Loading...
HomeMy WebLinkAbout06-26-17 City Commission Packet Materials - C9. Construction Agreement with L&L Site Services for 801 N. Rouse Demolition[m1] Commission Memorandum REPORT TO: Honorable Mayor and City Commission FROM: Mike Gray, Facilities Superintendent Anna Rosenberry, Assistant City Manager SUBJECT: Construction Contract for Demolition Services for property located at 801 N. Rouse Avenue. MEETING DATE: June 26, 2017 AGENDA ITEM TYPE: Consent RECOMMENDATION: Authorize the Interim City Manager to sign Construction Contract for Demolition Services for property located at 801 N. Rouse Avenue. Services will be contracted with L&L Site Services Inc.. SUGGESTED MOTION: Authorize the Interim City Manager to sign Construction Contract for Demolition Services for property located at 801 N. Rouse Avenue.. Services will be contracted with L&L Site Services Inc.. BACKGROUND: House located at 801 N. Rouse will be removed, the vacant property will become part of the existing shops complex. UNRESOLVED ISSUES: ALTERNATIVES: FISCAL EFFECTS: Funds are allocated in the current Public Work Budget to cover all associated cost with the requested Construction Contract. Attachments: Construction Contract for Demolition Services at 801 N. Rouse Ave. Attachment “A”, Scope of Work for Demolition Services at 801 N. Rouse Ave. Demo Bid, 801 N. Rouse Ave., L&L Site Service Inc. Report compiled on: June 8, 2017 103 Page 1 of 15 CONSTRUCTION AGREEMENT This Construction Agreement is made this ____ day of June, 2016, by and between the CITY OF BOZEMAN, MONTANA, a municipal corporation organized and existing under the laws of the State of Montana, P.O. Box 1231, Bozeman, Montana 59771-1231 (“City”), and L&L Site Services Inc., P.O. Box 1403, Belgrade MT 59714, (“Contractor”). In consideration of the covenants, agreements, representations, and warranties contained herein, the parties agree as follows: 1. Work to be Performed: a. A description of the work to be performed for demolition services at 801 N. Rouse Ave (the “Construction Project”) and Contractor’s duties is set forth in the drawings, plans, and specifications provided by the City, which are incorporated herein by this reference, and in the attached Scope of Services (Attachment A). b. Prior to the commencement of any work on the Construction Project, Contractor’s representatives and City’s representatives shall hold a meeting to establish a working understanding among the parties as to the scope of the Construction Project and duties of the Contractor. At this meeting, Contractor and City shall resolve any outstanding issues related to the plans, designs, drawings, and specifications. If the parties are unable to resolve these issues and the City fails, refuses, or is unable to approve the same, no work shall commence on the Construction Project until such issues are resolved and the City approves the related plans, designs, drawings, and specifications. c. Except as provided elsewhere in this Agreement, Contractor shall furnish all the labor, materials, equipment, tools, and services necessary to perform and complete the Construction Project. d. During work on the Construction Project, and as part of the final completion of the Construction Project, Contractor shall clean up the Project site, including the removal and satisfactory disposal of all waste, garbage, excess materials, and equipment, and the performance of any other work necessary to restore the site to at least as good order and condition as at the commencement of the Construction Project. 2. City-Supplied Materials: The City may supply materials from time to time in furtherance of the Construction Project. Such materials will be noted as an addendum to this Agreement. 3. Time of Performance: Contractor shall begin the Construction Project after receiving a Notice to Proceed from City and shall complete the Construction Project no later than December 31, 2017. Time is of the essence of completion of all work and each phase of the Construction Project. 104 Page 2 of 15 4. Liquidated Damages: If the Construction Project is not completed within the time provided by this Agreement, the City may deduct for each day the Construction Project remains uncompleted the sum of Five Hundred Dollars ($500.00) from the compensation hereinafter specified and retain that sum as payment for liquidated damages sustained by reason of the Contractor’s failure to complete the Construction Project on time. 5. Compensation: a. City shall pay to Contractor, and Contractor shall accept as full payment for the performance of this Agreement and the Construction Project, the amount of Twelve Thousand Dollars ($12,000). b. If work not included within the original Construction Documents is requested by City, such additional work and the related compensation shall be agreed to in writing by both parties prior to commencement of the additional work (“Change Order”). If abatement activities are required from the testing that is performed, the Contractor will provide the City with a written estimate for the amount required for abatement. City will approve this work prior to any work starting. c. City shall retain five percent (5%) of the total amount of compensation to be paid to the Contractor to ensure compliance with the terms and conditions of this Agreement and the timely completion of the Construction Project and any and all “punch list” items (“Retainage Amount”). The Retainage Amount shall be paid to Contractor thirty (30) days after the City’s final acceptance of the portion of work for which a separate price is stated in the specifications for the Construction Project. e. Upon acceptance of final payment and for other good and valuable consideration, Contractor shall and hereby does release and forever discharge City, its officers, agents, and employees of and from any and all claims, demands, actions, causes of action, obligations, and liabilities of every kind and character whatsoever, in law and in equity, whether now known or in the future discovered, arising from or related to this Agreement or the Construction Project that Contractor may have or assert against City, its officers, agents, and employees. 