law bond.
A Upon request by any person or entity appearing to be a potential beneficiary of this Bond,the Contractor and
Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made.
16. DEFINITIONS
161 Claim.A written statement by the Claimant including at aminimum:
.1 the name of the Claimant;
.2 the name of the person for whom the labor was done,or materials or equipment furnished;
.3 a copy of the agreement or purchase order pursuant to which labor,materials or equipment was furnished
for use in the performance of the Construction Contract;
.4a brief description of the labor,materials or equipment furnished;
.5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the
performance of the Construction Contract;
.tithe total amount earned by the Claimant for labor,materials or equipment furnished as of the date of the
Claim;
.7 the total amount of previous payments received by the Claimant;and,
.8 the total amount due and unpaid to the Claimant for labor,materials or equipment furnished as of the date
of the Claim.
16.2 Claimant:An individual or entity having a direct contract with the Contractor or with a subcontractor of the
Contractor to furnish labor,materials,or equipment for use in the performance of the Construction Contract.
The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable
mechanic's lien or similar statute against the real property upon which the Project is located. The intent of
this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of
water,gas power, light, heat, oil gasoline, telephone service or rental equipment used in the Construction
Contract, architectural and engineering services required for performance of the work of the Contractor
Printed in cooperation with the American Institute of Architects(AIA)by Chubb. The language in this document conforms to the language used in
AIA DocumentA312'n'-2010.
Form 15.02.0574•FED(Rev,11/16) 3
and the Contractor's subcontractors,and all other items for which a mechanic's lien may be asserted in the
jurisdiction where the labor,materials or equipment were furnished.
16.3 Construction Contract: The agreement between the Owner and the Contractor identified on the cover
page,including all Contract Documents and all changes made to the agreement and the Contract Documents.
16.40wner Default:Failure of the Owner,which has neither been remedied nor waived,to pay the Contractor
as required under the Construction Contract or to perform and complete or comply with the other material
terms of the Construction Contract.
16.9 Contract Documents.All the documents that comprise the agreement between the Owner and Contractor.
17. If this Bond is issued for an agreement between a Contractor and subcontractor,the term Contractor in this
Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor.
I& MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
18.1"Claim notices for FEDERAL INSURANCE COMPANY must be sent to the following address: Chubb,PO Box 2191,
Chesapeake,Virginia 23327,Attention:Surety SupportTeam."
(Space is provided below for additional signatures of added parties,other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (CorporateSeal) Company: (Corporate Seal)
Federal Insurance Company
Signature: Signature:
Name and Title: Name and Title:
Address: Address:
Printed in cooperation with the American Institute of Architects(ALA)by Chubb. The language in this document conforms to the language used in
AIA Document A312 T"'-2010.
Form 15.02.0574•FED(Rev.tl/io 4
CHUBB'
Power of Attorney
Federal Insurance Company I Vigilant Insurance Company I Pacific Indemnity Company
Know All by These Presents,That FEDERAL INSURANCE COMPANY,an Indiana corporation,VIGILANT INSURANCE COMPANY,a New York corporation,and PACIFIC
INDEMNITY COMPANY,a Wisconsin corporation,do each hereby constitute and appoint Anna Childress, Mark W. Edwards, II,Alisa B. Ferris, Robert R. Freel,
Ronald B.Giadrosich,Richard H.Mitchell,William M.Smith and Jeffrey M.Wilson of Birmingham,Alabama;Robert Read Davis of Atlanta,Georgia;
Richard E.Daniels of Pensacola,Florida;Robert M.Verdin of Metairie,Louisiana---------------------------------------------------------------------------------------
each as their true and lawful Attorney-in-Fact to execute under such designation in their names and to affix their corporate seals to and deliver for and on their behalf as surety
thereon or otherwise,bonds and undertakings and other writings obligatory in the nature thereof(other than bail bonds)given or executed in the course of business,and any
instruments amending or altering the same,and consents to the modification or alteration of any instrument referred to in said bonds or obligations.
In Witness Whereof,said FEDERAL INSURANCB COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY have each executed and attested these
presents and affixed their corporate seals on this Not day ofjuly,2017.
&.L� �Wz l� 1
Dawn M.Chloros.Assistant Secretary Stephen M.liancy.Vice I1r4'sident
. s
0 1009.
STATE OF NEW JERSEY
Countyofflunterdon SS.