6. Inspection and Testing: a. City has the right to inspect and test any and all work performed by Contractor on the Construction Project. Contractor shall allow City and its agents access to the Construction Project at all times and shall provide every reasonable facility for the purpose of such inspection and testing, including temporarily discontinuing portions of the work or uncovering or taking down portions of the finished work. Any inspection and testing performed by the City and its agents is for the sole benefit of the City and shall not relieve the Contractor of its duty, responsibility, and obligation to ensure that the work strictly complies with the Agreement terms and conditions and all applicable laws and building and safety codes. City’s inspection and testing shall not be deemed or considered acceptance by the City of any portion of the Construction Project. City’s 105 Page 3 of 15 inspection and testing shall not serve to nullify, amend, or waive any warranties provided by the Contractor under this Agreement. b. Contractor shall, without charge, replace any material or correct any work found by the City or its agents to be defective or otherwise not in compliance with the terms and conditions of this Agreement. In the event Contractor fails to replace or correct any defective work or materials after reasonable written notice by the City to do so, the City may take such corrective action, either with its own materials and employees or by retaining any third party to do so, and deduct the cost and expense of such corrective action from the Contractor’s compensation. 7. Partial Utilization of Construction Project: City shall have the right to use or occupy any portion of the Construction Project that City and Contractor mutually agree is substantially completed and constitutes a separately functioning and usable part of the Construction Project for its intended purpose without significant interference with Contractor’s performance of the remaining portions of the Construction Project. In the event City takes possession of any portion of the Construction Project, such possession shall not be deemed an acceptance of the Construction Project, in whole or in part. City’s use of any portion of the Construction Project shall not be grounds for extensions of any construction deadlines or a change in the Contractor’s compensation. Contractor’s warranties shall run from the completion of the total Construction Project and not from the date the City may take possession of selected portions of the Construction Project. 8. Related Work at the Site: Nothing in this Agreement shall prevent or preclude City, through its own employees or by contract with any third party, from performing other work related to the Construction Project at the construction site; provided such related work is not otherwise addressed in this Agreement and provided such related work does not otherwise interfere with Contractor’s performance of this Agreement or the completion of the Construction Project. Contractor shall afford any City employee, agent or representative, or any third party under contract with the City to perform the related work, proper and safe access to the construction site, a reasonable opportunity for the introduction and storage of materials and equipment, the opportunity to perform the related work, and shall properly coordinate the Contractor’s work on the Construction Project with the related work. 9. Contractor’s Warranties: Contractor represents and warrants as follows: a. Unless otherwise specified by the terms of this Agreement, all materials and equipment used by Contractor on the Construction Project shall be new and where not otherwise specified, of the most suitable grade for their intended uses. b. All workmanship and materials shall be of a kind and nature acceptable to the City. c. All equipment, materials, and labor provided to, on, or for the Construction Project must be free of defects and nonconformities in design, materials, and workmanship for a minimum period beginning with the commencement of the work 106 Page 4 of 15 on the Construction Project and ending one (1) year from the final completion and acceptance by the City of the Construction Project, regardless of whether such equipment, materials, or labor were supplied directly by Contractor or indirectly by Contractor’s subcontractors or suppliers. Other express warranties on materials that provide for a warranty period longer than one year apply for the period of that express warranty and are not reduced by this provision. Upon receipt of City’s written notice of a defective or nonconforming condition during the warranty period, Contractor shall take all actions, including redesign and replacement, to correct the defective or nonconforming condition within a time frame acceptable to the City and at no additional cost to the City. Contractor shall also, at its sole cost, perform any tests required by City to verify that such defective or nonconforming condition has been corrected. Contractor warrants the corrective action taken against defective and nonconforming conditions for a period of an additional one (1) year from the date of City’s acceptance of the corrective action. d. Contractor and its sureties are liable for the satisfaction and full performance of all warranties. e. Contractor shall give its personal attention to the faithful prosecution of the completion of the Construction Project and Contractor, or its duly authorized representative assigned to serve as the Construction Project Manager, shall be personally present at the site of the Construction Project during working hours for the term of this Agreement until the completion of the Construction Project. f. Contractor shall have a complete, accurate, and up-to-date set of construction plans, drawings, and specifications on site at all times. g. Contractor has examined all available records and made field examinations of the site of the Construction Project. Contractor has knowledge of the field conditions to be encountered during the Construction Project. Contractor has knowledge of the types and character of equipment necessary for the work, the types of materials needed and the sources of such materials, and the condition of the local labor market. h. Contractor is responsible for the safety of the work and shall maintain all lights, guards, signs, temporary passages, or other protections necessary for that purpose at all times. i. All work must be performed at Contractor’s risk, and Contractor shall promptly repair or replace all damage and loss at its sole cost and expense regardless of the reason or cause of the damage or loss; provided, however, should the damage or loss be caused by an intentional or negligent act of the City, the risk of such loss shall be placed on the City. 107 Page 5 of 15 j. Contractor is responsible for any loss or damage to materials, tools, or other articles used or held for use in the completion of performance of the Construction Project. k. Contractor’s performance must be without damage or disruption to any other work or property of the City or of others and without interference with the operation of existing machinery or equipment. l. Title to all work, materials, and equipment covered by any payment of Contractor’s compensation by City, whether directly incorporated into the Construction Project or not, passes to City at the time of payment, free and clear of all liens and encumbrances. 10. Delays and Extensions of Time: If Contractor’s performance of this Agreement is prevented or delayed by any unforeseen cause beyond the control of the Contractor, including acts or omissions of the City, Contractor shall, within ten (10) days of the commencement of any such delay, give the City written notice thereof. Further, Contractor shall, within ten (10) days of the termination of such delay, give the City written notice of the total actual duration of the delay. If the City is provided with these required notices and if the City determines that the cause of the delay was not foreseeable, was beyond the control of the Contractor, and was not a result of the fault or negligence of the Contractor, then the City will determine the total duration of the delay and extend the time for performance of the Agreement accordingly. Unless the delay is caused by the intentional interference of the City with the Contractor’s performance, Contractor shall make no claim for damages or any other claim other than for an extension of time as herein provided by reason of any delays. 11. Suspension: a. The City may, by written notice to the Contractor and at its convenience for any reason, suspend the performance of all or any portion of the work to be performed on the Construction Project (“Notice of Suspension”). The Notice of Suspension shall set forth the time of suspension, if then known to the City. During the period of suspension, Contractor shall use its best efforts to minimize costs associated with the suspension. b. Upon Contractor’s receipt of any Notice of Suspension, unless the notice requires otherwise, Contractor shall: (1) immediately discontinue work on the date and to the extent specified in the Notice of Suspension; (2) place no further orders or subcontracts for materials, services, or equipment; (3) promptly make every reasonable effort to obtain suspension upon terms satisfactory to City of all orders, subcontracts, and rental agreements to the extent that they relate to the performance of the work suspended; and (4) continue to protect and maintain the Project, including those portions on which work has been suspended. c. As compensation for the suspended work, Contractor will be reimbursed for the following costs, reasonably incurred, without duplication of any item, and to the extent that such costs directly resulted from the suspension: (1) a standby charge paid 108 Page 6 of 15 during the period of suspension which will be sufficient to compensate Contractor for keeping, to the extent required in the Notice of Suspension, Contractor’s organization and equipment committed to the Project in standby status; (2) all reasonably incurred costs for the demobilization of Contractor’s and subcontractor’s crews and equipment; (3) an equitable amount to reimburse Contractor for the cost to protect and maintain the Project during the period of suspension; and (4) an equitable adjustment in the cost of performing the remaining portion of the work post-suspension if, as a direct result of the suspension, the cost to Contractor of subsequently performing the remaining work on the Construction Project has increased or decreased. d. Upon receipt of written notice by the City to resume the suspended work (“Notice to Resume Work”), Contractor shall immediately resume performance of the suspended work as to the extent required in the Notice to Resume Work. Any claim by Contractor for time or compensation described in Section 11(c) shall be made within fifteen (15) days after receipt of the Notice to Resume Work and Contractor shall submit a revised Construction Schedule for the City’s review and approval. Contractor’s failure to timely make such a claim shall result in a waiver of the claim. e. No compensation described in Section 11(c) shall be paid and no extension of time to complete the Construction Project shall be granted if the suspension results from Contractor’s non-compliance with or breach of the terms or requirements of this Agreement. 