Onthis 14th day of July,2017 before me,a Notary Public of New Jersey,personally came Dawn M.Chloros,to me known to be Assistant Secretary of FEDERAL INSURANCE
COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY,the companies which executed the foregoing Power of Attorney,and the said Dawn M.
Chloros,being by me duly sworn,did depose and say that she is Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC
INDEMNITY COMPANY and knows the corporate seals thereof,that the seals affixed to the foregoing Power of Attorney are such corporate seals and were thereto affixed by
authority of said Companies;and that she signed said Power of Attorney as Assistant Secretary of said Companies by like authority;and that she is acquainted with Stephen M.
Haney,and knows him to be Vice President of said Companies;and that the signature of Stephen M.Haney,subscribed to said Power of Attorney is in the genuine handwriting of
Stephen M.Haney,and was thereto subscribed by authority ofsaid Companies and in deponent's presence.
Notarial Seal Poi KATHERINE A ADELAAR
pOTAgy g NOTARY PUBLIC OF NEW JERSEY
Om No.2318586
PUBLIC Comnvstaion Explts6 July 16,2018 �
.p Notary Public
JERg
CERTIFICATION
Resolutions adopted by the Boards of Directors of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY on August 30,2016:
"RESOLVED,that the following authorizations relate to the execution,for and on behalf of the Company,ofbonds,undertakings,recognizances,contracts and other written commitments of the Company
entered into in the ordinary course of business(each a"Written Commitment'l:
(1) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized to execute any Written Commitment for and on behalfof the Company,under the
seal of the Company or otherwise.
(2) Each duly appointed attorney-in-fact of the Company is hereby authorized to execute any written Commitment for and on behalf of the Company,under the seal of the Company or
otherwise,to the extent that such action is authorized by the grant of powers provided for in such person's written appointment as such attorney-in-fact.
(3) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalfof the Company,to appoint in writing any person the attomey-
in-fact of the Company with full power and authority to execute,for and on behalf of the Company,under the seal of the Company or otherwise,such written Commitments of the
Company as may be specified in such written appointment,which specification may be by general type or class of written Commitments or by specification of one or more particular
Written Commitments.
(4) Each of the Chairman,the President and the Vice Presidents of the Company is hereby authorized,for and on behalf of the Company,to delegate in writing to any other officer of the
Company the authority to execute,for and on behalf of the Company,under the Company's seal or otherwise,such Written Commitments of the Company as are specified in such
written delegation,which specification may be by general typeor classof Written Commitments or byspeciRcationofoneor more particular Written Commitments.
(5) The signature of any officer or other person executing any Written Commitment or appointment or delegation pursuant to this Resolution,and the seal of the Company,maybe affixed by
facsimile on such Written Commitment or written appointment or delegation.
FURTHER RESOLVED,that the foregoing Resolution shall not be deemed to be an exclusive statement of the powers and authority of officers,employees and other persons to act for and on behalfof
the Company,and such Resolution shall not limit or otherwise affect the exercise of any such power or authority otherwise validly granted or vested."
I,Dawn M.Chloros,Assistant Secretary of FEDERAL INSURANCE COMPANY,VIGILANT INSURANCE COMPANY,and PACIFIC INDEMNITY COMPANY(the"Companies")do hereby
certify that
(I) the foregoing Resolutions adopted by the Board of Directors of the Companies are true,correct and in full force and effect,
(ii) the Companies are duly licensed and authorized to transact surety business in all 50 of the United States of America and the District of Columbia and are
authorized by the U.S.Treasury Department;further,Federal and Vigilant are licensed in the U.S.Virgin Islands,and Federal is licensed in Guam,Puerto Rico,
and each of the Provinces of Canada except Prince Edward Island;and
(iii) the foregoing Power of Attorney is true,correct and in full force and effect.
Given under my hand and seals of said Companies at Whitehouse Station,M,this
Rwrn\I.Chloros.Assistant Nmretar?
IN THE EVENT YOU WISH TO NOTIFY US OF A CLAIM,VERIFY THE AUTHENTICITY OF THIS BOND OR NOTIFY US OF ANY OTHER MATTER,PLEASE CONTACT US AT-
Telephone(908)903.3493 Fax(908)903-3656 e-mail:surety@chubb.com
r
Form 15-10-0225B-U GEN CONSENT(rev.12-16)