12. Termination for Contractor’s Fault: a. If Contractor refuses or fails to timely do the work, or any part thereof, or fails to perform any of its obligations under this Agreement, or otherwise breaches any terms or conditions of this Agreement, the City may, by written notice, terminate this Agreement and the Contractor’s right to proceed with all or any part of the Construction Project (“Termination Notice Due to Contractor’s Fault”). The City may then take over the Construction Project and complete it, either with its own resources or by re-letting the contract to any other third party, and may immediately take possession of and use such materials, appliances, tools, and equipment as may be on the site and which may be necessary for the completion of the Construction Project. b. In the event of a termination pursuant to this Section 12, Contractor shall be entitled to payment only for those services Contractor actually rendered. In the case of a lump sum or unit price contract, Contractor shall not be entitled to any further payment until the Construction Project has been completed. Upon completion of the Construction Project, if the unpaid balance of the Contractor’s compensation exceeds the cost to the City of completing the work, including all costs paid to any subcontractors or third parties retained by the City to complete the Construction Project and all administrative costs resulting from the termination (“City’s Cost for Completion”), such excess shall be paid to the Contractor. If the City’s Cost for Completion exceeds the unpaid balance of the Contractor’s compensation, then Contractor and its sureties shall be liable for and shall pay the difference, plus interest at the rate applicable to court judgments, to the City. 109 Page 7 of 15 c. Any termination provided for by this Section 12 shall be in addition to any other remedies to which the City may be entitled under the law or at equity. d. In the event of termination under this Section 12, Contractor shall, under no circumstances, be entitled to claim or recover consequential, special, punitive, lost business opportunity, lost productivity, field office overhead, general conditions costs, or lost profits damages of any nature arising, or claimed to have arisen, as a result of the termination. 13. Termination for City’s Convenience: a. Should conditions arise which, in the sole opinion and discretion of the City, make it advisable to the City to cease work on the Construction Project, City may terminate this Agreement by written notice to Contractor (“Notice of Termination for City’s Convenience”). The termination shall be effective in the manner specified in the Notice of Termination for City’s Convenience and shall be without prejudice to any claims that the City may otherwise have against Contractor. b. Upon receipt of the Notice of Termination for City’s Convenience, unless otherwise directed in the Notice, the Contractor shall immediately cease work on the Construction Project, discontinue placing orders for materials, supplies, and equipment for the Construction Project, and make every reasonable effort to cancel all existing orders or contracts upon terms satisfactory to the City. Contractor shall do only such work as may be necessary to preserve, protect, and maintain work already completed, in progress, or in transit to the construction site. c. In the event of a termination pursuant to this Section 13, Contractor is entitled to payment only for those services Contractor actually rendered and materials actually purchased or which Contractor has made obligations to purchase on or before the receipt of the Notice of Termination for City’s Convenience, and reasonably incurred costs for demobilization of Contractor’s and any subcontractor’s crews. It is agreed that any materials that City is obligated to purchase from Contractor will remain the City’s sole property. d. The compensation described in Section 13(c) is the sole compensation due to Contractor for its performance of this Agreement. Contractor shall, under no circumstances, be entitled to claim or recover consequential, special, punitive, lost business opportunity, lost productivity, field office overhead, general conditions costs, or lost profits damages of any nature arising, or claimed to have arisen, as a result of the termination. 14. Limitation on Contractor’s Damages; Time for Asserting Claim: a. In the event of a claim for damages by Contractor under this Agreement, Contractor’s damages shall be limited to contract damages and Contractor hereby 110 Page 8 of 15 expressly waives any right to claim or recover consequential, special, punitive, lost business opportunity, lost productivity, field office overhead, general conditions costs, or lost profits damages of any nature or kind. b. In the event Contractor wants to assert a claim for damages of any kind or nature, Contractor shall provide City with written notice of its claim, the facts and circumstances surrounding and giving rise to the claim, and the total amount of damages sought by the claim, within ten (10) days of the facts and circumstances giving rise to the claim. In the event Contractor fails to provide such notice, Contractor shall waive all rights to assert such claim. 15. Representatives: a. City’s Representative: The City’s Representative for the purpose of this Agreement shall be Mike Gray, Facilities Superintendent or such other individual as City shall designate in writing. Whenever approval or authorization from or communication or submission to City is required by this Agreement, such communication or submission shall be directed to the City’s Representative and approvals or authorizations shall be issued only by such Representative; provided, however, that in exigent circumstances when City’s Representative is not available, Contractor may direct its communication or submission to other designated City personnel or agents and may receive approvals or authorization from such persons. b. Contractor’s Representative: The Contractor’s Representative for the purpose of this Agreement shall be Lance Johnson or such other individual as Contractor shall designate in writing. Whenever direction to or communication with Contractor is required by this Agreement, such direction or communication shall be directed to Contractor’s Representative; provided, however, that in exigent circumstances when Contractor’s Representative is not available, City may direct its direction or communication to other designated Contractor personnel or agents. 16. Locating Underground Facilities: Contractor shall be responsible for obtaining and determining the location of any underground facilities, including but not limited to, the location of any pipelines or utility supply, delivery, or service lines in accordance with the provisions of §69-4-501, et seq., MCA. Contractor shall make every effort to avoid damage to underground facilities and shall be solely responsible for any damage that may occur. If City personnel assume responsibility for locating any underground facilities, this fact shall be noted in writing prior to commencement of such location work. 17. Permits: Contractor shall provide all notices, comply with all applicable laws, ordinances, rules, and regulations, obtain all necessary permits, licenses, including a City of Bozeman business license, and inspections from applicable governmental authorities, pay all fees and charges in connection therewith, and perform all surveys and locations necessary for the timely completion of the Construction Project. 111 Page 9 of 15 18. Ownership of Documents; Indemnification: All plans, designs, drawings, specifications, documents, sample results and data, in whatever medium or format, originated or prepared by or for Contractor in contemplation of, or in the course of, or as a result of this Agreement or work on the Construction Project, shall be promptly furnished to the City (“City Documents and Information”). All City Documents and Information shall be the exclusive property of the City and shall be deemed to be works-for-hire. Contractor hereby assigns all right, title, and interest in and to the City Documents and Information, including but not limited to, all copyright and patent rights in and to the City Documents and Information. Neither party grants to the other any express or implied licenses under any patents, copyrights, trademarks, or other intellectual property rights, except to the extent necessary to complete its obligations to the other under this Agreement. 19. Laws and Regulations: Contractor shall comply fully with all applicable state and federal laws, regulations, and municipal ordinances including, but not limited to, all workers’ compensation laws, all environmental laws including, but not limited to, the generation and disposal of hazardous waste, the Occupational Safety and Health Act (OSHA), the safety rules, codes, and provisions of the Montana Safety Act in Title 50, Chapter 71, MCA, all applicable City, County, and State building and electrical codes, the Americans with Disabilities Act, and all non-discrimination, affirmative action, and utilization of minority and small business statutes and regulations. 20. Nondiscrimination: The Contractor shall have a policy to provide equal employment opportunity in accordance with all applicable state and federal anti-discrimination laws, regulations, and contracts. The Contractor shall not refuse employment to a person, bar a person from employment, or discriminate against a person in compensation or in a term, condition, or privilege of employment because of race, color, religion, creed, political ideas, sex, age, marital status, national origin, actual or perceived sexual orientation, gender identity, physical or mental disability, except when the reasonable demands of the position require an age, physical or mental disability, marital status or sex distinction. The Contractor shall be subject to and comply with Title VI of the Civil Rights Act of 1964; Section 140, Title 2, United States Code, and all regulations promulgated thereunder. The Contractor shall require these nondiscrimination terms of its sub-contractors providing services under this Agreement. 21. Intoxicants; DOT Drug and Alcohol Regulations: Contractor shall not permit or suffer the introduction or use of any intoxicants, including alcohol or illegal drugs, upon the site of the Construction Project. Contractor acknowledges it is aware of and shall comply with its responsibilities and obligations under the U.S. Department of Transportation (DOT) regulations governing anti-drug and alcohol misuse prevention plans and related testing. City shall have the right to request proof of such compliance and Contractor shall be obligated to furnish such proof. 22. Labor Relations: a. In the event that, during the term of this Agreement and throughout the course of Contractor’s performance of the Construction Project, any labor problems or disputes of any type arise or materialize which in turn cause any work on the 112 Page 10 of 15 Construction Project to cease for any period of time, Contractor specifically agrees to take immediate steps, at its own expense and without expectation of reimbursement from City, to alleviate or resolve all such labor problems or disputes. The specific steps Contractor shall take to resume work on the Construction Project shall be left to the discretion of Contractor; provided, however, that Contractor shall bear all costs of any related legal action. Contractor shall provide immediate relief to the City so as to permit the work on the Construction Project to resume and be completed within the time frames set forth in the Construction Schedule at no additional cost to City. b. Contractor shall indemnify, defend, and hold the City harmless from any and all claims, demands, costs, expenses, damages, and liabilities arising out of, resulting from, or occurring in connection with any labor problems or disputes or any delays or stoppages of work associated with such problems or disputes. 23. Subcontractors: a. Contractor may employ subcontractors for any work on the Construction Project. Contractor shall provide City with a list of all subcontractors employed. b. Contractor remains fully responsible for the acts and omissions of any subcontractor, just as Contractor is for its own acts and omissions, and Contractor shall remain fully responsible and liable for the timely completion of the Construction Project. c. Contractor is solely liable for any and all payments to subcontractors. Contractor shall hold all payments received from the City in trust for the benefit of subcontractors, and all such payments shall be used to satisfy obligations of the Construction Project before being used for any other purpose. Contractor shall make any payments due to any subcontractor within seven (7) days of Contractor’s receipt of payment, including a proportional part of the retainage Contractor has received from the City. In the event of a dispute regarding any subcontractor’s invoice, Contractor shall promptly pay the undisputed amount to the subcontractor and notify the subcontractor in writing of the amount in dispute and the reasons for the dispute. Any withholding of payment must comply with the requirements of §28-2-2103, MCA. In the event Contractor is unwilling or unable to make timely and proper payment to any subcontractor, City may elect to withhold any payment otherwise due to Contractor and upon seven (7) days’ written notice to Contractor, may pay subcontractor by direct or joint payment. 24. Indebtedness and Liens: Before City may make any final payment to Contractor, Contractor shall furnish City with satisfactory proof that there are no outstanding debts or liens in connection with the Construction Project. If the Contractor allows any indebtedness to accrue to subcontractors or others during the progress of the work, and fails to pay or discharge the same within five (5) days after demand, then City may either withhold any money due to Contractor until such indebtedness is paid or apply the same towards the discharge of the indebtedness. If any lien or claim is filed or made by any subcontractor, material supplier, 113 Page 11 of 15 or any other person, the Contractor shall immediately notify the City and shall cause the same to be discharged of record within thirty (30) days after its filing. 25. Hazard Communication: Contractor shall comply with all hazard communication requirements dictated by the Environmental Protection Agency, the Montana Department of Agriculture, OSHA, Hazard Communications Standard, 29 CFR 1910.1200, and applicable City ordinances. Contractor shall supply a chemical list, the associated material safety data sheets (MSDS), and other pertinent health exposure data for chemicals that the Contractor’s, subcontractor’s or the City’s employees may be exposed to while working on City property during the course of the Construction Project. One copy of this documentation must be delivered to City to the attention of the City’s Representative. This documentation must be delivered before work involving these chemicals may commence. 26. Accounts and Records: During the term of this Agreement and for two (2) years following the City’s final acceptance of the Construction Project, Contractor shall maintain accounts and records related to the Construction Project. Upon reasonable notice, City shall have the right to inspect all such accounts and records, including but not limited to, Contractor’s records, books, correspondence, instructions, drawings, specifications, field and site notes, receipts, invoices, bills, contracts, or other documents relating to the Construction Project. 27. Indemnification; Insurance; Bonds: a. Contractor agrees to release, defend, indemnify, and hold harmless the City, its agents, representatives, employees, and officers (collectively referred to for purposes of this Section as the City) from and against any and all claims, demands, actions, fees and costs (including attorney’s fees and the costs and fees of and expert witness and consultants), losses, expenses, liabilities (including liability where activity is inherently or intrinsically dangerous) or damages of whatever kind or nature connected therewith and without limit and without regard to the cause or causes thereof or the negligence of any party or parties that may be asserted against, recovered from or suffered by the City occasioned by, growing or arising out of or resulting from or in any way related to: (i) the negligent, reckless, or intentional misconduct of the Contractor; or (ii) any negligent, reckless, or intentional misconduct of any of the Contractor’s agents. b. Such obligations shall not be construed to negate, abridge, or reduce other rights or obligations of indemnity that would otherwise exist. The indemnification obligations of this Section must not be construed to negate, abridge, or reduce any common-law or statutory rights of the indemnitee(s) which would otherwise exist as to such indemnitee(s). c. Contractor’s indemnity under this Section shall be without regard to and without any right to contribution from any insurance maintained by City. d. Should any indemnitee described herein be required to bring an action against the Contractor to assert its right to defense or indemnification under this Agreement or under the Contractor’s applicable insurance policies required below the indemnitee shall be entitled to recover reasonable costs and attorney fees incurred in 114 Page 12 of 15 asserting its right to indemnification or defense but only if a court of competent jurisdiction determines the Contractor was obligated to defend the claim(s) or was obligated to indemnify the indemnitee for a claim(s) or any portion(s) thereof. e. In the event of an action filed against City resulting from the City’s performance under this Agreement, the City may elect to represent itself and incur all costs and expenses of suit. f. Contractor also waives any and all claims and recourse against the City or its officers, agents or employees, including the right of contribution for loss or damage to person or property arising from, growing out of, or in any way connected with or incident to the performance of this Agreement except “responsibility for his own fraud, for willful injury to the person or property of another, or for violation of law, whether willful or negligent” as per 28-2-702, MCA. g. These obligations shall survive termination of this Agreement and the services performed hereunder. h. In addition to and independent from the above, Contractor shall at Contractor’s expense secure insurance coverage through an insurance company or companies duly licensed and authorized to conduct insurance business in Montana which insures the liabilities and obligations specifically assumed by the Contractor in this Section. The insurance coverage shall not contain any exclusion for liabilities specifically assumed by the Contractor in subsection (a) of this Section. The insurance shall cover and apply to all claims, demands, suits, damages, losses, and expenses that may be asserted or claimed against, recovered from, or suffered by the City without limit and without regard to the cause therefore and which is acceptable to the City and Contractor shall furnish to the City an accompanying certificate of insurance and accompanying endorsements in amounts not less than as shown below:  Workers’ Compensation – not less than statutory limits;  Employers’ Liability - $1,000,000 per occurrence; $2,000,000 annual aggregate;  Commercial General Liability - $1,000,000 per occurrence; $2,000,000 annual aggregate;  Products and Completed Operations – $1,000,000;  Automobile Liability - $1,000,000 property damage/bodily injury; $2,000,000 annual aggregate (all owned, hired, non-owned vehicles);  Owner’s and Contractor’s Protective Liability: one policy designating the City (including its agents, representatives, employees, and officers) as the insured and another independent policy designated the City’s Representative (including its consultants, consultants, agents and employees) as the insured on the declarations with both policies covering: (i) operations performed by the Contractor under this Agreement for the City; and (ii) the City’s and City’s Representatives acts or omissions, including negligent acts, in connection with its general supervision of the work of the Contractor’s and its subcontractors - $1,000,000 per occurrence; $2,000,000 aggregate; 115 Page 13 of 15  Contractual Liability Insurance (covering the Contractor’s indemnity obligations described in this Agreement) - $1,000,000 per occurrence $2,000,000 aggregate The amounts of insurance provided shall be exclusive of defense costs. The City of Bozeman, its officers, agents, and employees, shall be endorsed as an additional or named insured on a primary non-contributory basis on both the Commercial General and Automobile Liability policies. The insurance and required endorsements must be in a form suitable to City and shall include no less than a thirty (30) day notice of cancellation or non-renewal. Contractor shall notify City within two (2) business days of Contractor’s receipt of notice that any required insurance coverage will be terminated or Contractor’s decision to terminate any required insurance coverage for any reason. The City must approve all insurance coverage and endorsements prior to the Contractor commencing work. i. Pursuant to the City’s authority provided for in 18-2-201(4), the Contractor shall not be required to provide bonds as required by 18-2-201(1) under this Agreement. 28. Taxes: Contractor is obligated to pay all taxes of any kind or nature and make all appropriate employee withholdings. Contractor understands that all contractors or subcontractors working on a publicly funded project are required to pay or have withheld from earnings a license fee of one percent (1%) of the gross contract price if the gross contract price is Five Thousand Dollars ($5,000) or more. This license fee is paid to the Montana Department of Revenue. 29. Dispute Resolution: a. Any claim, controversy, or dispute between the parties, their agents, employees, or representatives shall be resolved first by negotiation between senior-level personnel from each party duly authorized to execute settlement agreements. Upon mutual agreement of the parties, the parties may invite an independent, disinterested mediator to assist in the negotiated settlement discussions. b. If the parties are unable to resolve the dispute within thirty (30) days from the date the dispute was first raised, then such dispute shall be resolved in a court of competent jurisdiction in compliance with the Applicable Law provisions of this Agreement. 30. Survival: Contractor’s indemnification and warranty obligations shall survive the termination or expiration of this Agreement for the maximum period allowed under applicable law. 116 Page 14 of 15 31. Headings: The headings used in this Agreement are for convenience only and are not be construed as a part of the Agreement or as a limitation on the scope of the particular paragraphs to which they refer. 32. Waiver: A waiver by City of any default or breach by Contractor of any covenants, terms, or conditions of this Agreement does not limit City’s right to enforce such covenants, terms, or conditions or to pursue City’s rights in the event of any subsequent default or breach. 33. Severability: If any portion of this Agreement is held to be void or unenforceable, the balance thereof shall continue in effect. 34. Applicable Law: The parties agree that this Agreement is governed in all respects by the laws of the State of Montana. 35. Binding Effect: This Agreement is binding upon and inures to the benefit of the heirs, legal representatives, successors, and assigns of the parties. 36. Amendments: This Agreement may not be modified, amended, or changed in any respect except by a written document signed by all parties. 37. No Third-Party Beneficiary: This Agreement is for the exclusive benefit of the parties, does not constitute a third-party beneficiary agreement, and may not be relied upon or enforced by a third party. 38. Counterparts: This Agreement may be executed in counterparts, which together constitute one instrument. 39. Assignment: Contractor may not assign this Agreement in whole or in part without the prior written consent of the City. No assignment will relieve Contractor of its responsibility for the performance of the Agreement and the completion of the Construction Project. Contractor may not assign to any third party other than Contractor’s subcontractors on the Construction Project, the right to receive monies due from City without the prior written consent of City. 40. Authority: Each party represents that it has full power and authority to enter into and perform this Agreement and the person signing this Agreement on behalf of each party has been properly authorized and empowered to sign this Agreement. 41. Independent Contractor: The parties agree and acknowledge that in the performance of this Agreement and the completion of the Construction Project, Contractor shall render services as an independent contractor and not as the agent, representative, subcontractor, or employee of the City. The parties further agree that all individuals and companies retained by Contractor at all times will be considered the agents, employees, or independent contractors of Contractor and at no time will they be the employees, agents, or representatives of the City. 117 Page 15 of 15 42. Integration: This Agreement and all Exhibits attached hereto constitute the entire agreement of the parties. Covenants or representations not contained therein or made a part thereof by reference, are not binding upon the parties. There are no understandings between the parties other than as set forth in this Agreement. All communications, either verbal or written, made prior to the date of this Agreement are hereby abrogated and withdrawn unless specifically made a part of this Agreement by reference. IN WITNESS WHEREOF, Contractor and City have caused this Agreement to be executed, effective on the date written above, and intend to be legally bound thereby. CITY OF BOZEMAN, MONTANA CONTRACTOR By: _______________________________ By: Dennis Taylor, Interim City Manager Print Name: Title: APPROVED AS TO FORM (§18-2-406, MCA): By: _______________________________ Greg Sullivan, City Attorney 118 Attachment –A City of Bozeman Demolition Service at 801 N. Rouse Avenue Attachment - A Demolition Services at 801 N. Rouse Ave, Bozeman, MT 59715 Scope/Requirements:  Contractor will be responsible for the testing for hazardous materials as required by regulatory requirements.  Any mitigation required from testing a written estimate will be provided to the City for approval prior to work starting.  Contractor will be responsible for attaining a demolition permit from the City of Bozeman, Building Inspection Division. o Demolition permit requires a performance bond.  City of Bozeman, Facilities Division has received Certificate of Appropriateness Decision and COA approval. Contractor will use this document for the demolition permit. Mike Gray has the documentation.  Contractor will be responsible for following all City of Bozeman Storm Water requirements.  Contractor will be responsible for following all municipal, state, and federal regulatory requirements.  All concrete will be removed from property. o House foundation and basement. o Old garage foundation o Close-line o East sidewalk  Required backfill will be clean with 95% dry density, provided by contractor.  Grounds will be level at the completion of the project; existing grass areas and landscaping not disturbed can remain in place.  No large trees will be removed during the demolition process; one small tree on the South West side of property can be removed for access.  City of Bozeman, Solid Waste Division will provide roll-offs, haul services, and waste disposal fees. o Roll-offs will be 40yd units. o Materials that can recycled should be to reduce waste removal costs. o City will haul to recycling areas. o Construction materials that are not recycled will be hauled to Logan.  City of Bozeman, Facilities Division will coordinate the removal of gas, electric, water and sewer services to building. 119 L&L Site Services, Inc P.O. Box 1403 Belgrade Mt 59714 406-388-7171 April 10, 2017 Mike Gray Thank you for the opportunity to look at your project in Bozeman, Montana. This proposal would include the complete tear down and loading of the building located at 801 N Rouse into City of Bozeman rolloff containers. This proposal would be a total demolition of the house in accordance to scope of work dated April 6, 2017 from Mike Gray. Proposal does include the processing of concrete to be accepted at recycling facility to lower landfill charges unless coated with materials deemed unacceptable to recycle. Proposal includes labor to hand sort final cleanup of loose material from ground to help eliminate heavy rolloffs going to landfill. After completion of the demolition the existing hole from foundation will be filled with pit run and compacted to achieve 95% dry density. Proposal doesn’t include any abatement or hauling of hazardous material, but does include testing for hazardous materials. Upon acceptance of this proposal a contract will be generated between the owner of building and L&L Site Services, Inc prior to starting of any work. Demolition cost: $12,000.00 Lance Johnson L&L site Services, Inc 120